Rolling Hills Community Development District

April 12, 2022

AGENDA

Rolling Hills Community Development District
475 West Town Place
Suite 114 St. Augustine, Florida 32092
District Website: www.RollingHillsCDD.com

April 5, 2022

Board of Supervisors
Rolling Hills Community Development District Dear Board Members:
The Rolling Hills Community Development District Meeting is scheduled for Tuesday, April 12, 2022 at 6:00 p.m. at the Rolling Hills Amenity Center, 3212 Bradley Creek Parkway, Green Cove Springs, Florida 32092.
Following is the advance agenda for the meeting:

Roll Call

Audience Comments (Regarding Agenda Items Listed Below)

Approval of Minutes of the February 3, 2022 Special Meeting and February 8, 2022 Meeting

Consideration of Resolution 2022-07, Instructing the Clay County Supervisor of Elections to Conduct the General Election

Consideration of Resolution 2022-08, Designating Kutak Rock LLP as Registered Agent and Registered Office

Consideration of Proposal from Parry Pools for Pool Refurbishment

Series 2020 Project:
Update Regarding Series 2020 Project

Ratification of Requisitions (72-78)

Series 2022 Project:
Update Regarding Series 2021 Project

Ratification of Requisitions (001 - 008)

Consideration of Work Authorization No. 1

Discussion on Stop Signs

Ratification of Construction Contract for Shadow Crest

Consideration of Renewal of Pool Use Agreement with Clay High School Swim Team

Other Business

Staff Reports
Attorney

Engineer – Draft Stormwater Needs Analysis

Manager – Qualifying Period for Seats 2, 4 and 5

Operations / Amenity Manager
Report

Monthly Quality Inspection Report

Tree Amigos Increase Letter

Tree Amigos Landscape Enhancement at Entrance Sign

Tree Amigos Landscape Enhancement at Flag Pole Island

Supervisor’s Requests

Audience Comments

Financial Reports
Balance Sheet & Income Statement

Assessment Receipt Schedule

Check Register

Next Scheduled Meeting: June 14, 2022 @ 6:00 p.m. at the Rolling Hills Amenity Center

Adjournment

Community Interest:

Amenity Center – Chairperson Jordan
Security & Technology –Supervisor Miller
Communications, Programming/Events, Finance & Accounting – Supervisor Riggs
Landscape & Pond Maintenance – Supervisor Church

THIRD ORDER OF BUSINESS

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

A special meeting of the Board of Supervisors of the Rolling Hills Community Development District was held Thursday, February 3, 2022 at 10:00 a.m. in the Rolling Hills Amenity Center, 3212 Bradley Creek Parkway, Green Cove Springs, Florida.

Present and constituting a quorum were:

Shannon Jordan	Chairperson
Rose Bock	Supervisor
David Church	Supervisor
Nate Riggs	Supervisor by telephone Also present were:
Marilee Giles	District Manager
Michelle Rigoni	District Counsel by telephone
Freddie Oca	Riverside Management
Cynthia Wilhelm	Nabors Giblin Nickerson by telephone
Sete Zare	MNS Capital Markets by telephone

The following is a summary of the discussions and actions taken at the February 3, 2022 meeting. An audio copy of the proceedings can be obtained by contacting the District Manager.

FIRST ORDER OF BUSINESS	Roll Call
Ms. Giles called the meeting to order at 10:00 a.m. and called the roll.

SECOND ORDER OF BUSINESS	Audience Comments
There not being any, the next item followed.

THIRD ORDER OF BUSINESS	Consideration	of	Resolution	2022-05
Amending	Resolution	2022-02	Delegated Award Resolution
Ms. Giles stated Resolution 2022-05 amends Resolution 2022-02, the delegated award resolution.

February 3, 2022	Rolling Hills CDD

Ms. Wilhelm stated the resolution amends Resolution 2022-02, which was adopted by the board in October. We thought we were going to be issuing bonds by the end of the calendar year, 2021. At the time we adopted the resolution we had a not to exceed par amount of approximately
$9.7 million, we are requesting an increase to approximately $12.5 million and we can confirm that we are going to be calling in the 2022 bonds if there are any issued in 2022.
Ms. Zare stated since we first approved the delegation resolution in October there has been quite a bit of cost adjustments as well as the adjustments in the market that provides for the flexibility to issue just a little bit more in principal. We are asking for an increase in the not to exceed to give a little more flexibility on the date of pricing.
Ms. Jordan asked by raising the not to exceed will this increase the cost to the residents?
Ms. Zare stated the assessment levels are consistent with what you see, it is just that there may be a little more flexibility. What this means to the end user is consistent with all the documents you have read at this point.
Ms. Jordan asked how does that not affect the end user if the bond amount is higher?
Ms. Zare stated that is the 2022A-2 component, the developer has responsibility of prepaying the 2022A-2 bonds down at the time of sale to a builder or to the end user.

On MOTION by Mr. Jordan seconded by Mr. Church with all in favor Resolution 2022-05 was approved.

FOURTH ORDER OF BUSINESS	Supervisors Requests
There being none, the next item followed.

FIFTH ORDER OF BUSINESS	Audience Comments
There being none, the next item followed.

SIXTH ORDER OF BUSINESS	Next Meeting Scheduled for February 8, 2022
@ 6:00 p.m. at Rolling Hills Amenity Center
Ms. Giles stated the next meeting is February 8, 2022 at 6:00 p.m. at this location.

On MOTION by Ms. Bock seconded by Ms. Jordan with all in favor the meeting adjourned at 10:08 a.m.

February 3, 2022	Rolling Hills CDD

Secretary/Assistant Secretary	Chairman/Vice Chairman

MINUTES OF MEETING
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

The regular meeting of the Board of Supervisors of the Rolling Hills Community Development District was held Tuesday, February 8, 2022 at 6:00 p.m. in the Rolling Hills Amenity Center, 3212 Bradley Creek Parkway, Green Cove Springs, Florida.

Present and constituting a quorum were:

Shannon Jordan	Chairperson
John Miller	Vice Chairman
David Church	Supervisor
Nate Riggs	Supervisor by telephone Also present were:
Marilee Giles	District Manager
Katie Buchanan	District Counsel
Keith Hadden	District Engineer
Freddie Oca	Riverside Management
Brian Stephens	Riverside Management
Bill Huck	Waltham Development by telephone
Scott Blunck	Garden Street Communities Southeast, LLC
Sete Zare	MBS Capital Markets
Brett Sealy	MBS Capital Markets

The following is a summary of the actions taken at the February 8, 2022 meeting. An audio copy of the proceedings can be obtained by contacting the District Manager.

FIRST ORDER OF BUSINESS	Roll Call
Ms. Giles called the meeting to order at 6:00 p.m. and called the roll.

SECOND ORDER OF BUSINESS	Audience Comments
Ms. Cormier asked under the twelfth order of business, what is a special call?
Ms. Buchanan stated that relates to the bonds, meaning it is not part of the district’s operating and maintenance budget, it is part of the debt service budget.

February 8, 2022	Rolling Hills CDD

Ms. Cormier stated the twelfth order of business under section C, they have not blacked out the Clay County Sheriff’s Officer’s address. It is something I have addressed a couple times about not having that on public records.
Ms. Jordan stated it is up to the officer to black that out or request that it be blacked out. Ms. Cormier asked under the sixth order of business, the requisition for the inspectors.
Mr. Hadden stated Clay County no longer does their own inspections. These roads will eventually be turned over to Clay County and the developer is required to obtain the services of one of two engineering firms and that they have inspectors out here every day and that is a monthly expenditure paid by the developer and they report to the county.
Ms. Cornier stated I know it has been addressed before but when is the service road getting built and it was recently discovered that it has not been turned over to the county.
Mr. Hadden stated the county doesn’t want it right now. There is a letter from about five years ago that stated that the county does not want the developer to build the road as part of the county’s overall road plan and there is a document that says whenever the county wants to take ownership of that strip the developer will give it to them.
Ms. Cormier stated I was at the planning and zoning meeting last week and they told me that they wanted that road but the developer will not turn it over.
Mr. Hadden stated you talked to Mike Brown who is head of the planning department his predecessor was the one instrumental in getting the document.
Ms. Buchanan stated I looked it up and the special call is part of the 2015 bond series and it is not related to the O&M assessments.

THIRD ORDER OF BUSINESS	Approval of the Minutes of the December 14,
2021 Meeting and January 19, 2022 Special Meeting

On MOTION by Ms. Jordan seconded by Mr. Church with all in favor the minutes of the December 14, 2021 and January 19, 2022 meetings were approved as presented.

FOURTH ORDER OF BUSINESS	Consideration of Fee Agreement with Kutak
Rock, LLP
Ms. Buchanan stated as you are aware Hopping Green & Sams special district group left to join the law firm of Kutak Rock and you previously authorized the transfer and this agreement

February 8, 2022	Rolling Hills CDD

formalizes the arrangement between the CDD and Kutak Rock. The hourly rates are the same as what you previously paid and the agreement is terminable at will, meaning should you decide that you are unhappy with our service you can immediately provide notice to terminate the agreement.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor the fee agreement with Kutak Rock LLP was approved.

FIFTH ORDER OF BUSINESS	Consideration	of	Resolution	2022-06
Supplemental Assessment Resolution
Ms. Buchanan stated Resolution 2022-06 is what we call the supplemental assessment resolution. What you previously authorized was for the district to issue bonds in connection with the phase 3B 3C project. We levied special assessments to secure those bonds and what we have done now is actually had MBS sell the bonds from the district to bondholders and in doing so locking in the specific rates the district will pay on those bonds. The whereas clauses go through the details of the district’s issuance history, we had new money deals as well as a refunding deal and this particular bond issuance refunds the bonds that were issued in 2015 known as the 2015A-3 Bonds. Section 3 goes through the findings and notes we did have due notice and a public hearing and allowed for public comment. It specifically incorporates the supplemental engineer’s report, which is attached as Exhibit A, as well as the master special assessment methodology that was initially prepared in June and also incorporates the supplemental assessment report final numbers. It makes the finding that the project is going to provide benefit to the property and sets forth the terms of the 2022 bonds. The bonds are going to be issued in two components, one is $6,130,000 portion for the 2022A bonds and the second is $4,740,000 component and the reason for the difference is those are going to have different payoff schedules and different interest rates.
The exhibits will take you through the details of the bonds. The average coupon rate we have locked in for the $6,130,000 is between 3.125% and 4%, the $4,740,000 has an average coupon rate of 3.65%. The other difference that I noted is the distinction of the payoff, it is anticipated that the 2022A-2s are going to be paid off at closing in connection with the sale of lots. While we have them as a ten-year bond it is possible they would be completed in advance of that time.

February 8, 2022	Rolling Hills CDD

Ms. Buchanan then reviewed in detail the sources and uses of funds.

On MOTION by Ms. Jordan seconded by Mr. Church with all in favor Resolution 2022-06 was approved.

SIXTH ORDER OF BUSINESS	Consideration of Developer Agreement with
Garden Street Communities Southeast
Ms. Buchanan stated the developer agreement is something that the CCUA requests everyone who is building utilities to enter into with them. It identifies the connection fee, which in our case we don’t have one because we expect that has already been paid by the prior developer, but there is an inspection fee and recording fee and this details the transition process of the district building the improvements and conveying those improvements to CCUA because ultimately that will be the entity that controls our water and sewer, we don’t keep those improvements ourselves. While the agreement in your package is addressed to Garden Street, since the district is doing the construction work, Garden Street has requested that we are the ones to sign the developer agreement in connection with that conveyance process.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor the developer agreement with Garden Street Communities Southeast was approved.

SEVENTH ORDER OF BUSINESS	Consideration of Work Authorization for
Stormwater Needs Analysis
Mr. Hadden stated we discussed in previous meetings that the state now requires every local government do an analysis of the stormwater system, looking 20-years down the road and it has to be updated every five years. The county will put all those reports into one for the overall county.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor the work authorization to prepare the stormwater needs analysis in an amount not to exceed $7,500 was approved.

EIGHTH ORDER OF BUSINESS	Series 2020 Project
Update Regarding Series 2020 Project

February 8, 2022	Rolling Hills CDD

Mr. Hadden stated we made very good progress, all the water is in, all the reclaimed is in, the sewer is in except the part that crosses the bridge and when they finish that the crew will start putting in the force main. They have started work on the sub-base of the roads and behind that will be the curbing and asphalt.

Ratification of Requisitions 65-67

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor requisitions 65-67 were ratified.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor requisitions 68-71 were approved.

NINTH ORDER OF BUSINESS	Series 2021 Project
Update Regarding Series 2021 Project
Mr. Blunck stated at the meeting before last you authorized us to negotiate with the pipeline construction and we are real close on the contract and I have talked to Katie on a couple issue and I hope that is going to be done by the end of the week then we will bring it to the board for signature. We have our preconstruction meeting tomorrow with the contractor, engineer, ETM, myself and county staff and hope to start next week with basic surveying and once we get a contractor they will mobilize and start moving dirt. All permits are in place with the Clay County Utility Authority. We have a very aggressive 11-month schedule and will complete the project as quickly as possible.
Ms. Buchanan stated we do expect to take advantage of the direct purchase process and we will bring that back to the next meeting.

TENTH ORDER OF BUSINESS	Other Business
There being none, the next item followed.

ELEVENTH ORDER OF BUSINESS	Staff Reports
Attorney
There being none, the next item followed.

February 8, 2022	Rolling Hills CDD

Engineer
Mr. Hadden stated Major Giles is the one who got your roads fixed.
Ms. Giles stated everyone had input to the letter that we directed to Commissioner Burke and she took care of it within 48 hours.

Manager
There being none, the next item followed.

Operations/Amenity Manger
Report
Mr. Stephens gave an overview of the operations report.

Monthly Quality Inspection Report
Mr. Stephens distributed a copy of the January landscape inspection report.
Mr. Oca reported that he needed to get the marcite on the gutters repaired prior to opening the pool.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor staff was authorized to have the pool repairs done in an amount not to exceed $6,500.

TWELFTH ORDER OF BUSINESS	Supervisors Requests
Ms. Jordan stated we had talked about possibly getting water fountains by the tennis courts. I don’t know if we fixed them or if we were going to get prices.
Mr. Stephens stated I looked at them and they are beyond repair.
Mr. Oca stated we can get by with the two that are out there that are functioning this year. Ms. Jordan stated it may be in our best interest to try to prolong that.
Mr. Miller asked how do we get Clay Electric to fix the lights that keep popping on and
off?
I talked to one of the motor officers and there is a concern with speeding on Bradley
Creek and he suggested we contact the county sheriff’s department to do a study. I don’t know if

February 8, 2022	Rolling Hills CDD

it is going to cost anything but he recommended establishing more stop signs on Bradley Creek to slow the traffic down.
Ms. Jordan stated we previously discussed doing a traffic study for our speed limits.
Mr. Hadden stated stop signs are a double edge sword. The people who live in the back are going to have to stop six times. A few years ago I was the engineer for the Town of Orange Park and we put up six stop signs between Wells and Kingsley and it took longer to go down Plainfield with the stop signs than to stay on 17. The residents loved it. Stop signs would slow people down and make them stop and the county would support that.
Ms. Jordan asked could that be done without a study?
Mr. Hadden stated if you wrote through Marilee to Commissioner Burke and requested them from a safety and speed standpoint and you could offer to have them put up at your expense so the county didn’t have to pay for them. You could start with an officer giving out speeding tickets.
Ms. Giles stated if you can give me the intersections you want to put them at I can get the conversation started with public works at the county.

TIRTEENTH ORDER OF BUSINESS	Audience Comments
Ms. Cormier stated on the personal aspect of the situation with Wayne Simpson and the restraining order, the judge has temporarily extended the temporary restraining order and they are doing an evaluation. I have reached out to Shannon and the state’s attorneys office and if there is anything you can do to help remind them of the complaints that have happened in the neighborhood concerning him it would be greatly appreciated. He has definitely violated the conditional release and they are well aware of that based on the reports that were turned in and they know he is a danger to the community based on the complaints and evidence and statements, they are just making sure everything happens properly.

FOURTEENTH ORDER OF BUSINESS	Financial Reports
Balance Sheet & Income Statement
A copy of the balance sheet and income statement were included in the agenda package.

Assessment Receipt Schedule

February 8, 2022	Rolling Hills CDD

A copy of the assessment receipt schedule was included in the agenda package.

Check Register

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor the check registers were approved.

FIFTEENTH ORDER OF BUSINESS	Next Meeting Scheduled for April 12, 2022 @
6:00 p.m. at Rolling Hills Amenity Center
Ms. Giles stated the next meeting is April 12, 2022 at 6:00 p.m. at this location.

On MOTION by Ms. Jordan seconded by Mr. Miller with all in favor the meeting adjourned at 7:01 p.m.

Secretary/Assistant Secretary	Chairman/Vice Chairman

FOURTH ORDER OF BUSINESS

RESOLUTION 2022-07

A RESOLUTION OF THE BOARD OF SUPERVISORS OF THE ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT IMPLEMENTING SECTION 190.006(3), FLORIDA STATUTES, AND REQUESTING THAT THE CLAY COUNTY SUPERVISOR OF ELECTIONS CONDUCT THE DISTRICT’S GENERAL ELECTIONS; PROVIDING FOR COMPENSATION; SETTING FORTH THE TERMS OF OFFICE; AUTHORIZING NOTICE OF THE QUALIFYING PERIOD; AND PROVIDING FOR SEVERABILITY AND AN EFFECTIVE DATE.

WHEREAS, the Rolling Hills Community Development District (“District”) is a local unit of special-purpose government created and existing pursuant to Chapter 190, Florida Statutes, being situated entirely within unincorporated Clay County, Florida; and

WHEREAS, the Board of Supervisors of the District (“Board”) seeks to implement Section 190.006(3), Florida Statutes, and to instruct the Clay County Supervisor of Elections (“Supervisor”) to conduct the District’s elections by the qualified electors of the District at the general election (“General Election”).

NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF SUPERVISORS OF THE ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT:

GENERAL ELECTION SEATS. Seat 2, currently held by Rose Bock, Seat 34 currently held by David Church and Seat 5, currently held by Nate Riggs are scheduled for the General Election beginning in November 2022. The District Manager is hereby authorized to notify the Supervisor of Elections as to what seats are subject to General Election for the current election year, and for each subsequent election year.

QUALIFICATION PROCESS. For each General Election, all candidates shall qualify for individual seats in accordance with Section 99.061, Florida Statutes, and must also be a qualified elector of the District. A qualified elector is any person at least 18 years of age who is a citizen of the United States, a legal resident of the State of Florida and of the District, and who is registered to vote with the Clay County Supervisor of Elections. Campaigns shall be conducted in accordance with Chapter 106, Florida Statutes.

COMPENSATION. Members of the Board receive $200 per meeting for their attendance and no Board member shall receive more than $4,800 per year.

TERM OF OFFICE. The term of office for the individuals to be elected to the Board in the General Election is four years. The newly elected Board members shall assume office on the second Tuesday following the election.

REQUEST TO SUPERVISOR OF ELECTIONS. The District hereby requests the Supervisor to conduct the District’s General Election in November 2022, and for each subsequent General Election unless otherwise directed by the District’s Manager. The District understands that it will be responsible to pay for its proportionate share of the General Election cost and agrees to pay same within a reasonable time after receipt of an invoice from the Supervisor.

PUBLICATION. The District Manager is directed to publish a notice of the qualifying period for each General Election, in a form substantially similar to Exhibit A attached hereto.

SEVERABILITY. The invalidity or unenforceability of any one or more provisions of this Resolution shall not affect the validity or enforceability of the remaining portions of this Resolution, or any part thereof.
EFFECTIVE DATE. This Resolution shall become effective upon its passage.
PASSED AND ADOPTED this 12th day of April, 2022.

ROLLING HILLS
COMMUNITY DEVELOPMENT DISTRICT

CHAIRPERSON/VICE CHAIRPERSON
ATTEST:

SECRETARY/ASSISTANT SECRETARY

EXHIBIT A

NOTICE OF QUALIFYING PERIOD FOR CANDIDATES FOR THE BOARD OF SUPERVISORS OF THE
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

Notice is hereby given that the qualifying period for candidates for the office of Supervisor of the Rolling Hills Community Development District (“District”) will commence at noon on June 13, 2022, and close at noon on June 17, 2022. Candidates must qualify for the office of Supervisor with the Clay County Supervisor of Elections located at (	), (	), Florida 	; Ph: (  ) (  ). All candidates shall qualify for individual seats in accordance with Section 99.061, Florida Statutes, and must also be a “qualified elector” of the District, as defined in Section 190.003, Florida Statutes. A “qualified elector” is any person at least 18 years of age who is a citizen of the United States, a legal resident of the State of Florida and of the District, and who is registered to vote with the Clay County Supervisor of Elections. Campaigns shall be conducted in accordance with Chapter 106, Florida Statutes.

The Rolling Hills Community Development District has two (3) seats up for election, specifically seats 2, 4 and 5. Each seat carries a four-year term of office. Elections are nonpartisan and will be held at the same time as the general election on November 8, 2022, and in the manner prescribed by law for general elections.
For additional information, please contact the Clay County Supervisor of Elections.

Publish on or before May 30, 2022.

FIFTH ORDER OF BUSINESS

RESOLUTION 2022-08

A RESOLUTION OF THE BOARD OF SUPERVISORS OF THE ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT DESIGNATING A REGISTERED AGENT AND REGISTERED OFFICE OF THE ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT.

WHEREAS, Rolling Hills Community Development District (the “District”) is a local unit of special-purpose government created and existing pursuant to Chapter 190, Florida Statutes, being situated entirely within Clay County, Florida; and

WHEREAS, the District is statutorily required to designate a registered agent and a registered office location for the purposes of accepting any process, notice, or demand required or permitted by law to be served upon the District in accordance with Section 189.014(1), Florida Statutes.

NOW, THEREFORE, BE IT RESOLVED BY THE BOARD OF SUPERVISORS OF ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT:

SECTION 1. Katie Buchanan of Kutak Rock LLP is hereby designated as the Registered Agent for the Rolling Hills Community Development District.

SECTION 2. The District’s Registered Office shall be located at the office of Kutak Rock LLP, 107 West College Avenue, Tallahassee, Florida 32301.

SECTION 3. In accordance with Section 189.014, Florida Statutes, the District’s Secretary is hereby directed to file certified copies of this Resolution with Clay County and the Florida Department of Economic Opportunity.

SECTION 4. This Resolution shall become effective immediately upon adoption and any provisions of any previous resolutions in conflict with the provisions hereof are hereby superseded.
PASSED AND ADOPTED this 12th day of April 2022.

ATTEST:	ROLLING	HILLS	COMMUNITY DEVELOPMENT DISTRICT

Secretary/Assistant Secretary	Chairperson, Board of Supervisors

SIXTH ORDER OF BUSINESS

April 1, 2022

Rolling Hills amenity Pool Lake Asbury Fl. 32043

Re:	Rolling Hills

4571 St. Augustine Road Jacksonville, FL 32207
Phone: 904.733.7665
Fax: 904.733.7946
CPC 056638
CPC 044955

Parry Pools, Inc. is pleased to provide you with our budget number for the above- mentioned project. We propose to furnish all labor and materials necessary to complete the referenced project. Our budget number includes: Plaster and Tile to code (all step and waterline tile to be brought to code)

Rolling Hills Pool Plaster	$260,000.00

Plaster with Quartz Commercial finish
Drain and secure pool from ground water
Hydro blast existing surface to a solid sub-straight
Coat pool with perma-coat bond coat
Install new gutter grates
New floor returns
Remove and install 6 new racing lanes and 12 new targets
Replace 2-18”x18” VGB main drain grates
Replace 2-12”x12” VGB Main Drain grates
Replace step cap tile and bench edge tile
Replace waterline tile, non-skid per DOH
Fill and balance (water supplied by owner)
2 week start up period per manufacturer (water balance only)

Rolling Hills Splash Pad Plaster	TOTAL:
$18,000.00

Plaster with quartz Commercial finish
Drain and secure
Hydro blast existing surface to a solid sub-straight
Coat with perma-coat
Replace 1-18”x18” VGB frame and grate

Fill and balance water

TOTAL:
$278,000.00

Thank you for the opportunity to provide you with a proposal. Please call me if you have any additional questions or issues. This bid is valid for 60 days

Sincerely,

Billy

William E Parry, III President

SEVENTH ORDER OF BUSINESS

B.

REQUISITION FOR SERIES 2020 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number:	072
Name of Payee:	Vallencourt Construction Co. PayApp#16-Inv.7852

Amount Payable:	$224,014.68

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs oflssuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that:
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and Const1·uction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that hasnot previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, 01· attachment upon, or claim affecting the right' to receive payment of, any of the moneys payable to the Payee $et forth above, which has not been released or will not be 1·eleased simultaneously with the payment he1·eof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
O1·iginals or copies of the invoice(s) from the vendor of the p1·operty acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:	t{\	G
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 Project with 1·espect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

, ,,,.,\\)\-\J D'C!:'1-:.'J'//'I/ 
mg E ngft\Mil ..•••,.. I)	'l
-..,,V ,,,,'v''<-\\SI: ••, ''\<.-'	..

o

,-l:',v	,,_,,	•·\{,•

--, ..... ,,'

l')\'i"''
'1>

, .. c-l.

:,  :	-l<	: L'.I.
··: -· ',	of:	: y.,
':-• J(  I	-<"-i'c-	I<

-:,':l.:. ,,)'('\.'.,.

<:)'?',' .f!l

_,.; '  \	s\r'	I
FLO \,,',-;;:;•:
l'i:- - - - . . . • ••  V  ,'

iu,.

/11i l:'Gst0\1f \\\'>
i:! : I\\,\\,

}Za .J: 1--z...

'ALLENCOURT
Construction Co. Inc.

INVOICE

Date: 03/28/22	Pel'lodTo:	3/25/2022

To: Rolling Hills Community Development District 475 West Town Place Suite 114
St.Augustine, FL32092
Attn.: Accounts Payable/ Bill Tew

Invoice#:	7852
VCC Project#:	2020-52
Appllcatlon #:	16

Project Description: Rolllllg HIiis139 Lots Phase A
Bradley CreelcPkwy

LBSS RETIIINAGB......................................................._	$

ORIGINAL CONTRACT AMOUNT.-... ................................	...._ ................. ..	.	$4,198,326.03	
CHI\NGBOROBRSTODAT"---------------------·····-··	$	403,070.35	
RllVISF.D CONTRAc:I'IIMOUNT...- ,....._,...-------·----------·	$	4,601,404.38	
PERCCNTAGECOMPLET"---------	59.76%		
WORKCOMPL!ITETODI\Tc..	$
STOREDMIITERl/1..,	..		$	2,749,093.67	
TOTALCOMPl.llTBD&STORED-------	._._ $	2,749,093.67	

TOTAL61\RNUD LtiSS RETI\INI\GB.............................................................................................................	$
Ll!SSPREVIOUSDILLINCS.•..- .........,	--·	$

274,909.37
2,474,904.30
2,250,889.63

CURRENT DUil.••.••.•.•••.......•, .,.

...,., .......•.•••., .•• .• .• $

224,014.68

Account Summary,	Sales
ThisPeriod	Salos
To Date	

Gross:	
248,905.19	
2,749,893.67	
Rctalnagc:	24,090.52	274,989.37	
Net:	224,014.60	2,474,904.30	

449 Center Street, Green Cove Springs, FL 32043 I (904) 291-9330 I VALLENCOURT.COM

APPLICATION AND CERTIFICATE FOR PAYMENT	AlA DOCUMENT G702	(Instructions on reverse side)	PAGE

TO: Rolling Hills Community Development D 475 WestTown Place Suite 114
St. Augustine, FL 32092

PROJECT: Rolling Hills139 Lots Phase A
Bradley Creek Pkwy

APPLICATION NO: 78S2·16 PERIOD TO: 03/25/22

Distribution to:
[X] OWNER
[X] ENGINEER

FROM: Vallencoutt Construction Company, Inc.
P.O. Box1889

CHANGE ORDER SUMMARY	
Change Orders approved in previous months by Owner
TOTAL	ADDmONS	DEDUCTIONS	
Approved this Month			
Number	Date Approved			
1	4/26/2021	$	445,496.73		
2	8/16/2021	$	10,710.00		
3	8/16/2021	$	87,188.58		
4	10/29/2021	$	366,625.00		
5	10/29/2021	$	40,023.69		
6	11/21/2021		$	546,965.65	
				
TOTALS	$	950,044.00	$	546,965.65	
Net change by Cbange Orders	$	403,07835	

Green Cove Springs, FL 32043 CONTRACTOR'S APPLICATION FOR PAYMENT

ENGINEER'S PROJECT NO: N/A
CONTRACTOR'S PROJECT NO: 2020-52

Application is made for Payment, as shown below, in connection with the Contract. Continuation Sheet,AJA Document G703, is attached

1. ORIGINAL CONTRACT SU1J.Y1-	
Z. Net change by Change Orde,.--,,..	 _
CONTRACT SUM TO DATE (Line1 +- 2)-----------
TOTAL COMPLETED & STORED TO DA11:,	­
(Column G on G703)
S. RETAINAGE:

_ $  4,198,326.03
$	403,078.35
$	4,601,404.38
$ 	2,749,893.67 

a O % ofCompleted Work $
(Column D +Eon G703)
b._%  ofStoredMaterials$, 	_
(Column Fon G703) Total Retainage (Line Sa+ Sb or

274,989.37

The undersigned Contractor certifies that to the bestofthe Contractor's knowledge, information and belief the Work covered by this Application for Payment has been completed in accordance with the Contract Documents, thatallamounts have been paidbytheContractorforWorkforwhi	C •	wn
issued and payments received form O:w:Rel:,;and that altl<Sl4t1/1fa entsho n

Total in Column 1 ofG703)---------
6T.OTAL EARNED LESS RETAINAGr.:·	­
(Line 4 Less LineS Total)
LESS PREVIOUS CERTIFICATES FOR
PAYMENT (Line 6 from prior Certificate),--------
CURRENT PAYMENT DU-r---------------
BALANCE TO FINISH, PLUS RETAINAG,c	­

$ 	274,989.37	
$ 	2,474,90430	

$ 	2,250,889.63	
$ 	224,014.67	
$ 	2,126,500.08	

· ·
herein IS nowdue.

r°§ \ Notary Public· tale of Fiorica
, • ,,-t •,;;	commission • HH165052
'··'f:i-'ff(.7!t 1'-, CQmm. Exp;es Dec s, 2025

			(Line 3 less Line 6)		 Stateof:	FLORIDA	Countyof: CLAY

·-•• 5crc:r-r ih llationa! Notary r.

Date:	March 2s 2022

ENGINEER'S CERTIFICATE FOR PAYMENT
In accordance with the Contract Documents, basedon on-site observations and the

Subscribed and.._sw,a to before methls. , / 28th Notary Public-:11tt212,./_V'1lald..u:L-
My Commission Expires:	12/8/202S

day of	March,2022

$		Oftl,,_h1

data comprising the above application, the Architect certifies to the Owner thatto the bestof the Architect's knowledge, information and belief the Work hasprogressed as indicated, the qualit;y of the Work is in accordance with the Contract Documents, and the Contractor is entitled to payment of the AMOUNT CERTIFIED

'---lt'-11-irn-l-H -n::::t=ce=rtifi:::',_ed_<M= from  =-•:11711-

t	n negotiable. The AMOUNT CERTIFIED is payable on to the Contractor namedherein. Issuance, payment and acceptance ofpayment are without prejudice to any rights of the Owner or Contractor underthis Contract.

AlA DOCUMENT G702• APPLICATION AND CERTIFICATE FOR PAYMENT• MAY 1983EDITION• AIA"@ 1983 THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 NEW YOUR AVENUE, N.W.,WASHINGTON D.C. 20006

G702-1986

								, '	' ' ' ';	; ; , '	' '	' '			
>	
a								•. •t '''• •t, i a !!	f i [	, I
r	. L	!.	•'	§
' ' ': g '	•a	'
a L	. '	I	r
'i	i ' ]	s	I
I	f	a '	'
'		
I		
								j I-I - -"' t�,., j
I ill 0	! ";
0				

 					

m	

					

												
				...								
		....	.,,		,...	.....	...					

 					

Mlk v	ncneourt II,. Vie Prc.o.::.1d<::n't
J. o nlcl V..:iillcneoun. V,ee Prc:=1den't St.•n Bates P.E... V,ec P, 1dent

rvlJrc.,•- M.-::ln-•rn.-..y,. i=>res,dcn1:
Mike, V.;:allc..-,.ncourt Sr.,. Cha,rm..:in

..,...........,.......,_---

  onstruct■on  Co.Inc.

Ola aean1111AndUrtOwOrk

"''·'

"""'°""'"°	...,_	Ualt:elMaan	.........	...........

,....,,.......	,._

1000

900

900

-Oearino-EMffflMt	1

ACRE

ACRE

$13939,12

41

$13.o:39.12	1

-•=.53

14S0·• ◄O

50411

1	$0.00

$0.00

,001	$0.CO

$U.fl9.l.2

,32.:J.a7.S3

$145.15<.40

T.c:attoDac.

100\

100\'

100\'

-

Sile-	48.6

"'·'

60481.00

1001
1108

..

1109

o.wa....rorl'l>nd	60481.00
SlteCllt	26070.00

fineGrade LOTS-No Pads	156=

Pl>a!&	FIi	""751.00

Cf	$0.47

Cf

"""°

Cf	_,_
Cf	-12

$28426.07
SS8 .so

S39 m

$97161.12

H.U1 2'270

.....

ans1

,001
2'270
,,,s1

$0.00
$0.00
$0.00

$28.42,.07
$S1,H4.IO
$'7.Ul.12

l.OOl- lOOt lOot

•

"

1115

1110

Eatthwort._.,...T,... 	1

LS	$33.'146.S3

m-•

, ,,1.

1	$0.00

1s,ooo

$0.00

$ll.2".S3

$39,000.00

1001:

100

1118
1122

Flnal°"'5SO<Jt
Grade or 0-rze aa:hesOnsite

18073.00
-.oo

Si	S0.53

Si

S0.25

lF	... 02

$9=69
s11-.80

100

18'0

$0.00
$0.00

$0.00
$17,.047.80

1,00..

1JOO

-Sl3bll!zllfon	17	Si	s,.s,+ Tot21Price for .1boYcOJ.a Clcar1DCIAnd Ea:rtbwork n:ems:
I

$1J,44J8.20
$609.2.24.26

132S0

1l'2SO

so.co

••

$0.00

S,9,.905.00

=

$S6S

,,.

01.b Emsl0a AndsedlmentCOntrDIAad PollUUOn Abatement
-sa:-	114CNI.QO
NPOES	•s
601	SlltFenc:e mr1.1-11M"\	14600.00
608	JnletProlio:lx,n	123

lF
MO
Lf
6'0<

$1.36
S817.s+
$0.87
$11il.S1

S19 er.c:00 S6  .32
$12 702.00
S3  .73

1-c.,oo 14,00

•

2l

1'COO

•

1'COO
:z:,

$0.00
so.oo
$0.00
so.co

$U,IY.00
$,.sco.32
$12,702.00
SJ,.7'-0.73

100\'.
100', l.001 1001'

T(IQIPrl0efOr.-e01b&oslonAndSedlmentCoatrolAll<IPollUUonAba-U10mS:

=, ,9.os

<0.00

.OS

10n.

OlC5'armw><el'PolllRlon-	I

·-·-~

•	•	$0.00

$12.ss,.oa

1

1

o.oo

n.30a.oc

100t

lOOt

INPOESPe'ffllt ·-1anct	'8	MO	$ """.26
INPDESPermitFee	11	"'°'

$12.5§4,08
$1	06

Total Pr1ccfar above01c Stomrwater Pollution Pievendoa Dzms:	S13	4
I	I

$0.00

100\

1104

Stno1'

128.00	Cf	70

$135.345.60

50121

50121

so.oo

$135.345.,o

1001

ox.a Demolition And SitePrepaQt:icm	' so

110S

·•-•In""""	ISO128.00	Cf	$1..12
Total Pr1CeforODelmdolftloo And S1tll Preparation ltems:
I

$56.l.◄3.36

SOUi

50121

$0.00
$0.00

SSC,143.l'
$191A88.!l6

100\-
10H-

01g SOO""'
12!)1
12!)3

SlteSOd	' .P60.00	Si	IS2.4S
PaldSOd	l1p=oo	Si	1<2.◄S

$10<37.00
''462.SO

42"
l.USO

-c.2,0
u:so

$0.00
$0.(10

$10.437.00
s,2 ..c,2.so

100\"
100,

Total Pricefor aboYeOJ.gS0cSBid lterm:	.so
I	I

.so

100\

01ft5-ln9And/orMoldllng
1206	htd	S...SandMul:h	15660.00	ISi
1207	ISe!dandMUl:hl.OCS	156	00	ISi

,l<.,n,,.3..3.

•=.so

•

$S1480.00	•

$0,00

0

•

:;o.oo

so.oo
.oo

••••

I	TCOJPr1cefor above.OJ.JI5eedlDO Altd/orMuldatno

nc.,17.so
$0.00

$3C,.917,S0
$0.00

I

•=647.80

$Cl.OD

$0.00	••

02-	-

1402
1401

1302

Sidewall(

-

in

8" Umercdc
-I" BaseStabll2<dkassllioadToLS

27511

2'7S0

e,,--..e:l'orSideWall(

•

15130.00
2•=.00

•

1'".00

0

Si Si

"-4S
60

$203◄98.50
<16 -oo

••

SY	-•1

,.,=18	"

$0.00

$0.00	••

15ll3 1504

1· ... ._...t PaYerrent 1·

15130.00
15130.00

Si
SY

$6.◄9
$7.49

93,70
<113

0
0

••

$0.00
$0,00

$0.00
$0.00

1700

PrimoUmenxlt
eo.t

Sin-&

15130.00
15130.00

Si Si

l	LS

••••

1517
1518

on.ss
...ss

$0.00
$0.00

H:4QO.U

..-

.. =

$S«xl.11	0

$0.00 u,.110.00

$0,00	o•

-

•

•
"

•

$0,00
$0.00

••

'

s21.110 ..oo	3U

18)4

l8"MlamlCurt>&Guller

9720.00

lF	$937

CQl 076.40

0	3000	3000	••

2003

S'Sidew>I<

12 000.00

Sf	t4.36

...,, , oo

-

•

•

0

$0.00

•

$0,00

$0.00

•

••

so.co

2005
2006

A.O.A.Handlc:ao A.0.A.MalS

24
2<1(]

EAOi
Sf

Sl
$2ll.89

S3 921.24
$6" 60

$0.00
$65097.SO

$0.00
.so

u•, •

TOQIPrkZ foraoove 02hvlnQ AAdSldewalkltems:
I	I

03Dralaage-.,
3003	Qewal2rstcnn Dr31n
3026	CUrt>Inlcto-6'"'--

2	oo
7

LF	SlS.74	$36-wn 00	2300
EAot	-t'tl'll2.50	$21Nr7.SO	4

2300	$0.00	$1',202.00
,c	$0.00	$12,050.00

100\-
$7\

3027

cu.t,1n1et6-8'	7

EAOi	s+- »	S30 'V'l.89	7

.,	so.oo	no.12,.e,

100,

3028
3029

OJrblnlet&-10"-	5
Curblnlet:10-12"	3

EAOi	$61w:t.J7	$30 16.85	S
EAO(	$6964.20	$20  60	l

S	$0.00	$30,'1,.es
l	$0.00	$'2C,U2.,o

lOOt
1001

JOSS

o,ntn:11Stn.Jdurel2-14•-	1

EAOi	$9 90.s,	S9	1

1	so.oo	s,.,,o.$7

100,

3061

Storm Manhole 0-6" ,.. 	2

EAOi	S4  O.trJ	-	..4	2

2	so.oo	$&,221.74

1001

3062	StormManhote:6-8' .._	2	EACH	S4  5..27
3063	Storm Manhde:&-10"	9	EAOl	$5  0.49
3064	Storm Manhole 10--12'	1	EAO!	I  "-.66
3069	1-n-D Inll!t.6-8'	1	EA01	.u.Wl<ll.38
3074	YatdOralns	g	EA01	Sl.249.21

S9	,CA	2	2	so.co	$, •,•0.54	100\-
<tSl  .41	a	a:	so.co	s-t,,10.,2	u,
<re  .66	l.	l.	$0.00	$S,17J."	10011
#,11  .38	l.	l	so.co	$-l,.JO<l.JS	1001
$U  3.43	'	9	$0.00	Sll,243.0	100\
7

E,,J;08!:8::::t=.,. ,, ;;,.. 1n	From L,,,..,.:: ==== :O: :::::::::::::t [=====lif.56;.;[:: t::::::::5:	:: s ==::::j' 0!:t======== t::::: •o :J:::::::j! : :: ::t::::::::• • ·t'! : :: ::t::::::::j33 

...

ls-Mitered End Section	2	 EACH		$6.761.20	 l	l.	$0,00	$3,313.,o	SO:\' 3089	42• Ml:l!ted End Section	2	EAOi	<13493.12	O	 O	$0.00		$0.00		01

3191
3192
3193

1rRCP0-61.....
18"RCP6-8' lB"'RCPS.10-, 

'469	LF

3184	:ts- RCP 0-6'--	385	LF	55.74	$21491.90	US	315	$0.00	S21,f5!.'1>
3185	1S'"RCP6--8° ._	78'3	LF	7	«511:17.23	lat	719	$0.00	$<4S,&17.23

189	lF
122	LF

"'"
r...1:..70
n&

,t-')O ,c1..S3	o:z	.co2	so.oo	$2S,on,..c
$'" .,.,.v..	lH	lU	$0,00	SU,22&.30
<t0:469.64	122	ll2	so.oo	$'••"·"

lOOt 100:!J

100,
100,

3198
3199
3200

2.- RO>o-6"
RCP6-8'-
249P.0&-10"--

282	LF	!'.14.13	an.s.66	2&2	2&2	$0.00	Sl0,904."
521	LF	$16.47	$39 -  ...,	521	521.	:;o.oo	:;3,,940.11
150	lF	S93.97	$14 09S.50	150	150	$0.00	Sl4,0'5.SO

100\
100,
100•

3201
3206
3207

2.. RCP10-12'
30"RCP6-8'n-
JO"RCPIHO'

,409	LF
138	LF
449	LF

-aa.34	$40 .  42	o,	,o,	so.oo	S40,'4C.4.Z
.99	-t:13 -0 62	o	o	so.oo	$0.oo
113.90	$51 l◄L10	40	40	so.oo	$51,14.l.l.O

100•
o•
100\

3213
3214
:ms
3216
3219
3220
3221
3264
3279
3280

36"RO> 6-8' - JSWRCP&-10' 36"RCP10-12'
36.RCP12-14'
4l9RCPG-6'r-....-
42" RO> 6-8'
◄r RCP &-10' Deen
Underdraln Oeanout Pl.l'IChOUt5t0rm Drain lV SOorm CAin

29
1096.00
141
62
66
393
219
18
s  .00
S909.00

lF	121.90	-t1.709.l0	2,	2'	$0.00	SJ.10,.10
LF	139.80	$153	10,,	a,,	S0.00	Sl.Sl,220 ..10
LF	147J3	:$:20 R7V.93	141	141	 so.oo	$20,92'.'3 LF	1S7.6S		-774.30		,:		,2	so.oo		s,. 714.30
u:	$140.36	,  ,6	"	"	so.oo	s, ..2D.7'
Lf	IU44.94	961.42	1.1S	l.lS	$0.00	=,.au.,o
LF	 $156.&4			"Mn.96	n,	u,		so.oo	$34.341." EA0-1	 $1793S			 _,,.._		 o		 o	 $0.00		so.co LF	$1.12		0.163.48		 o		o	 so.oo		 so.oo LF		049.43		o		o	 s0.oo		 so.oo
Total Pr1ceforabove 03 DtalnaoeSysliemllems:	73	sa.ao
I

100,
l.OOt
100
100 lO,.O,t.. 1001,

...

Ot
o•
Ot

I
2  .00	11.F	1$24.83

$0.00	:;o.oo	••

I
OS Wllttr DISt:ribUtkm

Tota1Pr1cetor-.e  04 RoadwayUOdenlrabl.a..ms:	SD.GO	$0.00	...
...

7014	8"' CIUS PYCMain
7015	6" OIU8PVCW_. _,

I.F
I.F

$19.25
13.10

10U
700

10&$
100

$0.00
$0.00

$20,IH.25
$5,170.00

100\:

7016
7017

◄•CR.18PVCW:att:rMait'I
r  w.,t,t Main Rr Ult Slatlon

I.F
I.F

<'>.16
"'""	­

0	$0.00
0	$0.00

$0.00	o•
$0.00	o•

7022
7023
7053
7063
70&I
1r:m
7098
7101
710S
7106

20
30
--  ... Slv.and vai..
4"lc2"TIJ•S>ddlean:1V>!Ye
S-X&'Cross S-G>tev.i..
6"Gatevai..	12
vai..so.lnstallallcn	1◄
R•-"""'.....,.rant	6
Ate -	6

EAOi EAOi
EAO!
EAO! EAOl EAOi EAO! EAOi EAOi EAOl

170.01
124.93

$1 Mn IS1.381.08 S919.49
$165.21
.,=•=
- .44

<00.20	20

•

'47.90

$1 ;'74.00
1.68
r...i16

20	$0.00
$0.00

$0.00
$0.00
$0.00
so.oo
$0.00
$0.00

$0.00
so.oo

$1,8).t.98
$0.00
so.oo
$S,734.&a

,,.

o•

••

••

7132

8x8'Tcc

EAO!

SSS9.62

so.oo	100

"7l"S°4
7161
7187
7189
7241
72<3

6x6"Tee

---

6"90 Bend
-C-458end
a,eR,duc,r
..............

--	UftSbllan

2

•

139
1

EAO! EAO! EAOl EAOi EAO< EAO< EAOl

$232.28

92	2
-	08	0
$101	0	20

..

•1  .20	0

so.oo
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00

$0.00
S5'1 .60
$0.00

$0.00
$14.,SH.00
$0.00

llt
o•

••

100,
,...
ot

Punch OutfcrWlf'Zf'Main

6450.00

I.F

$1.91	$12 19.SO	$0.00	$0.00	Ot

 	

n48 n4'l
nso

&BT"sferWaterMain	'6450.00	Lf	l<ll.86
Locate:W1re:Test:Fcr WaterMain	16,450.00	Lf	l<n.SO
PressureTestf« Wa"'Main	76◄50.00	Lf	1$1.91

cs"'-.oo	0
:13--•-	0
$  19.50	0

0	$0.00
0	$0.00
0	so.oo

$0.00
$0.00

n

$0.00

...•..•

06 -

TotalPricefOf' bcwe OS Wale'DIStrtb&rtlOa ltelaS:	.OS

...

,..

S0.00

$0.00

= ,==
s1,.:.,u.oo

...

1001

901<
9015
9016
9023
9024
9025
9084
9091
9097
9098
9099
910Q.1
9103
9136
9155
9157
9183
9185
9214
9215
9216
9237
9239
9240
9241
9242

8"  ORlllPIIC Rase-
6'" ORlllPIICReuseMaln
◄"' CIUS PVCRet$I!Maki 8"JointRestr.,/n!s 6'"Jolnt-.tnts
◄- Joint Restraints 8"X4"Cro<s 8"Sloeve

.- -

8" """"
6'"Galle-
=-- -·
VllveBax:Installmon
6x6•Tee:

---

8"4S Bend 4"◄5 Bend 8x5"'Rod= 6'<4"-
8"Conllic:
6'"conmct
◄-COnllla

Punch out to, RellSe Main
A•--fl:ll'Ret.J!eMaln t.oc:ateWireTest:ForReuseMlfn P'lessure:Test rorReuse: Main

7<10
360
3 760.00
8
6
24
2
1
1
1
6
6
8
1
◄
2
1
2
2
1
3
139
4  .00
4•••.00
4""""".00
4

Lf	$19.25
Lf	13.10
Lf	$9.16
EACH	$153.◄9
cAOt	124.93
Lf	11S.71
cAOt	11"7.71
EACH	$540.15

=

EM:><	$1402.43
cAOt	$968.38
cAOt
cAOt	$1Cl'II\M
cAOt	S259.n
cAOt	$385.12

,.

cAOt	76
cAOt
EACH	=96
EM:><	$214.1$
EA01	3	18
EACH	"'19.43
EACH	85<.+I
EACH	.JS
Lf

Lf	.,-""91

Lf	"''
Lf

$14.245.00
«716.00
r'l.&'441.60
M,=.92
<749.58
.O<
<2.075.42
$540.15
$1.402.43
$968.38
$4- .40
ss .12
S2078.16
12
S1439.0<
.56
··  O<

ii

$<28.36

U.179.60
<2.<30.00
-	82.150

740
"o

.

•
'
2
0
1

•

1

0
0

•

1

2
1
2
2

•

1

>0

••

0

0

3'0

•

100

•

'
2
0
1
1
'0
0

•

'
2
1
2
2
'0
20
0

•

0

0

$0.00
,o.oo
$0.H
so.oo
$0.00
$0.00
$0.00
$0.00
$0.00
to.oo
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
$0.00
so.oo so.oo
$0.00
$0,00
$0.0D

$4,'11'.00
$7,321.00
$l,227.,2
$70.58
$4,2.14
$2.,075.42.
$0.00
$1,402."3
s,u.,a
.S29.40
$0.00
$0.00
$385.12
$1,439.04.
s.,	s,
$302.n 21.:1,
U.78'.U
$2.71-1.43
$0.00
S12.7C7.0o
so.oo
$0.00
$0.00
$0.00

l00t
,2U

...

!001
171<

••

lOot'
,
lOOt, 100,
o• o• 100,
100,
100,
1001
1001
1001

••

1001:

..

10

o,

••

4003
◄014

01S"ewer !GravilYAnd ForceMola)

TotalPrice for abOVe 06 Redllm01Str1butlon Items;	$209

s&2.9n.ao

Jo•

IJt

....

◄015
◄016
◄017
◄018
◄019
◄036 4058
◄068

4111

<069

-n-AMinhole6-8"	6

-r-,5ewer
.. Manhole0-6"""'

3-"'5.00
9

TVl"lf'AManholeS--10",._	3
T.- A Manhole 10-12' .,_	2
T-AManhdeU·t4"-	2
T  A Manhole 1+16' --..	1
-s-10'-	1
LinedManhole 12·14'"'--	1
Manhole:T""'-Out	25

8"'SOR26 Maift0-6'...

,_

ii39.oo

-

PoUrlnver!s	25

Lf
EACH

,$,1.6,.4,6,.,,

EACH	'62.65
EACH	M.U:5.72
EACH	u.&.n.57
EA01	tli:590.76
EACH	$6115.42
EACH	412.59
EACH	'""1.46
EACH	><76

Lf

EACH	4 ,22

19-90

•

•

124.10
''"•9233

-· 597.16	J
,55.34	2
$Ll 1&1 t""'I	2

'

'

-t t?S.◄2
<S412.59
•1-	46	0

0

•

"'"' .00

-

-

$40" .98	"'

.,

S7

-

$0.00
$0.00

$0.00

•

uoo
•

J	$0,00
2	$0.00
2	$0,00
1	$0.00
1	$0.00

0

,

$0.00
0	$0,00

"'

o.oo

$0.00

3200

su.oso.'° su.s,.,,u

ss:.,,2.00
$10,HS..U

SJ,JS!5.34
$U,111,S2 U:,17S.4.2
$5,4.12,59
$0.00
:;:o.oo
s.1.,2,.,e

$7.057•,C

.,
1001
100,

..

••,

10011 lOOI 100•
••
,,..

4112
410

8" SDR26Sewe-Maln fr8"

-

B"S0R.26$ewer'Maift8,,10'---

891
=

Lf	'24.79
IJ'	JJ

4	1,S.5,'

155<
Ul

$0,00
so.oo

$31,5?3.U
$24,:97.57

100•
100•

411◄
411S
4116

8"SOR265ewerMaln10·12"=
S-SOR.265ewer' 12-1-r r'\A-.

--

8"SOR26Sewe-Maln14-16'

375

291

Lf Lf IJ'

.71
66
96

'13 16.25
=

$8S

oo

$4 ,,.,6.60

'13

)75
122

58

2'1

J75
722

JOO

.sa

2'1

$0.00
$0.00

o.oo

$0.00

$0.00

$13,0U.2:$
$2t,3S,.S2

IS.313.00

Sl,477.lO

$13,"5.3'

lD0•
1001:

100,

•••

100\:

•

◄1<1 '"'

6'"&.S-Standar,IBootstorManholes

6$

EACH

.9S

41+1

l'l.-.cllOutS.,,,,-

sn<.00

IJ'

r2

,on-,,.	0

0	$0.00

$0.00

,0.t.

103

10,

$'1,4.81.12
$0.00

o•

2108

300.00

Lf

.61

)00

41.tlS
41◄6

5003

-Ull:Statlcn	1

lS	$30 730.39

$30;=

,.s'

1	$0.00

$30,730.3'

100,

lV Test Sewer Main

139
5774.00

EACH
Lf

.94
.36

sg,.<26.66
.,, 17◄.64

0

$0.00
$0.00

5019

urtSl:::atbl 26-28'	1

EACH

686.24

<?64	4

o.s

$0.00

$132,lQ.J.:Z

•••

6013

10" PIICOR IS ForceMain

••• 00

IJ'	=49

<·:3·4 -·0·

1410	lUO	$)4,7'5.20

$>4.765.20

100,

··-

6071

AJr-VlllveAss.

3

$10

Sl.57'. 73

15022

10-JolntRoslrak,ts	22

EACH	$222.29

-	0	22

22	$4,U0.31

$4.l!0.34

100\:

6072

AJrlloleaseManl!ole	3

EACH	t1 1:13.41

<4=	•	3

$4,140.23

$4,14.0..2)

100,

$3.,7,.73

33>

6075
6080
6096
6112
6153
6175.1

10" -	2
Solclnsl311otion	2
tOxlO'"Tee	1
10" 90 Bend	2
IO"Qo	1
OlredloNl0rtl1lO"HDPE	no

EACH	$306.73

EA01	"044.27

+I!

EA01	165.21
EA01 EA01 EA01
Lf	•=4S

$330.<12
$1.263.9<

.,

'$1 "7"7_76
.22
ffl016.SO

0

1

0	2
0
0	1
0	2
0	1
0	1'0

2'

1

0
1
2
77'0

$-1,011.s-t
$0.00
$1,2'3.,4
Sl.,171.,,
$477.22
sss.01,.so

$4,088.54
so.oo
$1,2'3.!K
$l.,177."1'
$477.22
sss.oH.so

1.00•
o•
100•
100,
100•
100,C

6183
6UIS
6186

Punc:11 0lt;Fon:eMain	2 .......00	lF	IS!..72
uateWttTestfot FCl'te Main	2-.00	lF	l«>.SS
Testfor Fa,:,e Main	12•-.oo	lF	l<l.91

$3.870.00

•

•

•

- .,.,.,_50
.so

$0.00

••

$0.00
$0.00

$0.00
$0.0CI
$0.00

••••
,•.•,

TClll>I Prtcefo,a._., 075eWer(GAYltyAod Force_)Items:	$9-	43

Sllll.7911-SO

$679=•.94

100
201	Genen!ICanditlcos
1---"	&.Perfonnance8onds	1
1	LS LS	<391171.85	==o<
.n=oo	l
l		l
l	$0.00
$0.00	$lt,1'11..8S
so,,02.00	100\
100,	
104.02	ConstnJ:tSon &rtrance- .. 	1	E.o0i	.. "HT .24	#C -,07.24	l		l	$0.00	Si,2O7.24	100,	
400
soo	s• -
MB<,its	1	LS
1	LS	t'U71)4.◄9
TotalPricefor above 08 Moblllzation Items:	n7,'7Z2..27
$3'4704.49
$1C •107.85	l
O.l		l
0.1	$0.00
$0.00
$0.00	$37, ,::.,,
.•,o.,s
$130 A1	l.OOt
lOt
llt	

08110lllllzatl0a

CbangeOrders
-0n:1er1	SeC 1

1<13 602.00

..,

LS	1<445496.73

$44S ,..,.....

•

o.,s

....

l	$22,27.(.U

sus.•"·n

100,

Oder 3 CO.IASet

1

=Cha---0-der 2 ATT9eeves	1

LS	$10.710.00

$10710.00

O.$

o.s

$5,355.00

$S,355.OO

so•

-188-SS

Ola  Q-der.f•-.Beartc:alse.t:	1
-,,,•. .._ 0-der SCCUA .1....-_ LSset	1

LS	<S66625.00

LS

188.58

LS	... 023.69

$366 625.00

0,1
l

O.l l

sn.,,2.so

O.IS	$1,711.U

$0.00

s1,.«2.so

$74.110.2,

$40,023-"

101

0.75	O.l

ISt

lOOt

OWttrDlrec:t.,,,..._

Core nt HainMlteial
cae:and Main Ta.zs

Tota1-ma110we  01>aoeOlders:	$9SO	0

1
1

LS LS

($104.889.22
S6.293 ,a

rs1o.;,ssg.22
($5,2933

l
i

$73.011.19

i

l

$601.648.21

u:,,:'3.)S)
(:;3-.,,H!..")

($10..,SH.2:l

•••

...

100•

l.O.O.t

--=

Foct-.>Ma""1al	1	LS	S41Lll6.lll
1	LS	S24.666.97}

fS411 ll6.ll
$24,665.9

0.15
0.15

0.15

$0.00
u.oo
$0.00

0.1s	$0.00

{S:o,,"-9:.!l

...

TotalPrk:efor ucr4eQangeOnSers:	($$46,965.65
$,,H1,4H.31

0.00
$2:U,!O5.ll

($481.598.19'	an
$2,7H,U3.'7

WAIVER AND RELEASE OF LIEN CONDITIONAL UPON PROGRESS PAYMENT

The undersigned llenor, upon payment from the lienee,of thesum of $	224,014.68 , hereby waives and releases Itslien and right toclaim a lien Including all claims, change orders,or demands whatsoever for labor,services,
or materials furnished through		March 25,2022	on the jobof	Rolling HIiis Community Development Dlstl'lct to thefollowingdescribed property:

Pl'oject: R,olling Hills 139 Lots Phase A Location: Bradley Creek Pkwy Invoice#: 7852-16
This waiver and releasedoes notcover any labor,services, or materials furnished after the datespecified. The undersigned represents that he/she Isan authorized agent of Llcnor and hasauthority toexecute this Waiver and Release ofLlen on behalf of Llenor.

Dated on:	March 28, 2022

Lienol"s Name: Vallencourt Construction Co., Inc.
Address: P.O. Box1889
Green Cove Springs, FL 32043

Phone:  904-291-9330

Br, J#Jf-	
Prlnted Name: Kyle Gammon

Title: CFO

STATE OF FLORIDA COUNTY OF CLAY

The foregoing Instrument was acknowledged before me this	20th	dayof byICyle Gammon ofVallencourt Construction Co., Inc., a Florida corporation, on behalf of thecorporation.

  March  	2022

Personally known	X	or Produced ldentlflcatlo-"n	_	Typeof Identification 	 _

{f <t:\ Hotary Public·State of florlda

/ ;i,-·•, -,

MARIA VALDES
j} Commission# HH 165052
1.o,r-. /  My Comm. Expires Oec8, 2025
Bonded through tlatlonal Notary Ann.

Notary I

NOT6: This Iso stat11tory form pres"lbed bySection 713.ZO, Florida Statutes(1996). Effective October 1, 1996,o person may notraqu/r,a 1/enor tofurn/1/1 a waiver orrelease ofl/e11that Is cllfferer1tfro111thestatutory form.

REQUISITION FOR SERIES 2020 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Tn1st Indenture from the District to U.S. Bank National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number:	073
Name of Payee:	TREE AMIGOS Outdoor Services

Amount Payable:	$1,155.00	Invoice 16626

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that:
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and Construction Account referenced above, that each disbursement set forth above was incuned in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;

OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that has not previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be 1·eleased simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: /\	 Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON·COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 P1·oject with respect to which such disbursement is being made, and (iii) the 1·eport of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

,,,,,,1 .
.._.,. ,':,-., \\,•.t -.,.; ,

µ'nlg Engineer

"..._"' ·,"• -

I •\'V",us •· \. #"V / /

•::.:.::.!.. • ,/' V

"?.

'\•''(•  ...

....:: -::	'	', ..,, :::

=

.:·. l!J ,	1,,0 'joB-' •	,	.,•:;::.

:-: .,, !,

i: ,., or- , ; LI-

,::·_·,.•'J..., '\

c·f/\1 c.	' LI{  -

-.I/-

I ,,•• '- ,
-.::,}.\:<-..Ft ors ,,'

,,,,,. ( '	V

\>-. ,' ,:::  ...:

·1. .,' ' '. ,_..,.·-•··.••.,-,,•r,-,

1>\\,'-.....

•I	' • I	"	\ \
• ! ' .'	' ; \ 'i\ \ \ \ • '

-	Tre_e_Amigos
Outdoor s·el'vices

l(a. . ,,t,\, 1 '.s

Invoice
Invoice#: 16626 Date: 12/16/2021

BIiied To: Riverside Management Services 9655 Florida Mining Blvd
Bldg 300 Suite 305 Jacksonville FL

Project: 30247
Rolling HIiis CDD O/S 9655 Florida Mining Blvd Bldg 300 Suite 305 Jacksonville FL

Description	Quantity	Price	Ext Price	
Fix Damage to Center Island Cause by Vallencourt				
(2) yards Landscape Soll @ $75.00 per yard	2.00	75.00	150.00	
(15) 1 gal. Society Garlic@ $7.00 each	15.00	7.00	105.00	
Labor	1.00	900.00	900.00	
Notes:				
		Invoice Total:	$1,155.00	

5000-18 Highway 17 No. 235 Fleming Island, FL 32003 Office: (904) 778-1030 Fax:(904) 778-1045
Emall:cryan@lreeamlgosoutdoor.com Website: www.TreeAmlgosOutdoor.com

Page 1 or 1

REQUISITION FOR SERIES 2020 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the Disti·ict to U.S. Bank National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenturn") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number:	074
Name of Payee:	GP Materials, Inc.

Amount Payable:	$9,964.80	Invoice 3196

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that:
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and Construction Account refe1·enced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each 1·epresents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that has not previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, 1-ight to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set fOl'th above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item 1·epresenting payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquil'ed or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:	.l;>	 Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 Project with 1·espect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

, .,,,r,·. -,0:

.:::: I,

.:::: ' -	,g gineer
I  \,	' ' .\..;::.
..,  .._,. I	" ,•·	.,,,,
:·':::lu:,'	No'36B'32	:'.c' :, :•-•.
:.::: ·l-e	v:	!Ir: :::

,,	I

I

-;;, •-;.\ '.

or-
S1/\f{;. •

'J -
,' liJ ::.:;

.,., • ".'\ \	I ,;.":., '••ot

'l

,.,- ' l"	l'>... ,  '..,. "',

/. .:,:,' ,...:. ....	,,.,

'l l;.;,-.>,. '•./ 0,n,,\'.O',:,:-,' (:J",•.•:•::::-

,,,:-S·

.	.....	"'(,,'
·/; .·.-Odf,\,
! · f. , ii I\\\\\ ' '

PRITCHETT
'"0'

GP Materials, Inc. 1050 SE 6th Street Lake Butler, FL 32054 (386) 496-2630

'(2a\-:f'It·	c\

BIii to: ROLLING HILLS CDD*
3212 BRADLEY CREEK PARKWAY GREEN COVE SPRINGS, FL 32043

Invoice number: 3196
BIii date: 03/19/2022 Reference number: #13243-Rolllng HIiis

Description	Rate method	Units	Rate	Amount

LIME ROCK	Flat amount	1660.8000	6.0000	9,964.80

Total invoice amount:	$9,964.80

03/23/2022 1725

Shipper Actual Arrival	

Bo!	ORDERS LISTING
Pritchett Trucking, Inc.
Commoeflty Description	

Customer	

Rating Units	
Page 1	

03/16/2022 0000	
156386	
LIMEROCK		
28.3700		
03/16/2022 0000	156387	LIMEROCK		30.0900		
03/16/2022 0000	156391	LIMEROCK		28.4500		
03/16/2022 0000	156403	LIMEROCK		27.6500		
03/16/2022 0000	166404	LIMEROCK		28.5000		
03/16/2022 0000	156408	LIMEROCK		24.8200		
03/16/2022 0000	166409	LIMEROCK		29.4800		
03/16/2022 0000	156410	LIMEROCK		29.4200		
03/16/2022 0000	156411	LIMEROCK		29.0700		
03/16/2022 0000	156412	LIMEROCK		28.8300		
03/16/2022 0000	156413	LIMEROCK		28.8700		
03/16/2022 0000	156414	LIMEROCK		26.7300		
03/16/2022 0000	156418	LIMEROCK		28,8400		
03/16/2022 0000	156419	LIMEROCK		28.8300		
03/16/2022 0000	156429	LIMEROCK		28.5000		
03/16/2022 0000	156432	LIMEROCK		25.2500		
03/16/2022 0000	156439	LIMEROCK		24.3200		
03/16/2022 0000	156444	LIMEROCK		29.7300		
03/16/2022 0000	156447	LIMEROCK		29,5100		
03/16/2022 0000	156449	LIMEROCK		28.6800		
03/16/2022 0000	156454	LIMEROCK		29.1600		
03/16/2022 0000	166469	LIMEROCK		29.5600		
03/16/2022 0000	156464	LIMEROCK		29.5000		
03/16/2022 0000	156472	LIMEROCK		29.0600		
03/16/2022 0000.	166473	LIMEROCK		24.6000		
03/17/2022 0000	156508	LIMEROCK		30,0300		
03/17/2022 0000	156619	LIMEROCK		24.6300		
03/17/2022 0000	156620	LIMEROCK		29.6100		
03/17/2022 0000	156522	LIMEROCK		28.8900		
03/17/2022 0000	156526	LIMEROCK		30.0700		
03/17/2022 0000	156527	LIMEROCK		29.3700		
03/17/2022 0000	166639	LIMEROCK		29.1600		
03/17/2022 0000	166542	LIMEROCK		29,4600		

03/23/2022 1725

Shipper Actual Arrival	

Bol	ORDERS LISTING
Pritchett Trucking, Inc.
Commodity Description	

Customer	

Rating Uni!$	
Paga2	

03/17/2022 0000	
156543	
LIMEROCK		
24.8000		
03/17/2022 0000	166644	LIMEROCK		29.0600		
03/17/2022 0000	156545	LIMl;:ROCK		28.8200		
03/17/2022 0000	156550	LIMEROCK		27.1700		
03/17/2022 0000	156552	LIMEROCK		28.8300		
03/17/2022 0000	156555	L.IMEROCK		28.5300		
03/17/2022 0000	166566	LIMEROCK		24.4400		
03/17/2022 0000	156559	LIMEROCK		29.4700		
03/17/2022 0000	156562	LIMEROCK		29.4000		
03/17/2022 0000	156565	LIMEROCK		28.6800		
03/17/2022 0000	156588	LIMEROCK		28.5000		
03/17/2022 0000	156672	LIMEROCK		25.0000		
03/17/2022 0000	156573	LIMEROCK		28.8200		
03/17/2022 0000	156577	LIMEROCK		29,0900		
03/17/2022 0000	156583	LIMEROCK		28.7900		
03/18/2022 0000	156607	LIMEROCK		28,0000		
03/18/2022 0000	156619	LIMEROCK		26,7000		
03/18/2022 0000	156622	LIMEROCK		27.7000		
03/18/2022 0000	156628	LIMEROCK		28.3800		
03/18/2022 0000	156630	LIMEROCK		29.6100		
03/18/2022 0000	156647	LIMEROCK		27,0000		
03/1812022 0000	156657	LIMEROCK		28.0000		
03/18/2022 0000	156667	LIMEROCK		26.0000		
03/18/2022 0000	156668	LIMEROCK		27.5000		
03/18/2022 0000	156669	LIMEROCK		28.9700		
03/18/2022 0000	156673	LIMEROCK		27.5000		
Listing totals						
				1,660.8000		
Number of records: 59						

REQUISITION FOR SERIES 2020 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank National Association, Orlando, Florida, as trustee (the 11Trustee11), dated as of November 1, 2006 (the "Master IndentUl'e11), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the 11Indentme11) (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
(A)	Requisition Number:	075
(8)	Name of Payee:	GP Materials, Inc.

Amount Payable:	$4,181.34	Invoice 3212

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hernby certifies that:
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;

OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that has not previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals 01· copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: N\	L
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 P1·oject with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

..'..-...

, \'

\ \ \ \\ l1/tl!lfiff"1'i

?,?,,

':"'	' . \ ,,,.,,

"' . -•••.·§"!.r(,·tt'j,ng Engineer
\',,, . llSt:;'•, -0 "/

::::·I-. ,' V	',. (,  ,;:,.
-. • ..._ I	'l"l	\ •	.,.,.

:•=•:• l"J.1• :I

?,o\lJl-	\  •'( _.

o	'.

>  :.::.

Fi :.:

• • :i_, I	•	1 r,I --
: :: .).	-jt	:
·._.·:'-._'_\' ',	c:ff-\(\:.Of	,' I1_:1:::

n

.·.·.,. ••','	V

.. V, · ,'',,•; •

rwS .-- •
•. •'	I

'0'

PRITCHETT

GP Materials, Inc. 1050 SE 6th Street Lake Butler, FL 32054 (386) 496-2630

12 ,J!i  1 ·

Bill to: ROLLING HILLS CDD"
3212 BRADLEY CREEK PARKWAY GREEN COVE SPRINGS, FL 32043

Invoice number: 3212
BIii date: 03/26/2022 Reference number: #13243-ROLLING HILLS

Description	Rate method	Units	Rate	Amount

LIME ROCI(	Flat amount	696.8900	6.0000	4,181.34

Total Invoice amount:	$4,181.34

03/31/2022 0804

Shipper Actual Arrival	

Bol	ORDERS LISTING
Pritchett Trucking, Inc.
Commodity Description	

Customer	

Rating Units	
Page 1	

03/22/2022 0000	
156721	
LIMEROCK		
28.9300		
03/22/2022 0000	156722	LIMEROCK		29.1600		
03/22/2022 0000	156723	LIMEROCK		25,2800		
03/22/2022 0000	156729	LIMEROCK		29.1700		
03/22/2022 0000	156730	LIMEROCK		29.7600		
03/22/2022 0000	156731	LIMEROCK		29.5500		
03/22/2022 0000	156733	LIMEROCK		25.3900		
03/22/2022 0000	156734	LIMEROCK		24.6200		
03/22/2022 0000	156735	LIMEROCK		28.0400		
03/22/2022 0000	156736	LIMEROCK		28,9500		
03/22/2022 0000	156742	LIMEROCK		27.9200		
03/22/2022 0000	156743	LIMEROCK		28.8500		
03/22/2022 0000	156757	LIMEROCK		24.6800		
03/22/2022 0000	156758	LIMEROCK		28.6800		
03/22/2022 0000	156767	LIMEROCK		29.0500		
03/22/2022 0000	156768	LIMEROCK		29.0600		
03/22/2022 0000	156769	LIMEROCK		30.0700		
03/22/2022 0000	156773	LIMEROCK		28.7900		
03/22/2022 0000	156792	LIMEROCK		28.7800		
03/22/2022 0000	156796	LIMEROCK		28.6300		
03/22/2022 0000	156804	LIMEROCK		24.0300		
03/21/2022 0003	215	LIMEROCK		29.0000		

03/21/2022 0200	216	LIMEROCK

25.5000

03/21/2022 0100	217	LIMEROCK		
03/21/2022 0100
Listing totals	218	LIMEROCK	29.5000	

Number of records: 25			696.8900	

I	25.5000

REQUISITION FOR SERIES 2020 PROJECT
The undersigned, an Authorized Officer of !Rolling Hills Community Development District (the "District") hereby submits the following requisition fo1· disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Maste1· Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning asc1·ibed to such term in the Indenture):

Req-uisition Number:
Name of Payee:

076
VALLENCOURT CONSTRUCTION, CO.

Amount Payable:  $21,113.88	Invoice 7784· PAY APP 14B

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving p1·ogress payments or state Costs of Issuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that:
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that hasnot previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested ai·e on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:{Y\&	 Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON·COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such 1·eport shall have been amended or modified on the date hereof.
:::,.\\ 1· 'dr-l"ri, '.1..)1,.	I
...,	.. ·v•,c.v. s1,11)-f ngineer
.::;:;1,,: ,' "	', '.A,;:,,
,.._• .•- ., I	\ ,,. /
:::::¼::,'	o?,ou?,?.	'.••,,1(_:,,;,..

•-• !,  I

:, .·,. ',

i< -	: I [pl =--

,,.,: -.-_:

·;:::.':J.\	51/\'Or : LU.:-;
,:_',','\
,,:. .. .'r,, , 1 1OP,fJ'r;/ ._r:7.,::
.	. .-. ·:; -. ? -.<. _ ·

'(Ze11/: 1

Rolling Hills
Community Development District	Request112020-1
March 1, 2022
Serles 2020 Capital Improvement Revenue Bonds

LApp	.. ~

Payee

-.,-	:- -=-	....:....=-=-=--=

Amount

14B	Vallencourt Construction Co. Inc.
-	lnvll 7784	$

,_	TOTAL TO BE FUNDED	$

21,113.88

21,113.88

Wire Instructions;

U.S. Bank NationalAssociation 777E Wlnsconsln Avenue Milwaukee, WI 53202-5300 ABA Routing No.: 091000022 BNF: U.S. Bank CT WIRE CLRG BNF:AccountNo:257088008
Ref: ROLLING HILLS COD2020 Acq & Construction

 Linda Hadden	

From:
Sent:
To:
Subject: Attachments:

Marilee Giles <mgiles@gmsnf.com> Tuesday, April 05, 2022 12:43 PM Keith Hadden; Linda Hadden
Fwd: Rolling Hills Pay Requisition Pay App 14B Funding Request No 1, $21,113.88.pdf; ATT00001.htm

Keith and Linda,

Just following up on this requisition.

Marilee Giles District Manager GMS,LLC
475 West Town Place, Suite 114 St. Augustine, FL 32092
Office: (904) 940-5850 x412
Email: Mgiles@gmsnf.com

Begin forwarded message:

From: Marilee Giles <mgiles@gmsnf.com>
Subject: Rolling Hills Pay Requisition Pay App 148 Date: April 1, 2022 at 3:10:15 PM EDT
To: Keith Hadden <keithhadden@haddeneng.com>
Cc: Linda Hadden <lindahadden@haddeneng.com>, Bill Huck <bhuck@commonbondcap.com>, "david@gscarolina.com" <david@gscarolina.com>, Patti Powers <ppowers@gmssf.com>, "mike2@vallencourt.com" <mike2@vallencourt.com>

Keith

I just spoke to Patti. Can you create a Pay Requisition for this Funding Request as soon as possible? Come to find out, the only way for the Trustee to pay is tlu-u Pay Requisitions (only). The Funding Request was to ADD the $21,113.88 IN TO the Construction account and has not actually been paid out yet.

Looks like on February 23, 2022 you asked Maria Valdes to revise Pay App 1-4 and I see email traffic with the new Pay App A for the $114,000. Please create a Pay Requisition for Pay App B, $21,113.88.

I apologize - I did not understand the process.

REQUISITION FOR SERIES 2020 PROJECT

The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank National Association, Ol'lando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master IndentUl'e"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Numbe1•:	077
Name of Payee:	ETM
Amount Payable:	$5,224.46	INV 0201333
-	$6,351.17	INV0201749
Total:	$11,575.63
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that:
D  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Sei-ies 2020 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that has not previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the

Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.
The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the Disti·ict.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:lf\	
Autho1·ized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cos..t of the Series 2020 Project and is conjlist nt with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

\\\\\\ill

--·

. \\\ ,._().OD
:--..' \
...._, -1V:- ,.,.,.o,,"(;.fltf' ll!J-1., -,[l,:,._._,-"'>:..---------	

2!:/	. 6Ct/nJsU:1tilS-.lf_Engineer

rt   

:::: L!.I •	""o	:
:·-:	:	' t·J :::

1,  1

c•(f>-°'C QY	• IJ.! :::

~::,	1
•• •,, \

1
\C-	I ,>.; ,

·:..;:.• :.\. ',	,J	,' ;,;  :
·,;•·,,·•.,	, ,'!•", .....
,· • , ',. Fl nv,l-• ;-."-" ,:-
•. •".,•	\_I'•:•
• f •	\ \ .'·

'4dt -i

Lof2

Hadden Engineering, Inc.	February 03, 2022		
P.O. Box 9509	Project No:	17186.27000	
Fleming Island, FL 32003	Invoice No:	0201333	

Project	17186.27000	Rolling Hills - CEI Professional Services rendered through January 29, 2022

Total Fee	77,170.87			
Percent Complete	86.77 Total Earned	66,961.16		
	Previous Fee Billing	61,736.70		
	Current Fee Billing	5,224.46		
	Total Fee		5,224.46	
Invoice Total this Period  •	$5,224.46

Outstanding Invoices
Number
0200953
Total

Date
1m2022

Balance
5,401.96
5,401.96

Englancl·Thim)&millczr,lnc.
0:0tUP.$•M:lffiS•S\.IRVEYOR$•Gli•Ul.w.»£AACHffECts
unsruStAuµ. • •W.l»cr,.1t,fl:w'dlln£1•1t1tG16'z..&m•l.ut).163ffll
CAO'l/'2!.U lC«O)lll

rz4 77

;t

0-F

Hadden Engineering, Inc.	March 03, 2022		
P.O. Box 9509	Project No:	17186.27000	
Fleming Island, FL 32003	Invoice No:	0201749	

Project	17186.27000	Rolling Hills - CEI Professional Services rendered through February 26, 2022

Total Fee	77,170.87		
Percent Complete	95.00 Total Earned	73,312.33 Previous Fee BIiiing	 66,961.16		
	Current Fee Billing	6,351.17		
	Total Fee	6,351.17	
	Invoice Total this Period	$6,351.17	
Outstanding Invoices			
Number	Date	Balance		
0201333	2/3/2022	5,224.46		
Total	5,224.46		

England•Thim:.&millar,lnc,
EtXilti££RS•PU:IIIEM•SlJMYCffl1Gl:$• AamCTS
U11500$1A19rlMR»t•,WJ.w<le,fb'.4!Ul51•ftlt)l ffll•luti>lf0.,n.S CA-W..cl!tl lc«o»II

REQUISITION FOR SERIES 2020 PROJECT

The undersigned, an Authorized Officer of Rolling Hills Community Development District, (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank National Association, Ol'lando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Fifth Supplemental Trust Indenture from the District to the Trustee, dated as of October 1, 2020 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):

Requisition Number:

Name of Payee:

Amount Payable:

078
HADDEN ENGINEERING, INC

$3,375.00	INV 6006

Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs ofissuance, if applicable):
Fund or Account and subaccount, if any, from which disbursement to be made:
The undersigned hereby certifies that: -
obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2020 Acquisition and .Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2020 Project and each represents a Cost of the Series 2020 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2020 Costs of Issuance Account that hasnotpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, 01· attachment upon, or claim affecting the right to 1·eceive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: 0L) J\L
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2020 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2020 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2020 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting-Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

,;;-

,,.

,,,\!!!!!J\\\		1,,	.    '
,,,',.,	.

.·..-,".v·-!.·,•,

. -.-	-.;:-::.

'rn:::

,'	'	No 36832	',
:::: )t  ,'	•	I,	-

=::.>\'.:]
-·,

*	: >I-:::

-· l",' .

'(• '

i-1,102,-	•

; J	SJ..	,' ##  --.
-,<\\ \	A	t ,/,'. '
••. ,-·\ 1'  "	,, \.V  ',
-::-;.\1 '• ••oRID{:.,• • :-.,"

1. f..\ \\

, .,.,	\., ', ") •••. -- 0 "'
,·'•,•, C //,'".
•• , • / i Ii/I/!\I\\\

HADDEN ENGINEERING, INC.
POST OFFICE BOX 9509 FLEMING ISLAND, FL 32006 (904) 269-9999

Invoice

DATE	INVOICE#
4/6/2022	6006

Jim Oliver
Rolling Hills CDD
475 West Town Place, Suite 114 World Golf Village
St. Augustine, FL 32092

BILL TO

02/07/22 -- 04/05/22

PERIOD COVERED

	PROJECT NO.	PROJECT	
	14201	RHCDD	
DESCRIPTION	HOURS	RATE	AMOUNT	

Engineering Services
*Approve and Ce1tify to Contractor Pay Requests	
27	
125.00	
3,375.00	
*Create Requisitions and send to GMS
*Communications and coordination with				
Contractors and CDD Manager				

*Scheduling with Contractor
*Site Meetings with Owner & Contractor		

0.00	

0.00
0.00	
	Total	
$3,375.00	
THANK YOU FOR YOUR BUSINESS!	//L

EIGHTH ORDER OF BUSINESS

B.

EXHIBIT C
FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 001
Name of Payee: Pipeline Constructors, Inc.
Amount Payable: $292,884.62
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Monthly progress payment of invoice number 257-1.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
[Kl  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has notpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set

C-1

forth above, which has not been released or will not be released simultaneously with the payment hereof.
The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:(Y"\ 0	
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

8-0'

Alliant Engineering, Inc. Joseph R. Schofield, P.E.
Olgitallysigned by Joseph Schofield
Reason:I attest tothe accuracy
and Integrity of tnis document
Date: 2022.03.08 07:17:03-05'00'

Consulting Engineer

C-2

2U7Norill TempleA,enoe ♦ P.O. Box ISO,Staffle, FL 32001

PIPELINE
ConstJ•11cto1-s, Inc.
Llceme�cuco�ns�kCBC121S4712
ClanYFire"' 7747ll900012006

Phone (004) OfU..2019 • Fax (904) 064-2916

Invoice

3/1/2022		Invoice No. 257-1		
Rolling Hills Community Development District		Project:		
Scott Blunck		Shadow Crest at Rolling Hills		
		Green Cove Springs, FL		

Description:				
Current Gross Monthly Billing			$	308,299.60	
Less 5% Retainage			$	15,414.98	
Current Net Monthly Billing			$	292,884.62	

Payment Due Net Thirty				

Engineer Certification		
Date:				

Net Change Orders #1thru #   _

Revised agreement amount (a+b)

..........................................$_o_.o_o	_
..........................................$.8,057,453.00

d)	Workcompletedtodate

.....................................................      $308,299.60

e)	Value of stored materials (itemized inventory attached)	..............................   $·0-.0-0  -------

f)  Total completed & stored to date (d+e)

.........................................  $308,299.60

g)

Less previous applications (line f from previous draw)

Current application (f-g)
Less_5	%retainage(h"%)

$0.00
$.308,299.60

........................................ $-15-,4-14-.9-8-----

j)	Less other deductions (State if applicable)

k)

Net amount this request (h-i-j)

I)	Balancetocompleteagreement(c-f)

..............................  $·0-.0-0 --------
$,292,884.62
.........................................    $7,749,153.40

m)  Job-To-Date Retainage Held	$.15,414.98

CONDITIONAL PARTIAL WAIVER AND RELEASE OF LIEN

The undersigned subcontractor acknowledges that there are no additional costs or claims for any extras or additions tor labor or material on the described real estate performed to date, except as authorized by signed Change Orders which are included on line "b" belowand further certifies that all 'N'Ork performed or materials installed are in accordance with the approved plans and specificationson the agreement
The undersigned certifies that all laborers and materialmen with regard to the job have been fully paid and that none of such laborers and materialmen have any claims, demands or claims of lien against said premises, and the undersigned subcontractor does hereby agree to indemnify andhold harmless
Rolling HillsComm Dev District against any loss or damage, including a reasonable attorney's fee, whichit may sustain by reason of placing or filing of liens against saidreal estate by subcontractor's laborers or materialmen for amounts due them for services performed to date.

This agreement constitutes a partial release of lien to the extent of all monies due and owing, including the cost of additional labor and material for work being performed without a signed Change Order up to date hereof, and further
is given in accordance with Governing Mechanics Lien Law and the undersigned subcontractor certifies that he has paid all laborers and materialmen to the date hereof and this agreement constitutes a swom affidavit inducing
Rolling Hills Comm Dev District	to make the payment requested.

SIGNATURE MUST BE NOTARIZED OR WITNESSED BY TWO PERSONS.

Witness the hand and seal of the undersigned this 1ST Pipeline Constructors, Inc.
lameof-COrripany
2117 N. Temple Ave Starke, FL 32091

day of March

2022
By:	·--t)J, (...n.i,lflJ«/, /J (()	Project:,.nager
904-964-2019

Before me, the undersigned authortty, personally appeared MarneyBeSt	who, by me being first duly sworn, did acknowledge that heor she is the Project Manager of PipelineConstructors, Inc. and as such has the authority to execute this document and that the facts statedtherein are true.
Dated this 1st 	date of March	20 2022 . My Commission Expires: _3_/_2_6_12 5	_

STATE OF Florida	couNTY OF Bradford

-	Witness: 	

In.A1/.)I«_
Notary 1-'UOIIC

$· = .,...

:. :, ,1

C...IMicflllfMC7)1a,		
.l.c;lliK-..,l,,JDz,
W'"1 ._""""'1*wyW.

CHECK DELIVERY (CIRCLE ONE)• DELIVER TO JOB SITE• REGULAR MAIL• OVERNIGHT-FEDEX/UPS #

Job Name: Shadow Crest at Rolling Hills Job Address: Garden Moss Drive City, State, Zip: Green Cove Springs, FL

This release is contingent upon receipt by the undersigned of the consideration specified above and upon full collection by the undersigned of any and all checks, drafts and instruments given in payment for labor, services or materials on the job.
This waiver and release does not cover any retention or labor, services, or materials furnished after the date specified.
DATED on 22	2022
 Pipeline Constructors, Inc.	

Ptn

(Subcontractoi;.1_Na;ne)
By: --fh°"{,rW/.f::'>e<Jr,
Printed Name Marney Best, PM

STATE OF FLORIDA
COUNTY OF -B-radf-ord----
The foregoing  instrument  was acknowledged  before  me this _M_a_rc_h

_	day

of 2022		, 20.B_g by_	Marney Best	, as	Project Manager of	Pipeline Constructors, Inc.	who is:
(Subcontractor's Name)

------'

Personally known Produced Identification
Type ofldentification Produced	_

"'	I

Pl, IK·SU olflo,1"
eo,,,..t,u •I0401htS
_  ""JC-.U:ir.i-.., l♦. JC?S
bcttdOnucfl"llO'l1I

  2k/rvl(M_
\- F1PUBLIC
My Commission Expires  3/26/25

This is a statutory form prescribed by Section 713.20, Florida Statutes (2001).

Pipeline Constructors, Inc. Shadow Crest at Rolling Hills Schedule of Values

Billing No. Date: Thru Date:

1
3/1/2022
3/1/2022

Description of Work	
Scheduled Value	From Previous Application	This Period Complete	Material Stored	Total Completed to Date	
%	
Balance to Finish	
Retainage	
Mobilization/Construction Stake Out	
Mobilization	$	45,000.00		$	11,250.00		$	11,250.00	25%	$	33,750.00	$	562.50	
Construction Entrance	$	10,500.00		$	-		$	-	0%	$	10,500.00	$	-	
Construction Stake Out	$	25,000.00		$	6,250.00		$	6,250.00	25%	$	18,750.00	$	312.50	
Umbrella	$	100,000.00		$	100,000.00		$	100,000.00	100%	$	-	$	5,000.00	
Total Mobilization	180,500.00	-	117,500.00	-	117,500.00		63,000.00	5,875.00	
Clearing & Earthwork	
Clearing	$	135,120.00		$	-		$	-	0%	$.	135,120.00	$	-	
Stripping	$	300,304.00		$	45,045.60		$	45,045.60	15%	$	255,258.40	$	2,252.28	
Respread	$	205,000.00		$	-		$	-	0%	$	205,000.00	$	-	
Cut	$	147,250.00		$	-		$	-	0%	$	147,250.00	$	-	
Fill	$	340,270.00		$	-		$	-	0%	$	340,270.00	$	-	
Export Strippings	$	210,300.00		$	-		$	-	0%	$	210,300.00	$	-	
Finish Grade	$	58,625.00		$	-		$	-	0%	$	58,625.00	$	-	
Export Good	$	244,375.00		$	-		$	-	0%	$	244,375.00	$	-	
Haul Road	$	53,183.00		$	-		$	-	0%	$	53,183.00	$	-	
Tree Protection	$	6,992.00		$	5,244.00		$	5,244.00	75%	$	1,748.00	$	262.20	
Total Earthwork	1,701,419.00	-	50,289.60	-	50,289.60		1,651,129.40	2,514.48	
Pond Excavation	
Cut	568,800.00		$	-		$	-	0%	$	568,800.00	$	-	
Total Pond Excavation	568,800.00	-	-	-	-		568,800.00	-	
Erosion Control	
Silt Fence	24,420.00		$	12,210.00		$	12,210.00	50%	$	12,210.00	$	610.50	
Erosion Control	24,000.00	$	-	$	1,200.00		$	1,200.00	5%	$	22,800.00	$	60.00	
Total Erosion Control	48,420.00	-	13,410.00	-	13,410.00		35,010.00	670.50	
SWPPP	
N.0.1.	2,200.00		$	2,200.00		$	2,200.00	100%	$	-	$	110.00	
N.P.D.E.S.	18,000.00		$	900.00		$	900.00	5%	$	17,100.00	$	45.00	
Total SWPPP	20,200.00	-	$	3,100.00		$	3,100.00		$	17,100.00	$	155.00	
Storm Drain System	
C Inlet	3,489.35		$	-		$	-	0%	$	3,489.35	$	-	
Curb Inlet	76,427.50		$	-		$	-	0%	$	76,427.50	$	-	
Double Curb Inlet	163,039.10		$	-		$	-	0%	$	163,039.10	$	-	

 	

Pipeline Constructors, Inc. Shadow Crest at Rolling Hills Schedule of Values

Billing No. Date: Thru Date:

1
3/1/2022
3/1/2022

Manhole	21,879.30		$	-		$	-	0%	$	21,879.30	$	-	
Junction Box	6,959.00		$	-		$	-	0%	$	6,959.00	$	-	
Control Structure	14,534.00		$	-		$	-	0%	$	14,534.00	$	-	
Skimmer	11,616.00		$	-		$	-	0%	$	11,616.00	$	-	
Yard Drain	4,230.00		$	-		$	-	0%	$	4,230.00	$	-	
15" MES	1,563.00		$	-		$	-	0%	$	1,563.00	$	-	
18" MES	3,326.00		$	-		$	-	0%	$	3,326.00	$	-	
24" MES	2,260.00		$	-		$	-	0%	$	2,260.00	$	-	
36" MES	12,120.00		$	-		$	-	0%	$	12,120.00	$	-	
42" MES	10,200.00		$	-		$	-	0%	$	10,200.00	$	-	
15" HP	23,565.20		$	-		$	-	0%	$	23,565.20	$	-	
18" HP	106,705.36		$	-		$	-	0%	$	106,705.36	$	-	
24" HP	94,425.52		$	-		$	-	0%	$	94,425.52	$	-	
30" HP	28,722.80		$	-		$	-	0%	$	28,722.80	$	-	
36" HP	115,891.21		$	-		$	-	0%	$	115,891.21	$	-	
42" HP	57,666.56		$	-		$	-	0%	$	57,666.56	$	-	
Orifice Materials	717.00		$	-		$	-	0%	$	717.00	$	-	
Rip Rap	14,880.00		$	-		$	-	0%	$	14,880.00	$	-	
Laser Profile	50,750.10		$	-		$	-	0%	$	50,750.10	$	-	
Layout	9,100.00		$	-		$	-	0%	$	9,100.00	$	-	
As-builts	14,300.00		$	-		$	-	0%	$	14,300.00	$	-	
Total Storm Drain System	848,367.00	-	-	-	-		848,367.00	-	
Water Main	
Remove Plug & Connect	7,450.00		$	-		$	-	0%	$	7,450.00	$	-	
12" DR 18	383,748.78		$	-		$	-	0%	$	383,748.78	$	-	
8" DR 18	127,890.36		$	-		$	-	0%	$	127,890.36	$	-	
6" DIP	7,090.56		$	-		$	-	0%	$	7,090.56	$	-	
4" DR 18	10,558.80		$	-		$	-	0%	$	10,558.80	$	-	
Short Service	23,901.00		$	-		$	-	0%	$	23,901.00	$	-	
Short Double Service	65,007.00		$	-		$	-	0%	$	65,007.00	$	-	
Long Single Service	9,580.95		$	-		$	-	0%	$	9,580.95	$	-	
Long Double Service	120,333.00		$	-		$	-	0%	$	120,333.00	$	-	
12" Gate Valve	46,444.20		$	-		$	-	0%	$	46,444.20	$	-	
8" Gate Valve	14,542.80		$	-		$	-	0%	$	14,542.80	$	-	
6" Gate Valve	28,850.70		$	-		$	-	0%	$	28,850.70	$	-	
Fire Hydrant	49,144.45		$	-		$	-	0%	$	49,144.45	$	-	
Flushing Hydrant	1,655.25		$	-		$	-	0%	$	1,655.25	$	-	

Blow Off	4,965.75		$	-		$	-	0%	$	4,965.75	$	-	
12" Misc Fittings	32,777.10		$	-		$	-	0%	$	32,777.10	$	-	
8" Misc Fittings	13,946.80		$	-		$	-	0%	$	13,946.80	$	-	
4" Misc Fittings	2,214.00		$	-		$	-	0%	$	2,214.00	$	-	
Restraints/Wire	41,222.60		$	-		$	-	0%	$	41,222.60	$	-	
PT/BT	17,000.00		$	-		$	-	0%	$	17,000.00	$	-	
Layout	18,000.00		$	-		$	-	0%	$	18,000.00	$	-	
Wire Testing	23,121.90		$	-		$	-	0%	$	23,121.90	$	-	
Asbuilts	24,000.00		$	-		$	-	0%	$	24,000.00	$	-	
Total Water Main	1,073,446.00	-	-	-	-		1,073,446.00	-	
Ke-use Mam	
Remove Plug & Connect	3,725.00		$	-		$	-	0%	$	3,725.00	$	-	
12" DR 18	386,678.16		$	-		$	-	0%	$	386,678.16	$	-	
6" DR 18	45,007.54		$	-		$	-	0%	$	45,007.54	$	-	
4" DR 18	50,469.10		$	-		$	-	0%	$	50,469.10	$	-	
Short Service	13,926.60		$	-		$	-	0%	$	13,926.60	$	-	
Short Double Service	89,234.55		$	-		$	-	0%	$	89,234.55	$	-	
Long Single Service	7,395.50		$	-		$	-	0%	$	7,395.50	$	-	
Long Double Service	107,696.00		$	-		$	-	0%	$	107,696.00	$	-	
12" Gate Valve	42,222.00		$	-		$	-	0%	$	42,222.00	$	-	
6" Gate Valve	5,091.30		$	-		$	-	0%	$	5,091.30	$	-	
4" Gate Valve	5,206.40		$	-		$	-	0%	$	5,206.40	$	-	
Flushing Hydrant	3,400.20		$	-		$	-	0%	$	3,400.20	$	-	
Blow Off	5,100.65		$	-		$	-	0%	$	5,100.65	$	-	
12" Misc Fittings	23,110.35		$	-		$	-	0%	$	23,110.35	$	-	
6" Misc Fittings	2,580.65		$	-		$	-	0%	$	2,580.65	$	-	
4" Misc Fittings	3,539.00		$	-		$	-	0%	$	3,539.00	$	-	
Restraints/Wire	39,248.40		$	-		$	-	0%	$	39,248.40	$	-	
PT/BT	12,500.00		$	-		$	-	0%	$	12,500.00	$	-	
Layout	8,800.00		$	-		$	-	0%	$	8,800.00	$	-	
Wire Testing	22,728.60		$	-		$	-	0%	$	22,728.60	$	-	
Asbuilts	12,400.00		$	-		$	-	0%	$	12,400.00	$	-	
Total Re-Use Main	890,060.00	-	-	-	-		890,060.00	-	
Sewer System	

Pipeline Constructors, Inc. Shadow Crest at Rolling Hills Schedule of Values

Billing No. Date: Thru Date:

1
3/1/2022
3/1/2022

Pipeline Constructors, Inc. Shadow Crest at Rolling Hills Schedule of Values

Billing No. Date: Thru Date:

1
3/1/2022 •
3/1/2022

Manhole "A" (4-6)	143,264.35		$	-		$	-	0%	$	143,264.35	$	-	

Manhole "B" (10-12)	27,229.55		$	-		$	-	0%	$	27,229.55	$	-	

Drop Bowls	2,925.22		$	-		$	-	0%	$	2,925.22	$	-	

10" PVC	10,769.47		$	-		$	-	0%	$	10,769.47	$	-	

8" PVC (4-6}	384,542.76		$	-		$	-	0%	$	384,542.76	$	-	
Services	289,199.95		$	-		$	-	0%	$	289,199.95	$	-	
Dewater	134,848.00		$	-		$	-	0%	$	134,848.00	$	-	
Layout	4,900.00		$	-		$	-	0%	$	4,900.00	$	-	
T.V.	67,634.70		$	-		$	-	0%	$	67,634.70	$	-	
Asbuilts	7,700.00		$	-		$	-	0%	$	7,700.00	$	-	
Total Sewer System	1,073,014.00	-	-	-	-		1,073,014.00	-	
Conduit	
Gray Conduit (1260')	24,926.00		$	-		$	-	0%	$	24,926.00	$	-	
Total Conduit	24,926.00	-	-	-	-		24,926.00	-	
Roadway	
Mixing	176,400.00		$	-		$	-	0%	$	176,400.00	$	-	
Asphat Base - 6"	238,317.00		$	-		$	-	0%	$	238,317.00	$	-	
Base Finishing	152,994.47		$	-		$	-	0%	$	152,994.47	$	-	
Asphalt Paving - 2 ea 1" Lifts	362,111.30		$	-		$	-	0%	$	362,111.30	$	-	
Prime	19,634.23		$	-		$	-	0%	$	19,634.23	$	-	
Pavement Marking/Signage	9,295.00		$	-		$	-	0%	$	9,295.00	$	-	
Pavement Marking Final	1,595.00		$	-		$	-	0%	$	1,595.00	$	-	
Total Roadway	960,347.00	-	-	-	-		960,347.00	-	
Curb & Gutter	
Curbs Miami	268,094.00		$	-		$	-	0% $	268,094.00	$	-	
Total Curb & Gutter	268,094.00	-	-	-	-		268,094.00	-	
Concrete Sidealks	
Sidewalk	77,620.00		$	-		$	-	0%	$	77,620.00	$	-	
ADA Mats	28,380.00		$	-		$	-	0%	$	28,380.00	$	-
-	
Total Sidewalks	106,000.00	-	-	-	-		106,000.00		
Sodding	
Sodded Path Sand	356.40		$	-		$	-	0%	$	356.40	$	-	
Sodded Path	96.25		$	-		$	-	0%	$	96.25	$	-	
Sod Pond #1	21,602.35		$	-		$	-	0%	$	21,602.35	$	-	

 	

Pipeline Constructors, Inc. Shadow Crest at Rolling Hills Schedule of Values

Billing No. Date: Thru Date:

1
3/1/2022 •
3/1/2022

Sod Pond #2	19,658.10		$	-		$	-	0%	$	19,658.10	$	-	
Sod Pond #3	14,029.40		$	-		$	-	0%	$	14,029.40	$	-	
Sod Pond Backs	19,681.50		$	-		$	-	0%	$	19,681.50	$	-	
Sod Lot Slopes	24,547.60		$	-		$	-	0%	$	24,547.60	$	-	
Sod Swales	18,283.65		$	-		$	-	0%	$	18,283.65	$	-	
Sod Spreader Swales	88.55		$	-		$	-	0%	$	88.55	$	-	
Sod B.O.C.	13,576.20		$	-		$	-	0%	$	13,576.20	$	-	
Total Sod	131,920.00	-	-	-	-		131,920.00	-	

Seeding/Mulching
Jseeding ROW & Lots		I	180,125.00	I$	-	I$	-	I	0%	$	180,125.oo I	$	-	I	
!Total Seeding/Mulching	
I	180,125.00	-	I	-	-	I	-	I	1so,12s.oo I	-	
Bond
!Bond	l	124,000.00 I	$	124,000.00 I		l$	124,000.00  I	100%1	$	-	l $	6,200.00	
!Total Bond	1	124,000.00  I	124,000.00 I	-	1	124,000.00 I	I	-	1	6,200.00	
Sales Tax Credit
Sales Tax Credit	(142,185.00}		$	-		$	-	0%	$	{142,185.00)	$	-	
Total Bond	(142,185.00)	-	-	-	-	-	(142,185.00)	-	
TOTAL	8,057,453.00	-	308,299.60	-	308,299.60		7,749,153.40	15,414.98	

EXHIBIT C
FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 002

Name of Payee: Kutak Rock LLP
Amount Payable: $941.00
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Monthly progress payment of invoice number 17523-4.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
!Kl  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;

OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has notpreviously been paid out of such Account.

The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set

C-1

forth above, which has not been released or will not be released simultaneously with the payment hereof.
The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: (Y\	►
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specificationsfor the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.
Alliant Engineering, Inc. Joseph R. Schofield, P.E.
Dlgttally signed by Joseph Schollekl
Reason: I attest 10theaccuracy
and Integrity olthisdocument
Dale: 2022.03.08 07:26:50-05'00'

Consulting Engineer

C-2

KUTAK  ROCK  LLP
TALLAHASSEE, FLORIDA
Telephone 404-222-4600
Facsimile 404-222-4654

Federal ID 47-0597598

March 4, 2022

Check Remit To: Kutak Rock LLP PO Box 30057
Omaha, NE 68103-1157

Wire Transfer Remit To:
ABA # I040000 I 6
First National Bank of Omaha
Kutak Rock LLP
NC# 24690470
Reference: Invoice No. 3020386 Client Matter No. 17523-4

Marilee Giles Rolling Hills CDD
Governmental Management Services - St. Augustine Suite 114
475 West Town Place
St. Augustine, FL 32092	Invoice No. 3020386
17523-4

Re:	2022 Construction

For Professional Legal Services Rendered

11/18/21	M. Rigoni	0.10	25.00	Follow-up with Buchanan regarding	
				bid process	
12/13/21	K. Buchanan	0.80	244.00	Confer with Blunck regarding review	
				of construction proposals and rebid
process;	prepare	request	for	

12/13/21

M. Rigoni

0.80	200.00

proposals; confer with Sweeting regarding same
Conference with Buchanan regarding upcoming board meeting; review District rules regarding noticing procedures; prepare form notices rejecting all bids

	easement for Phase 3B and 3C	
01/17/22	K. Buchanan	0.40	122.00	Review Phase 3B/C site work bid	
01/19/22	M. Rigoni	0.60	150.00	Prepare form notices of intent to
award  Phase  3B/3C  bids;  review	

01/26/22	
M. Rigoni	
0.20	
50.00	final agenda
Correspondence	with	Blunk	

01/10/22

M. Rigoni

0.60

150.00

Prepare	temporary	construction

regarding	form	of	construction agreement

KUTAK ROCK LLP
Rolling Hills CDD March 4, 2022
Client Matter No. 17523-4 Invoice No. 3020386
Page 2
TOTAL HOURS	3.50
TOTAL FOR SERVICES RENDERED	$941.00
TOTAL CURRENT AMOUNT DUE	$941.00

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 003
Name of Payee: Alliant Engineering, Inc.

Amount Payable: $1,067.50
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): CDD Engineering support
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
!XI  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has notpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

C-1

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:	M	 b,	
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

Alliant Engineering, Inc. Joseph R. Schofield, P.E.
Digitally signed byJosephSchofield Roasoo: I attest to theaccuracy and llltegrity or this document
Dale:2022.03.2317:23:11·04'00'

Consulting Engineer

C-2

Rolling Hills Community Development District
Attn: Accounts Payable			
475 West Town Place, Suite 114, World Golf Village	March 10, 2022		
St. Augustine, FL 32092	Invoice No:	69804	
	Due Date:	April 9, 2022	

Project Contact	Johnson, Stacey
Project	221‐0076.1	Rolling Hills CDD
Professional Services from February 1, 2022 to February 28, 2022
Task	001	CDD
Fee
Total Fee	12,500.00
Percent Complete	100.00 Total Earned	 12,500.00 Previous Fee Billing	12,500.00
Current Fee Billing	0.00
Total Fee	0.00

Total this Task	0.00

Task	002	CDD Engineering
Professional Personnel

Employee

Hours	Rate	Amount

Oestman, Adam	1.50	95.00	142.50
Pre‐con Meeting
Schofield, Joseph	1.00	185.00	185.00
plan change and submittal prep. per pre‐construction mtg. w/ county and contractor requests.
Schofield, Joseph	1.00	185.00	185.00
plan revisions and corres. per contractor and count pre‐con. mtg. action items.
Schofield, Joseph	3.00	185.00	555.00
pre‐construction mtg. at County, travel, and support to contractor.
Totals	6.50	1,067.50
Total Labor	1,067.50

Total this Task	$1,067.50

Total this Invoice 	$1,067.50

email: accounting@alliant‐inc.com

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 004
Name of Payee: Pipeline Constructors, Inc.

Amount Payable: $407,082.01
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Monthly progress payment of invoice number 257-2.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
IKJ  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incuned in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has notpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:M	 k
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than theSeries 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.
Alliant Engineering, Inc. Joseph R. Schofield, P.E.
DigHairysigned by Joseph
SChOlleld
Reason:I amapproving this
document
Dale: 2022.03.31 14:54:30-04'00'

Consulting Engineer

Capital City
W.Bank

1/21/22

Re: ACH Account information for Pipeline Constructors Inc

This letter is to confirm that account number 10000928837 under the name of Pipeline Constructors Inc is held at Capital City Bank. The account was established and has been in good standing at the bank since 9/15/21.

Below are our wiring and ACH ABA information: Bank Routing Number: 063100688
For payments being sent via wire, the ABA is 063100688. For payments being sent via ACH, the ABA is 063100688.

Please feel free to contact me should you need any further information.

Sincerely,

Matthew Dyal, Client Experience Manager, Starke Office

Capital CitY Bank I  P.O. Box 900 I  Tallahassee, FL 32302-0900 I  850.671.0400 I ""w.ccbg.com

Invoice

3/30/2022		Invoice No. 257-2		
Rolling Hills Community Development District Scott Blunck		Project:
Shadow Crest at Rolling Hills Green Cove Springs, FL		

Description:				
Current Gross Monthly Billing			$	428,507.38	
Less 5% Retainage			$	21,425.37	
Current Net Monthly Billing			$	407,082.01	

Payment Due Net Thirty				

Engineer Certification		
Date:		

REQUEST FOR PAYMENT

DRAW (INVOICE) #: DRAW DATE: PERIOD END DATE: PROJECT # PROJECT: LOCATION:

CONDITIONAL PARTIAL WAIVER AND RELEASE OF LIEN

Amount of original agreement	$	
Net Change Orders #1 thru #	$	
Revised agreement amount (a+b)	$	

Work completed to date	$	
Value of stored materials (itemized inventory attached)	$	
Total completed & stored to date (d+e)	$	
Less previous applications (line f from previous draw)	$	
Current application (f-g)	$	
Less 	% retainage (h*%)	$	
Less other deductions (State if applicable)	$	
Net amount this request (h-i-j)	$	
Balance to complete agreement (c-f)	$	
Job-To-Date Retainage Held	$			OFFICE USE ONLY		

The undersigned subcontractor acknowledges that there are no additional costs or claims for any extras or additions for labor or material on the described real estate performed to date, except as authorized by signed Change Orders which are included on line "b" below and further certifies that all work performed or materials installed are in accordance with the approved plans and specifications on the agreement.
The undersigned certifies that all laborers and materialmen with regard to the job have been fully paid and that none of such laborers and materialmen have any claims, demands or claims of lien against said

This agreement constitutes a partial release of lien to the extent of all monies due and owing, including the cost of additional labor and material for work being performed without a signed Change Order up to date hereof, and further
is given in accordance with Governing Mechanics Lien Law and the undersigned subcontractor certifies that he has paid all laborers and materialmen to the date hereof and this agreement constitutes a sworn affidavit inducing

premises, and the undersigned subcontractor does hereby agree to indemnify and hold harmless		to make the payment requested.

SIGNATURE MUST BE NOTARIZED OR WITNESSED BY TWO PERSONS.

	against any loss or damage, including a reasonable attorney's fee, which it may sustain by reason of placing or filing of liens against said real estate by subcontractor's laborers or materialmen for amounts due them for services performed to date.

Witness the hand and seal of the undersigned this 	day of 	,20	

Signature

Title

By:
Name of Company

Address	Phone

Before me, the undersigned authority, personally appeared 	who, by me being first duly sworn, did acknowledge that

he or she is the 	of 	and as such has the authority to execute this document and that the facts stated therein are true.
Dated this 	date of 	, 20	. My Commission Expires: 	

STATE OF 	COUNTY OF 	

Witness: 	

Notary Public

CHECK DELIVERY (CIRCLE ONE) * DELIVER TO JOB SITE * REGULAR MAIL * OVERNIGHT-FEDEX/UPS #	

CONDITIONAL WAIVER AND RELEASE OF LIEN
UPON PROGRESS PAYMENT
The undersigned lienor, in consideration of the sum of $	, hereby waives and releases its lien and right to claim a lien for labor, services or materials
furnished through 	 to 	 on the job of
	, to the following described property:
Job Name: 		 Job Address: 	 City, State, Zip: 		

This release is contingent upon receipt by the undersigned of the consideration specified above and upon full collection by the undersigned of any and all checks, drafts and instruments given in payment for labor, services or materials on the job.
This waiver and release does not cover any retention or labor, services, or materials furnished after the date specified.
DATED on 	, 20	.

STATE OF FLORIDA

Pipeline Constructors, Inc.

(Subcontractor’s Name)
By: 	 Printed Name Marney Best, PM

COUNTY OF

Bradford

The foregoing instrument was acknowledged before me this 	 day

of 	, 20  , by	Marney Best	, as

Project Manager

of	Pipeline Constructors, Inc.
(Subcontractor’s Name)

, who is:

	Personally known
	Produced Identification
Type of Identification Produced	

NOTARY PUBLIC
My Commission Expires

3/26/25

This is a statutory form prescribed by Section 713.20, Florida Statutes (2001).

Pipeline Constructors, Inc.	Billing No.	2	
Shadow Crest at Rolling Hills	Date:	3/30/2022	
Schedule of Values	Thru Date:	3/30/2022	

Description of Work

Scheduled Value

From Previous Application

This Period Complete

Material Stored

Total Completed
to Date	%

Balance to Finish

Retainage

Mobilization/Construction Stake Out

Mobilization Construction Entrance Construction Stake Out Umbrella
Total Mobilization

Clearing Stripping Respread Cut
Fill
Export Strippings Finish Grade Export Good Haul Road
Tree Protection
Total Earthwork

Cut
Total Pond Excavation

Silt Fence Erosion Control
Total Erosion Control

N.O.I. N.P.D.E.S.

$	45,000.00
$	10,500.00
$	25,000.00
$	100,000.00
180,500.00

$	135,120.00
$	300,304.00
$	205,000.00
$	147,250.00
$	340,270.00
$	210,300.00
$	58,625.00
$	244,375.00
$	53,183.00
$	6,992.00
1,701,419.00

568,800.00
568,800.00

24,420.00
24,000.00
48,420.00

2,200.00
18,000.00

$	11,250.00
$	-
$	6,250.00
$	100,000.00
117,500.00

$	-
$	45,045.60
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	5,244.00
50,289.60

-

$	12,210.00
$	1,200.00
13,410.00

$	2,200.00
$	900.00

$	-
$	2,625.00
$	-
$	-
2,625.00	-
Clearing & Earthwork
$	135,120.00
$	180,182.40
$	-
$	-
$	34,027.00
$	-
$	-
$	-
$	7,977.45
$	1,748.00
359,054.85	-
Pond Excavation
$	56,880.00
56,880.00	-
Erosion Control
$	12,210.00
$	1,200.00
13,410.00	-
SWPPP
$	-
$	900.00

$	11,250.00
$	2,625.00
$	6,250.00
$	100,000.00
120,125.00

$	135,120.00
$	225,228.00
$	-
$	-
$	34,027.00
$	-
$	-
$	-
$	7,977.45
$	6,992.00
409,344.45

$	56,880.00
56,880.00

$	24,420.00
$	2,400.00
26,820.00

$	2,200.00
$	1,800.00

25% $
25% $
25% $
100% $

100% $
75% $
0% $
0% $
10% $
0% $
0% $
0% $
15% $
100% $

10% $

100% $
10% $

100% $
10% $

33,750.00  $
7,875.00  $
18,750.00  $
-	$
60,375.00

-	$
75,076.00  $
205,000.00  $
147,250.00  $
306,243.00  $
210,300.00  $
58,625.00  $
244,375.00  $
45,205.55  $
-	$
1,292,074.55

511,920.00  $
511,920.00

-	$
21,600.00  $
21,600.00

-	$
16,200.00  $

562.50
131.25
312.50
5,000.00
6,006.25

6,756.00
11,261.40
-
- 1,701.35
-
-
- 398.87
349.60
20,467.22

2,844.00
2,844.00

1,221.00
120.00
1,341.00

110.00
90.00

									

									

									

									

									

									

									

									

									

									

	

									

Total SWPPP

C Inlet Curb Inlet
Double Curb Inlet Manhole Junction Box

20,200.00

3,489.35
76,427.50
163,039.10
21,879.30
6,959.00

3,100.00

$	900.00
Storm Drain System
$	-
$	-
$	-
$	-
$	-

$	4,000.00

$	-
$	-
$	-
$	-
$	-

$

0% $
0% $
0% $
0% $
0% $

16,200.00	$

3,489.35  $
76,427.50  $
163,039.10  $
21,879.30  $
6,959.00  $

200.00

-
-
-
-
-

Pipeline Constructors, Inc.	Billing No.	2	
Shadow Crest at Rolling Hills	Date:	3/30/2022	
Schedule of Values	Thru Date:	3/30/2022	

Control Structure Skimmer
Yard Drain 15" MES
18" MES
24" MES
36" MES
42" MES
15" HP
18" HP
24" HP
30" HP
36" HP
42" HP
Orifice Materials Rip Rap
Laser Profile Layout
As-builts
Total Storm Drain System

14,534.00
11,616.00
4,230.00
1,563.00
3,326.00
2,260.00
12,120.00
10,200.00
23,565.20
106,705.36
94,425.52
28,722.80
115,891.21
57,666.56
717.00
14,880.00
50,750.10
9,100.00
14,300.00
848,367.00

$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-	$
$	-
$	-	$
$	-
$	-	$
$	-
$	-
$	-
$	-
$	-
$	-
-	-

$
$
$
$
$
$
$
$ 7,165.20  $
$ 17,467.20  $
$ 31,022.40  $
$
$
$
$
$
$
55,654.80

-
-
-
-
-
-
-
- 7,165.20
- 17,467.20
- 31,022.40
-
-
-
-
-
-
55,654.80

0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $
0% $

14,534.00  $
11,616.00  $
4,230.00  $
1,563.00  $
3,326.00  $
2,260.00  $
12,120.00  $
10,200.00  $
16,400.00  $
106,705.36  $
76,958.32  $
28,722.80  $
84,868.81  $
57,666.56  $
717.00 $ 14,880.00 $ 50,750.10 $ 9,100.00 $ 14,300.00  $
792,712.20

-
-
-
-
-
-
-
- 358.26
- 873.36
- 1,551.12
-
-
-
-
-
-
2,782.74

									

									

									

									

									

									

									

									

									

									

									

									

									

Remove Plug & Connect	7,450.00
12" DR 18	383,748.78
8" DR 18	127,890.36
6" DIP	7,090.56
4" DR 18	10,558.80
Short Service	23,901.00
Short Double Service	65,007.00
Long Single Service	9,580.95
Long Double Service	120,333.00
12" Gate Valve	46,444.20
8" Gate Valve	14,542.80
6" Gate Valve	28,850.70
Fire Hydrant	49,144.45
Flushing Hydrant	1,655.25
Blow Off	4,965.75
12" Misc Fittings	32,777.10
8" Misc Fittings	13,946.80
4" Misc Fittings	2,214.00

Water Main
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-

$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $

7,450.00  $	-
383,748.78  $	-
127,890.36  $	-
7,090.56  $	-
10,558.80  $	-
23,901.00  $	-
65,007.00  $	-
9,580.95  $	-
120,333.00  $	-
46,444.20  $	-
14,542.80  $	-
28,850.70  $	-
49,144.45  $	-
1,655.25  $	-
4,965.75  $	-
32,777.10  $	-
13,946.80  $	-
2,214.00  $	-

Pipeline Constructors, Inc.	Billing No.	2	
Shadow Crest at Rolling Hills	Date:	3/30/2022	
Schedule of Values	Thru Date:	3/30/2022	

Restraints/Wire
PT/BT
Layout
Wire Testing Asbuilts
Total Water Main

41,222.60	$	-
17,000.00	$	-
18,000.00	$	-
23,121.90	$	-
24,000.00	$	-
1,073,446.00	-	-

$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
-	-

41,222.60  $	-
17,000.00  $	-
18,000.00  $	-
23,121.90  $	-
24,000.00  $	-
1,073,446.00	-

Remove Plug & Connect	3,725.00
12" DR 18	386,678.16
6" DR 18	45,007.54
4" DR 18	50,469.10
Short Service	13,926.60
Short Double Service	89,234.55
Long Single Service	7,395.50
Long Double Service	107,696.00
12" Gate Valve	42,222.00
6" Gate Valve	5,091.30
4" Gate Valve	5,206.40
Flushing Hydrant	3,400.20
Blow Off	5,100.65
12" Misc Fittings	23,110.35
6" Misc Fittings	2,580.65
4" Misc Fittings	3,539.00
Restraints/Wire	39,248.40
PT/BT	12,500.00
Layout	8,800.00
Wire Testing	22,728.60
Asbuilts	12,400.00

Re-Use Main
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-
$	-

$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $

3,725.00  $	-
386,678.16  $	-
45,007.54  $	-
50,469.10  $	-
13,926.60  $	-
89,234.55  $	-
7,395.50  $	-
107,696.00  $	-
42,222.00  $	-
5,091.30  $	-
5,206.40  $	-
3,400.20  $	-
5,100.65  $	-
23,110.35  $	-
2,580.65  $	-
3,539.00  $	-
39,248.40  $	-
12,500.00  $	-
8,800.00  $	-
22,728.60  $	-
12,400.00  $	-

									

									

	

									

									

									

									

									

									

									

									

									

Total Re-Use Main

Manhole "A" (4-6)
Manhole "B" (10-12) Drop Bowls
10" PVC
8" PVC (4-6)
Services

890,060.00

143,264.35
27,229.55
2,925.22
10,769.47
384,542.76
289,199.95

-	-	-
Sewer System
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$

-

-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $

890,060.00	-

143,264.35  $	-
27,229.55  $	-
2,925.22  $	-
10,769.47  $	-
384,542.76  $	-
289,199.95  $	-

Pipeline Constructors, Inc.	Billing No.	2	
Shadow Crest at Rolling Hills	Date:	3/30/2022	
Schedule of Values	Thru Date:	3/30/2022	

Dewater
Layout T.V.
Asbuilts
Total Sewer System

134,848.00	$	-
4,900.00	$	-
67,634.70	$	-
7,700.00	$	-
1,073,014.00	-	-

$	-	0% $
$	-	0% $
$	-	0% $
$	-	0% $
-	-

134,848.00  $	-
4,900.00  $	-
67,634.70  $	-
7,700.00  $	-
1,073,014.00	-

Gray Conduit (1260')	24,926.00

Conduit
$	-	$

14,553.00  $

14,553.00

0% $

10,373.00  $

727.65

Total Conduit

Mixing
Asphat Base - 6" Base Finishing
Asphalt Paving - 2 ea 1" Lifts Prime
Pavement Marking/Signage Pavement Marking Final Total Roadway

Curbs Miami
Total Curb & Gutter

24,926.00

176,400.00
238,317.00
152,994.47
362,111.30
19,634.23
9,295.00
1,595.00
960,347.00

268,094.00
268,094.00

-	-
Roadway
$	-
$	-
$	-
$	-
$	-
$	-
$	-
-	-
Curb & Gutter
$	-
-	-

14,553.00

$
$
$
$
$
$
$
-

$
-

14,553.00

-
-
-
-
-
-
-
-

-
-

0% $
0% $
0% $
0% $
0% $
0% $
0% $

0% $

10,373.00

176,400.00  $
238,317.00  $
152,994.47  $
362,111.30  $
19,634.23  $
9,295.00  $
1,595.00  $
960,347.00

268,094.00  $
268,094.00

727.65

-
-
-
-
-
-
-
-

-
-

Sidewalk	77,620.00
ADA Mats	28,380.00

Concrete Sidealks
$	-	$
$	-	$

-	0% $
-	0% $

77,620.00  $	-
28,380.00  $	-

									

									

									

									

									

									

									

									

	

									

									

									

	

Total Sidewalks

Sodded Path Sand Sodded Path
Sod Pond #1
Sod Pond #2
Sod Pond #3 Sod Pond Backs Sod Lot Slopes Sod Swales
Sod Spreader Swales Sod B.O.C.
Total Sod

Seeding ROW & Lots

106,000.00

356.40
96.25
21,602.35
19,658.10
14,029.40
19,681.50
24,547.60
18,283.65
88.55
13,576.20
131,920.00

180,125.00

-	-	-
Sodding
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
$	-	$
-	-	-
Seeding/Mulching
$	-	$

-

-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-	0% $
-

-	0% $

106,000.00	-

356.40  $	-
96.25  $	-
21,602.35  $	-
19,658.10  $	-
14,029.40  $	-
19,681.50  $	-
24,547.60  $	-
18,283.65  $	-
88.55  $	-
13,576.20  $	-
131,920.00	-

180,125.00  $	-

Pipeline Constructors, Inc.	Billing No.	2	
Shadow Crest at Rolling Hills	Date:	3/30/2022	
Schedule of Values	Thru Date:	3/30/2022	
Total Seeding/Mulching	180,125.00	-	-	-	-		180,125.00	-	
Bond	
Bond	124,000.00	$	124,000.00	$	-		$	124,000.00	100%	$	-	$	6,200.00	
Total Bond	124,000.00	124,000.00	-	-	124,000.00		-	6,200.00	
ODP and Sales Tax Credit	
Sales Tax Credit	(142,185.00)		$	(4,362.47)		$	(4,362.47)	3%	$	(137,822.53)	$	(218.12)	
March 2022 - ODP Payments	(70,207.80)		$	(70,207.80)		$	(70,207.80)	100%	$	-	$	(3,510.39)	
Total Bond	(212,392.80)	-	(74,570.27)		(74,570.27)		(137,822.53)	(3,728.51)	
TOTAL	$	7,987,245.20	$ 308,299.60	$	358,299.58	$  70,207.80	$	736,806.98		$	7,250,438.22	$	36,840.35	

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):

Requisition Number: 005
Name of Payee: Fortline, Inc.

Amount Payable: $70,207.80
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Three (3) invoices 5608584, 5608621, and 5625944 for Sch. 40 PVC conduit and HP storm pipes.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
IKI  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;

OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that hasnotpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

C-1

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:

 . DL
Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

Alliant Engineering, Inc. Joseph R. Schofield, P.E.
Dlgilally signed byJoseph Scholleld
Reason: I am approving this
document
Date: 2022.04.04 15:47:15-04'00'

Consulting Engineer

C-2

F08J}	(•)

INVOICE	INVOICE NUMBER: BILL OF LADING: INVOICE DATE:

5608584
46769288.001
3/21/22

a MORSCO company
7025 Northwinds Dr. NW
Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

 DUE DATE:	4/17/22	
Please Remit Payment To:
Fortiline, Inc.
PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD
475 WTOWN PL STE 114
ST AUGUSTINE FL 32092-3649

ROLLING HILLS COD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

l440CONDUIT20

4"X20' SCH40 PVC CONDUIT
1BID LINE#00110

FT	1260

1260	0

11.5500

14,553.00

Project Name
 Shadow Crest at Rolling Hills	 l;zjAPPROVED	O REJECTED
DREVISE	D NOT REVIEWED

BY Marney Best Project Manager
'--J)1c"11Ur&,1, r»i

DATE 311212022

·•	,P!I!N.C!.;.,.!!.

FORTILINE offers online payments and access to invoice copies for your convenience at http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT htlp:I/FORTILINE.8/LLTRUSLCOM

011/i11e Pavme11ts  View a11d Download !11voices a11d Statements

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http://www.fortiline.com

14,553.00
$0.00
$0.00
$0.00
$14,553.00

FO J}k!!'J (•)

INVOICE	INVOICE NUMBER: BILL OF LADING: INVOICE DATE:

5608621
20249512
3/30/22

a MORSCO company
7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

 DUE DATE:	4/28/22	
Please Remit Payment To: Fortiline, Inc.
PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS CDD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL
32092

ROLLING HILLS COD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

l36N12HP	136" N12 HP PIPE IB BID LINE# 00450

l24N12HP	24" N12 HP PIPE 18
BID LINE# 00470

I FT I  620	I  240  I  380  I	64.63001	15,511.20
I	FT I	1680 I	240 I	1440 I	36.39001	8,733.60

15N12HP

15" N12 HP PIPE 18

□NOT REVIEWED
DATE
3.30.22

□REJECTED

Project Name

 Shadow Crest at RollilJ.9H. ills	

BID LINE# 00490

I	FT I

420  I

240  I

180  I

17.06001

4,094.40

[2I APPROVED

□REVISE

BY Marney Best Project Manager
L /)'/(11/li.t,r/},(d, /?,)

41  ,P!!.'-.l!!

INC.

FORTILINE offers online payments and access to invoice copies for your convenience at http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE  ACCOUNT  AT http:I/FORTILINE.8/LLTRUST.COM
011/i11e Payments View, and Download hivoices and Statements

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http://www.fortiline.com

128,339.20
$0.00
$0.00
_$_Q.OO
$28,339.20

FDtlJJ!v!!'J (•)
a MORSCO company

INVOICE		INVOICE NUMBER: BILL OF LADING: INVOICE DATE: DUE DATE:

5625944
20249527
3/30/22
4/28/22

7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
Federal Tax ID# 57-0819190

Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL 32092

ROLLING HILLS COD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

l36N12HP

124N12HP

36" N12 HP PIPE IB BID LINE# 00450

	FT	380	
	
FT	
1440	
	
FT	
180	
	
Project Name

Shadow Crest at Rollin.9. Hills	
G2JAPPROVED	□REJECTED
□REVISE	□NOT REVIEWED
BY Marney Best	DATE Project Manager
'-/))(11111,lj &d, {'Iii	3.30.22	
	,....••	, -IN-C.'-'- !	

24" N12 HP PIPE IB BID LINE# 00470

240

240

140

1200

64.6300

36.3900

15,511.20

8,733.60

15N12HP	115" N12 HP PIPE IB BID LINE# 00490

180	0

17.06001

3,070.80

FORTILINE offers online payments and access to invoice copies for your convenience at http://Fo1tiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT http://FORTILINE.8/LLTRUST.COM

Online Pav111e111s  View and Download Invoices and Sra1e111e11ts

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION.  AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http://www.fortiline.com

TO VIEW AND PAY ONLINE:	Fortiline.com	I USE THIS ENROLLMENT TOKEN: I	RXZXTHWKL

i27,315.60
$0.00
$0.00
$0.00
$27,315.60

Page 1 of 1

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 006

Name of Payee: Kutak Rock LLP

Amount Payable: $1,480.00
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Invoice 3024476 for legal services.

Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
IKI  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;

OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has not previously been paid out of such Account.

The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: -¥-'-1M"""OAA. L Y\=--L="--------
A'uthorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

Alliant Engineering, Inc. Joseph R. Schofield, P.E.

Digitally signed by Joseph Schofield
Reason: I am approving thls document
Date: 2022.04.04
	16:02:42-04'00'	
Consulting Engineer

KUTAK  ROCK  LLP
TALLAHASSEE, FLORIDA
Telephone 404-222-4600
Facsimile 404-222-4654

Federal ID 47-0597598

March 24, 2022

Check Remit To: Kutak Rock LLP POBox30057
Omaha, NE 68103-1157

Wire Transfer Remit To:
ABA #104000016
First National Bank of Omaha
Kutak Rock LLP
NC#  24690470
Reference: Invoice No. 3024476 Client Matter No. 17523-4

Marilee Giles Rolling Hills CDD
Governmental Management Services - Suite 114
475 West Town Place St. Augustine, FL 32092

St. Augustine

Invoice No. 3024476
17523-4

Re:	2022 Construction
For Professional Legal Services Rendered

02/09/22	K. Buchanan	0.50	152.50	Confer with Henderson and Blunck	
02/10/22	M. Rigoni	0.60	150.00	Finalize	temporary	construction	

02/15/22	M. Rigoni

0.20

50.00

easement agreement; draft notice of commencement
Correspondence	with	Henderson

	regarding easement finalization	
02/21/22	K. Buchanan	0.70	213.50	Review revised EJCDC agreement	

02/21/22	
J. Gillis	
0.30	
42.00	for Phase 3B/3C
Confer with staff regarding EJCDC	

02/21/22	
M. Rigoni	
0.20	
50.00	agreement for Shadow Crest
Confer with Buchanan and Gillis	
				regarding construction contract	
02/22/22	J. Gillis	0.60	84.00	Coordinate recording of performance and payment bond and temporary	
				construction  and access  easement	
agreement for Garden Street Phase 3B and 3C; confer with staff regarding contractor's bid and research regarding same

KUTAK ROCK LLP
Rolling Hills CDD March 24, 2022
Client Matter No. 17523-4 Invoice No. 3024476
Page 2

02/22/22

02/23/22

M. Rigoni

J. Gillis

1.20	300.00

0.40	56.00

Review		executed	agreement, performance and payment bonds, contractor's		bid		and		 insurance certificate and correspondence with Gillis and Giles regarding same Confer	with	staff		regarding

				construction contract documents for
Shadow Crest; review and compile same	
02/23/22	M. Rigoni	0.20	50.00	Confer with Gillis and Buchanan
regarding performance and payment	

02/24/22	
J. Gillis	
0.40	
56.00	bonds
Follow-up on recorded performance	
				and payment bonds and easement	
				agreement;	confer	with	staff	

02/27/22

M. Rigoni

0.40	100.00

regarding same
Review recorded performance and payment bonds; finalize notice of commencement; correspond with Blunk, Henderson and Schillinger regarding same

TOTAL HOURS	5.70

TOTAL FOR SERVICES RENDERED

DISBURSEMENTS		$1,304.00	
Filing and Court Fees	176.00		
TOTAL DISBURSEMENTS		176.00	
TOTAL CURRENT AMOUNT DUE		$1,480.00	

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 007
Name of Payee: Fortline, Inc.
Amount Payable: $83,559.20
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Four (4) invoices 5630418, 5630419, 5631297, and 5631298 for 18" and 42" HP storm pipes.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
1KJ  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has not previously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.
ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By: M.c.,µ,o ·_..\,	-- Authorized Officer

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

Alliant Engineering, Inc. Joseph R. Schofield, P.E.

DlgilaHy sigmld by Joseph Scho1ield Reason: I am approving this document
Date: 202204.05 08:35:48-04'00'

Consulting Engineer

FORTILINE
WATERWORKS
a MORSCO company

7025 Northwinds Dr. NW
Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

INVOICE	INVOICE NUMBER: 5630418 BILL OF LADING:	20254718 INVOICE DATE:	 3/31/22
 DUE DATE:	4/30/22	
Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254

SHIP TO

Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL
.

ROLLING HILLS CDD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

32092

Projoo1H,m•
Shadow Crest at Rolllng Hills

0 I/OT REVIOWSP

l!Y l.l moy eesl Project f,1aMg•r
'-J>io,ot,_rd:Y,1>,.

DATE
41212012

-	•

..	•	•

014	5607323	227261	NET 30 DAYS

200

FORTILINE offers online payments and access to invoice copies for your
convenience  at  http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT  http://FORTfLfNE.BILLTRUSTCOM
Online Payments View and Download Invoices and Statements.

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. All CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http:/fwww.fortillne.com

AMOUNT DUE
TAX FREIGHT OTHER TOTAL DUE

16 602.00
$0.00
$0.00
$0.00
$16,602.00

FORTILINE
WATERWORKS

INVOICE	INVOICE NUMBER: BILL OF LADING: INVOICE DATE:

5630419
20254743
3/31/22

a MORSCO company
7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

 DUE DATE:	4/30/22	
Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL 32092

ROLLING HILLS CDD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

42N12HP

42" N12 HP PIPE IB BID LINE# 00440

FT	280

200	80

83.0100

16,602.00

Project Name

 Shadow Crest at Rolling Hills	

G2j APPROVED
□REVISE
BY Marney Best Project Manager
'--Jlit.uu. ,rdtd, 1-'lii

□REJECTED
□NOT REVIEWED
DATE
4/2/2022

PIPELINE

REGISTER TO ACCESS YOVR ONLINE ACCOUNT AT http://FORT/L/NE.8/LLTRUST.COM
Online Payments View and Download Invoices and Statements.

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE F!LED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http://www.fortiline.com

AMOUNT DUE TAX
FREIGHT OTHER TOTAL DUE

16 602.00
$0.00
$0.00
$0.00
$16,602.00

FORTILINE

INVOICE	INVOICE NUMBER: 5631297 BILL OF LADING:	20256624

WATERWORKS
a MORSCO company

INVOICE DATE: DUE DATE:

3/31/22
4/30/22

7025 Northwinds Dr. NW
Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
Federal Tax ID# 57-0819190

Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLUNG HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL
32092

....

ROLLING HILLS CDD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961

.	..

CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043
•	•

5631297	Direct	227261	NET 30 DAYS

18N12HP

18" N12 HP PIPE IB BID LINE# 00480

FT	1120

22.4800

25,177.60

Project Name

 Shadow Crest at Rolling Hills	

G2l APPROVED
D REVISE
BY Marney Best Project Manager
-!)i,-1,,nLij f:1/.d, /'1,,

□NOT REVIEWED
DATE
4/212022

0 REJECTED

FORTILINE offers online payments and access to invoice copies for your
convenience  at  http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOVR ONLINE ACCOUNT AT  http:I/FORT/L/NE.8/LLTRUST.COM
Online Payments View and Download Invoices and Statements.

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http:f/www.fortiline.com

AMOUNT DUE
TAX FREIGHT OTHER TOTAL DUE

25 177.60
$0.00
$0.00
$0.00
$25,177.60

TO VIEW AND PAY ONLINE:	Fortlline.com	IUSE THIS ENROLLMENTTOKEN: I	RXZXTHWKL	Page 1 of 1

FORTILINE
WATERWORKS

INVOICE	INVOICE NUMBER: BILL OF LADING: INVOICE DATE:

5631298
20256825
3/31/22

a MORSCO company
7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

 DUE DATE:	4/30/22	
Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL 32092

•

ROLLING HILLS COD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961

..

CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043
•	•

5607323	Direct	227261	NET 30 DAYS

18N12HP

18" N12 HP PIPE IB BID LINE# 00480

FT	1120	60

22.4800

25,177.60

Project Name

 Shadow Crest at Rolling Hills	

G2i APPROVED
□REVISE
BY Marney Best Project Manager
1-'J}Jaai/..y-·did, ('Ij I

□REJECTED
□NOT REVIEWED
DATE
4/2/2022

PIPELINE

■11\llfC_ .-
FORTILINE offers online payments and access to invoice copies for your
convenience  at  http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT  http://FORTJL/NE.BILLTRUST.COM
Online Pavments View and Download Jm>oices and Statements.

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. All CLAIMS MUST BE FILED WITH THE CARRIER.
For TERMS and CONDITIONS of sale, please visit http://www.fortiline.com

AMOUNT DUE TAX
FREIGHT OTHER TOTAL DUE

25 177.60
$0.00
$0.00
$0.00
$25,177.60

TO VIEW AND PAY ONLINE:	Fortiline.com	I USE THIS ENROLLMENTTOKEN, I	RXZXTHWKL	Page 1 of 1

FORM OF REQUISITION FOR SERIES 2022 PROJECT
The undersigned, an Authorized Officer of Rolling Hills Community Development District (the "District") hereby submits the following requisition for disbursement under and pursuant to the terms of the Master Trust Indenture from the District to U.S. Bank Trust Company, National Association, Orlando, Florida, as trustee (the "Trustee"), dated as of November 1, 2006 (the "Master Indenture"), as supplemented by the Sixth Supplemental Trust Indenture from the District to the Trustee, dated as of February 1, 2022 (the "Supplemental Indenture" and together with the Master Indenture, the "Indenture") (all capitalized terms used herein shall have the meaning ascribed to such term in the Indenture):
Requisition Number: 008
Name of Payee: Fortline, Inc.
Amount Payable: $43,668.00
Purpose for which paid or incurred (refer also to specific contract if amount is due and payable pursuant to a contract involving progress payments or state Costs of Issuance, if applicable): Two (2) invoices 5633739 and 5633459 for 24" HP storm pipe.
Fund or Account and subaccount, if any, from which disbursement to be made: Series 2022 bonds.
The undersigned hereby certifies that:
!Kl  obligations in the stated amount set forth above have been incurred by the District, that each disbursement set forth above is a proper charge against the Series 2022 Acquisition and Construction Account referenced above, that each disbursement set forth above was incurred in connection with the acquisition and/or construction of the Series 2022 Project and each represents a Cost of the Series 2022 Project, and has not previously been paid out of such Account;
OR
D  this requisition is for costs of issuance payable from the Series 2022 Costs of Issuance Account that has notpreviously been paid out of such Account.
The undersigned hereby further certifies that there has not been filed with or served upon the District notice of any lien, right to lien, or attachment upon, or claim affecting the right to receive payment of, any of the moneys payable to the Payee set forth above, which has not been released or will not be released simultaneously with the payment hereof.

The undersigned hereby further certifies that such requisition contains no item representing payment on account of any retained percentage which the District is at the date of such certificate entitled to retain.
Originals or copies of the invoice(s) from the vendor of the property acquired or services rendered with respect to which disbursement is hereby requested are on file with the District.

ROLLING HILLS COMMUNITY DEVELOPMENT DISTRICT

By:	""	\
Au	orized Ofucer	J-.-­

CONSULTING ENGINEER'S APPROVAL FOR NON-COST OF ISSUANCE REQUESTS ONLY
If this requisition is for a disbursement from other than the Series 2022 Costs of Issuance Account, the undersigned Consulting Engineer hereby certifies that this disbursement is for a Cost of the Series 2022 Project and is consistent with (i) the applicable acquisition or construction contract, (ii) the plans and specifications for the portion of the Series 2022 Project with respect to which such disbursement is being made, and (iii) the report of the Consulting Engineer attached as an exhibit to the Supplemental Indenture, as such report shall have been amended or modified on the date hereof.

Alliant Engineering, Inc. Joseph R. Schofield, P.E.
Digitally$igned byJos.,phSchofield Au son:1am approving thisdocument Date: 202204.1210:05:56-04'00

Consulting Engineer

FD JJ.k! !;(•)

INVOICE	INVOICE NUMBER: BILL OF LADING: INVOICE DATE:

5633459
20258788
4/06/22

a MORSCO company
7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

 DUE DATE:	5/05/22	
Please Remit Payment To:
Fortiline, Inc.
PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL 32092

ROLLING HILLS CDD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

24" N12 HP PIPE IB BID LINE# 00470		
	
Project Name

 Shadow Crest at Rollin.9.Hills	
G21APPROVED	0 REJECTED
□REVISE	0 NOT REVIEWED
BY Marney Best	DATE Project Manager
L-r,11:>.•Ni,r&d; hn	April 6, 2022	
	·•	,!:I!N.C'.-.,.!!	

l24N12HP
1

FT	1200

600

600

36.3900

21,834.00

FORTILINE offers online payments and access to invoice copies for your convenience at http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT http://FORT/LINE.8/LLTRUST.COM
011/i11e Pavments View, a11d Dow11/oad Invoices and State111e11ts.

■

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION.  AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.

For TERMS and CONDITIONS of sale, please visit http://wwwfortlline.com
I

i21,834.00
$0.00
$0.0Q
$0.00
$21,834.00

TO VIEW AND PAY ONLINE:	Fortiline.com	USE THIS ENROLLMENT TOKEN:	RXZXTHWKL	Page 1 of 1

FDBJJ!v!!'J (.)
a MORSCO company

INVOICE		INVOICE NUMBER: BILL OF LADING: INVOICE DATE: DUE DATE:

5633739
20260703
4/06/22
5/05/22

7025 Northwinds Dr. NW Concord, NC 28027
Payment Inquiries 704-788-9800

SOLD TO

SHIP TO

Please Remit Payment To:
Fortiline, Inc. PO Box 744053
Atlanta, GA 30384-4053
 Federal Tax ID# 57-0819190	
Warehouse:
FORTILINE JACKSONVILLE 6982 HIGHWAY AVE.
JACKSONVILLE, FL 32254
Telephone: 904-652-0962

ROLLING HILLS COD 475 WEST TOWN PL SUITE 114
ST AUGUSTINE, FL 32092

ROLLING HILLS COD
3212 BRADLEY CREEK PARKWAY RICHARD: 904.408.2961
CHICO: 352.572.3892
GREEN COVE SPRINGS, FL 32043

l24N12HP

24" N12 HP PIPE 18

□NOT REVIEWED
DATE

□REJECTED

Project Name

Shad w Crest at Rolling Hills	

1BID LINE# 00470

FT	600

600	0

36.3900

21,834.00

l;zj APPROVED

□REVISE

BY Ma ney Best ProJect Manager
'-ma""-',r&d, Prl1

·•	.

I!N.C\.

!.!!

FORTILINE offers online payments and access to invoice copies for your convenience at http://Fortiline.Billtrust.com.
REGISTER TO ACCESS YOUR ONLINE ACCOUNT AT http://FORT/L/NE.B/LLTRUST.COM
OnlinePqy111e11ts  View and Dow11/oad Invoices andState111e11ts.

■

.

NO RETURNS ACCEPTED WITHOUT PRIOR AUTHORIZATION. AUTHORIZED RETURNS ARE SUBJECT TO RESTOCKING FEES. SPECIAL ORDER ITEMS ARE NOT RETURNABLE. ALL CLAIMS MUST BE FILED WITH THE CARRIER.

•

For TERMS and CONDITIONS of sale, please visit http-//www.fortiline.com

i21,834.00
$0.00
$0.00
$0.00
$21,834.00

April 6, 2022

	TO VIEW AND PAY ONLINE:	Fortiline.com	I USE  THIS ENROLLMENT TOKEN: I	RXZXTHWKL	Page 1 of 1

C.

Work Authorization

April 12, 2022

Board of Supervisors
Rolling Hills Community Development District 475 West Town Place, Suite 114
St. Augustine, Florida 32092

Subject:	Work Authorization Number 1
Rolling Hills Community Development District

Dear Chairperson, Board of Supervisors:

Alliant Engineering, Inc. (the “Engineer”) is pleased to submit this work authorization to provide engineering services for the Rolling Hills Community Development District (the “District”). We will provide these services pursuant to our current agreement dated June 8, 2021 (the “Engineering Agreement”) as follows:

Scope of Work
The Engineer will act as Purchasing Agent for the District with respect to the direct purchase of construction materials for the District’s Improvements located in District projects known as Phases 3B and 3C, in accordance with the procurement procedures adopted by the Board of Supervisors.

Compensation
The Engineer will be compensated for this work at the hourly rates established pursuant to the Engineering Agreement.

Other Direct Costs
Other direct costs include items such as printing, drawings, travel, deliveries, et cetera, pursuant to the Engineering Agreement.

Engineer hereby represents it understands and will abide by all terms of the District’s Procurement Procedures for Direct Purchase Materials. In preparing and executing any documentation for purposes of ordering or purchasing materials in the name of and on behalf of the District, the Engineer will affirm that the vendor supplying the Direct Purchase Materials is not also the installer of the Direct Purchase Materials, and further will affirm that the installer of the Direct Purchase Materials did not manufacture, fabricate or furnish the Direct Purchase Materials.

This work authorization, together with the Engineering Agreement, represents the entire understanding between the District and the Engineer with regard to the referenced services and supersedes any previously executed proposal or agreement related to the provision of such services. If you wish to accept this work authorization, please sign where indicated and return to our office. Upon receipt, we will promptly schedule our service.

Sincerely,

By: 	
Its:	

APPROVED AND ACCEPTED

Authorized Representative of
Rolling Hills Community Development District Date: 	

TENTH ORDER OF BUSINESS

AGREEMENT BETWEEN OWNER AND CONTRACTOR FOR CONSTRUCTION CONTRACT (STIPULATED PRICE)

SHADOW CREST AT ROLLING HILLS
This Agreement is by and between the Rolling Hills Community Development District ("Owner") and Pipeline Constructors, Inc. ("Contractor'').
Terms used in this Agreement have the meanings stated in the General Conditions and the Supplementary Conditions.
Owner and Contractor hereby agree as follows:

ARTICLE 1-WORK

1.01  Contractor shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: All labor, materials, equipment, services, and documentation necessary to construct the Project defined herein. The Work may include related services such as testing, start-up, and commissioning, all as required by the Contract Documents

ARTICLE 2-THE PROJECT

2.01  The Project, of which the Work under the Contract Documents is a part, is generally described as follows: Phase 3B and 3C of the Rolling Hills CDD, also known as Shadow Crest at Rolling Hills. Project includes all site development work within the project site, with the completion resulting in 247 finished lots.

ARTICLE 3-ENGINEER

The Owner has retained Alliant Engineering, Inc. located at 10475 Fortune Parkway, Suite 101, Jacksonville, FL 32256 ("Engineer'') to act as Owner's representative, assume all duties and responsibilities of Engineer, and have the rights and authority assigned to Engineer in the Contract.
The part of the Project that pertains to the Work has been designed by Engineer.

ARTICLE 4-CONTRACT TIMES

Time is of the Essence
All time limits for Milestones, if any, Substantial Completion, and completion and readiness for final payment as stated in the Contract Documents are of the essence of the Contract. The Work to be performed under this Agreement shall be commenced no later than ten (10) calendar days, including Saturdays, Sundays, and holidays, from the date of the Notice to Proceed.
CeRt.<act Times: Qetes
/\. nie  \IVork will 13e  s bstaRtially comf)lete OR  or  13efare		aREI comf)leteEI aREI reaEly far  fiRal JJaymeRt iR accorElaRce ,..,.itR  flaragraf)R 1§.06 of tRe GeReral CoRElitioRs OR  or  13efare

EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Contract Times: Days
The Work will be substantially complete within 335 days after the date when the Contract Times commence to run as provided in Paragraph 4.01 of the General Conditions, and completed and ready for final payment in accordance with Paragraph 15.06 of the General Conditions within 365 days after the date when the Contract Times commence to run.
Mi.'estones
Parts of the \/.'ark must Ile substantially Eom13leteEI on or before the following Milestone(s):
Milestone 1 (e\"BRt & date/da•ttS)
Milestone 2 (e,,eAt & date/da•1s)
Milestone 3 (e•,eRt & date/days)
Liquidated Damages
Contractor and Owner recognize thattime is of the essence as stated in Paragraph 4.01above and that Owner will suffer financial and other losses if the Work is not completed aRd Milestones not aEhie •eEI within the Contract Times, as duly modified. The parties also recognize the delays, expense, and difficulties involved in proving, in a legal or arbitration proceeding, the actual loss suffered by Owner if the Work is not completed on time. The Owner and Contractor agree that an assessment of actual damages as of the date of this Agreement would be uncertain, and the amount of liquidated damages set forth herein is reasonable. Accordingly, instead of requiring any such proof of actual damages, Owner and Contractor agree that as liquidated damages for delay {but not as a penalty):
l.  Substantial Completion: Contractor shall pay Owner $1,000 for each day that expires after the time (as duly adjusted pursuant to the Contract) specified above for Substantial Completion, until the Work is substantially complete.
Completion of Remaining Work: After Substantial Completion, if Contractor shall neglect, refuse, or fail to complete the remaining Work within the Contract Times (as duly adjusted pursuant to the Contract) for completion and readiness for final payment, Contractor shall pay Owner $1,000 for each day that expires after such time until the Work is completed and ready for final payment.
Milestones: ContraEtor shall 13ay  O•,,mer Slnumllerl for eaEh Elay that ei(13ires after the time (as Eiuly aajustea i:iursuant to the ContraEt) s13eEifieEi  allo•,•e for aEhievement of Milestone 1, until Milestone 1 is aEhieveEI, or until the time s13eEifieEi  for  Substantial Com13letion is reaEhea, at whiEh time the rate inEliEatea in Paragrai:ih 4.0§./1.1 will a1313ly, rather than the Milestone rate.
Liquidated damages for failing to timely attain Milestones, Substantial Completion, and final completion are not additive; and will not be imposed concurrently.
If Owner reE0•1ers liquiEiatea Elamages for a Elelay in Eomi:iletion lly ContraEtor, then SUER liquiElatea Elamages are Owner's sole ana ei(dusi •e remeEiy for suEh Elelay, anEI Owner is i:ireEluaeEI  from reEo •ering any other Elamages, whether aEtual, ElireEt, el(Eess,  or eonsequential, for suEh Elelay, exEe13t for  s13eEial Elamages (if any) s13eEifiea in this Agreement.
BoRIJ5: ContraEtor ana Owner further reEognize the Owner will realize finanEial anEI other benefits if the Work is eom13leteEI i:irior to the time s13eEifieEI  for  Substantial Com13letion.

EJCOC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

.'\ccaraingl•t, Owner ana Cantractar agree tRat as a llanus for early campletian, Owner sRall pa',' Cantraetar $En11mller) far  eacR aay prier ta tRe time specifiea allave far Sullstantial Campletian (as auly aajustea pursuant ta tRe Cantract) tRat tRe '.Vari< is sullstantially camplete. TRe maiEimum value af tRe Ila nus will Ile limitea ta Sln11mberj.
Qe SfJeciai 9amal:Jes
Cantractar sRall reimllurse Owner (1) far any fines er penalties impasea an Owner as a airect result af tRe Cantraetar's failure ta attain Sullstantial Campletian acceraing ta tRe Cantract Times, ana (2) far tRe aetual easts reasanallly incurrea lly Owner far engineering, canstructian allservatian, inspectian, ana aaministrative services neeaea after tRe time specifiea in ParagrapR 4.02 far Sullstantial Campletian (as auly aajusted pursuant ta tRe Cantract), until tRe Wark is sullstantially camplete.
ll. After Cantractar acRieves Sullstantial Campletian, if Cantractar sRall neglect, refuse, er fail ta cemplete tRe remaining '#arl( witRin tRe Cantract Times, Cantractar sRall reimllurse Owner far tRe actual casts reasanallly incurrea ily Owner far engineering, canstruetian ellservatian, inspectian, ana aaministrative services neeaea after tRe time specifiea in ParagrapR 4.02 far Wark ta ile campletea ana reaay far final pa•,ment (as auly aajustea pursuant ta tRe Cantract), until tRe Werk is campleted ana reaay far final payment.
C. TRe special aamages impasea in tRis paragrapR are supplemental ta any lieiuidatea aamages far aelayea campletian estaillisRea in tRis Agreement.

ARTICLE 5-CONTRACT PRICE

Owner shall pay Contractor for completion of the Work in accordance with the Contract Documents, the amounts that follow, subject to adjustment under the Contract:
For all Work other than Unit Price Work, a lump sum of$ 8,057,453.00.
All specific cash allowances are included in the above price in accordance with
Paragraph 13.02 of the General Conditions. See Section 3, C. Special Conditions, 2. Export of excess dirt from the site for explanation on how the sale of excess dirt has been credited against the contract amount.
For all Unit Price Work, an amount equal to the sum of the extended prices (established for each separately identified item of Unit Price Work by multiplying the unit price times the actual quantity of that item).

Unit Price Work	
Item
No.	
Description	
Unit	Estimated Quantity	Unit Price	Extended Price	
1	Underdrain system at roads	LF	15,300	$	32.00	$  489,600	
2	Cleanouts for underdrain	EA	150	$ 520.00	$	78,000	

3	Furnish and install 8-inch base In lieu of 6-inch base under
roads	
LS	
1	
$ 76,798	
$	76,798	

EJCDC®-C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price), Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

Item No.	
Description	Unit Price Work	I
Unit	lEstimated	Unit
Quantity	Price	Extended Price	
Total of all Extended Prices for Unit Price Work (subject to final adjustment based on actual quantities)	$ 644,398	

The eiiteREleEl priees fer Unit Priee Werk set fertlci as sf the 1'ffeetive Elate sf the Cantraet are IJases en estimates f!Uantities. As pravises in Paragraph B.Q3 sf the General Censitians, estimates f!Uantities are net guarantees, ans seterminatians of aetual f!Uantities ans elassifieations are to Ile mase IJy 1'ngineer.
Total sf bump Sum /\mount ans Unit Priee Work {sulJjeet to final Unit Priee asjustment)
$1nurnl!erj.
For all Work, including additions or changes to the Work. payment shall be made in accordance with at-the prices stated in Contractor's Bid, attached hereto as an exhibit. Unit Pricing. as shown in the Contractor's Bid attached hereto. shall only be used in connection with pricing for change orders.

ARTICLE 6-PAYMENT PROCEDURES

Submittal and Processing of Payments
Contractor shall submit Applications for Payment in accordance with Article 15 of the General Conditions. Applications for Payment will be processed by Engineer as provided in the General Conditions.
Progress Payments; Retainage
Owner shall make progress payments on the basis of Contractor's Applications for Payment in a manner consistent with the Local Government Prompt Payment Act. sections 218.70 through 218.80 of the Florida Statutes. on or alJout the lonlinal n11rnl!er, s11eh  as §th! say sf eaeh menth suring perforrnanee of the Worn as provises in Paragraph 6.Q2..'\.l IJelov,·, pre\·ises that sueh l'.pplieations fer Pa·tment have Ileen sulJmitted in a timely manner ans otherwise meet the reEjuirements of the Contraet. All such payments will be measured by the Schedule of Values established as provided in the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no Schedule of Values, as provided elsewhere in the Contract. Five percent (5%) of the amount of each progress payment shall be withheld as retainage until final completion of the Work. acceptance of the Work by the Owner, satisfaction of all punch list requirements. and submission of all documents required under Paragraph 15.06 of the General Conditions. subject to any offsets to which the Owner is entitled. Procedures for withholding and release of retainage shall be in accordance with Florida law. including sections 218.735 and 255.078, Florida Statutes.
Prior to SulJstantial Cempletien, progress payments will Ile mase in an amount eeiual to the pereentage insieates IJelow IJut, in eaeh ease, less the aggregate sf payments previeusly mase ans less sueh amounts as Owner may 'h'ithhols, inelusing IJut not limitea to liEjuiaatea samages, in aeeorsanee with the Contraet.

EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price).

(AYFRheFJ  13eFEeRt  af  the  vahie af the Wark €8FRl3leteEI  (•,•,•ith  the  llalaREe lleiRg retaiRage).
If §0 13erEeRt  SF  FRSFe  af  the  Wark has lleeR €9FRflleteEI, as EleterFRiReEI lly ERgiReer, aREI if  the  EharaEter aREI 13ragress af the Wark ha •e lleeR satisfaEtary ta Q•1mer aREI  ERgiReer, theR as laRg as the EharaEter aREI 13ragress af the Wark reFRaiR satisfaEtary ta GwRer aREI ERgiReer, there will Ile Ra aEIElitiaRal retaiRage; 300
Ii. (AYFRheFJ 13erEeRt af  €9St af FRaterials aREI equi13FReRt Rat iRE9Ffl9FateEI iR the  V\fark (with the llalaREe lleiRg retaiAage).
Y13aA  SullstaAtial GaFR13letiaR,  GwAer shall 13ay  aR aFRauRt suffiEieAt ta iRErease tatal 13a','FReRts ta  CaAtraEtar ta (AYFRheFJ 13erEeAt af the  Wark EBFR13leteEI,  less such aFRauAts set aff B',' QwAeF flUFSU3Rt ta  llaragra13h 1§.01.E af the GeReral GaAElitiSAS, aREI less (AYFRherJ 13erEeAt af EAgiAeer's estiFRate af the value af 'Nari( ta Ile EBFR13leteEI  er  EarreEteEI as sha',YR BR the  flURCh list af iteFRS ta  Ile  69FRflleteEI SF EBrrecteEI 13fi8F ta fiAal 13ayFReAt.
Final Payment
Upon final completion and acceptance of the Work, in accordance with Paragraph 15.06 of the General Conditions, and subject to final acceptance by Clay County and/or the local utility provider, as applicable, Owner shall pay the remainder of the Contract Price as recommended by the Engineer and in accordance with Paragraph 15.06 of the General Conditions.
Consent of Surety
Owner will not make final payment, or return or release retainage at Substantial Completion or any other time, unless Contractor submits written consent of the surety to such payment, return, or release.
Interest
All payments due and not made within the time prescribed by Section 218.735, Florida Statutes, shall bear interest from thirty (30) days after the due date at the rate of one percent (1%) per month on the unpaid balance in accordance with Section 218.74, Florida Statutes.
/\11 aFRauRts Rat 13aiEI  wheA Elue •,•,•ill bear iRterest at the rate af (AYFRheFj 13erceRt 13er aARUFR.

ARTICLE 7-CONTRACT DOCUMENTS

Contents
The Contract Documents consist of all of the following:
This Agreement as modified herein.
Bonds:
Performance bond (together with power of attorney).
Payment bond (together with power of attorney).
Biel llaAEI (tagether with 11a·11er  af  attaFReyl
General Conditions as modified therein.

EJCDC® C S20, Agreement between Owner and Contractor for Construction Contract (Stipulated Price).

Supplementary Conditions Relating to Insurance Requirements. Subsurface Conditions. and Hazardous Conditions.
Project Manual. including but not limited to Specifications as listed in the table of contents of the Project Manual (copy of list attached). See Drawings
G.  DFaWiAgs (Rat attadiea Slit iAEBF BFatea 13y  FefeFeAEe) EBASistiAg af (RLIFAlleFI  slieets 'A'itR eaER slieet 13eaFiAg tlie fallawiAg geAeFal title: !title 8R DFa'NiRgsJ.
Drawings listed on the attached sheet index. (Section V)
Contract Addenda - N/ A
Exhibits to this Agreement (enumerated as follows):
Contractor's Bid (Exhibit A)
Geotech Reports (Section IV)
C.	TeERAiEal S13eEifirntiaAS 13age	tRFOLlflR	, iAEIYsi•,•e
The following which may be delivered or issued on or after the Effective Date of the Contract and are not attached hereto:
Notice to Proceed.
Work Change Directives.
C. Change Orders.
Field Orders.
Warranty Bond, if any.
The Contract Documents listed in Paragraph 7.01.A are attached to this Agreement (except as expressly noted otherwise above).
There are no Contract Documents other than those listed above in this Article 7.
The Contract Documents may only be amended, modified, or supplemented as provided in the Contract.

ARTICLE 8-REPRESENTATIONS, CERTIFICATIONS, AND STIPULATIONS

Contractor's Representotions
In order to induce Owner to enter into this Contract, Contractor makes the following representations:
Contractor has examined and carefully studied the Contract Documents, including Addenda -
Contractor has visited the Site, conducted a thorough visual examination of the Site and adjacent areas, and become familiar with the general, local, and Site conditions that may affect cost, progress, and performance of the Work.
Contractor is familiar with all Laws and Regulations that may affect cost, progress, and performance of the Work.

Contractor has carefully studied the reports of explorations and tests of subsurface conditions at or adjacent to the Site and the drawings of physical conditions relating to existing surface or subsurface structures at the Site that have been identified in the Supplementary Conditions, with respect to the Technical Data in such reports and drawings.
Contractor has carefully studied the reports and drawings relating to Hazardous Environmental Conditions, if any, at or adjacent to the Site that have been identified in the Supplementary Conditions, with respect to Technical Data in such reports and drawings.
Contractor has considered the information known to Contractor itself; information commonly known to contractors doing business in the locality of the Site; information and observations obtained from visits to the Site; the Contract Documents; and the Technical Data identified in the Supplementary Conditions or by definition, with respect to the effect of such information, observations, and Technical Data on (a) the cost, progress, and performance of the Work; (b) the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor; and (c) Contractor's safety precautions and programs.
Based on the information and observations referred to in the preceding paragraph, Contractor agrees that no further examinations, investigations, explorations, tests, studies, or data are necessary for the performance of the Work at the Contract Price, within the Contract Times, and in accordance with the other terms and conditions of the Contract.
Contractor is aware of the general nature of work to be performed by Owner and others at the Site that relates to the Work as indicated in the Contract Documents.
Contractor has given Engineer written notice of all conflicts, errors, ambiguities, or discrepancies that Contractor has discovered in the Contract Documents, and of discrepancies between Site conditions and the Contract Documents, and the written resolution thereof by Engineer is acceptable to Contractor.
The Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work.
Contractor's entry into this Contract constitutes an incontrovertible representation by Contractor that without exception all prices in the Agreement are premised upon performing and furnishing the Work required by the Contract Documents.
Contractor is financially solvent. able to pay its debts as they mature and possesses sufficient working capital (subject to payments by Owner required under this Agreement) to complete the Work required to be performed of it under this Contract.
Contractor is able to furnish (directly or by subcontract or through vendors) any plant. tools. materials. supplies. equipment and labor necessary to complete the services required of Contractor under this Contract and Contractor has sufficient experience and competence to perform the Work under the Contract.
Contractor is authorized to do business in the State of Florida and is properly licensed (to the extent required by law) by all necessary governmental authorities having jurisdiction over the Work.

Contractor's Certifications
Contractor certifies that it has not engaged in corrupt, fraudulent, collusive, or coercive practices in competing for or in executing the Contract. For the purposes of this Paragraph 8.02:
"corrupt practice" means the offering, giving, receiving, or soliciting of anything of value likely to influence the action of a public official in the bidding process or in the Contract execution;
"fraudulent practice" means an intentional misrepresentation of facts made (a) to influence the bidding process or the execution of the Contract to the detriment of Owner,
(b) to establish Bid or Contract prices at artificial non-competitive levels, or (c) to deprive Owner of the benefits of free and open competition;
"collusive practice" means a scheme or arrangement between two or more Bidders, with or without the knowledge of Owner, a purpose of which is to establish Bid prices at artificial, non-competitive levels; and
"coercive practice" means harming orthreatening to harm, directly or indirectly, persons or their property to influence their participation in the bidding process or affect the execution of the Contract.
Standard General Conditions
Owner stipulates that if the General Conditions that are made a part of this Contract are EJCDC® C-700, Standard General Conditions for the Construction Contract (2018), published by the Engineers Joint Contract Documents Committee, and if Owner is the party that has furnished said General Conditions, then Owner has plainly shown all modifications to the standard wording of such published document to the Contractor, through a process such as highlighting or "track changes" (redline/strikeout), and/or in the Supplementary Conditions.

ARTICLE 9-MISCELLANEOUS

A. Terms used in the Agreement will have the meanings stated in the General Conditions and the Supplementary Conditions unless otherwise stated herein.
Assignment of Contract
Unless expressly agreed to elsewhere in the Contract. no assignment by a party hereto of any rights under or interests in the Contract will be binding on another party hereto without the written consent of the party sought to be bound; and. specifically but without limitation. money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law). and unless specifically stated to the contrary in any written consent to an assignment. no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents.

EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price}. Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

Successors and Assigns

Owner and Contractor each binds itself, its partners. successors. assigns, and legal representatives to the other party hereto, its partners, successors. assigns. and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents.
Public Records
The Contractor understands and agrees that all documents of any kind provided to the District in connection with this Contract may be public records. and, accordingly. Contractor agrees to comply with all applicable provisions of Florida law in handling such records, including but not limited to Section 119.0701. Florida Statutes. Contractor acknowledges that the designated public records custodian forthe District is Marilee Giles ("Public Records Custodian"). Among other requirements and to the extent applicable by law, the Contractor shall:
keep and maintain public records required by the District to perform the service;
upon request by the Public Records Custodian, provide the District with the requested public records or allow the records to be inspected or copied within a reasonable time period at a cost that does not exceed the cost provided in Chapter 119. Florida Statutes;
	ensure that public records which are exempt or confidential. and exempt from public records disclosure requirements, are not disclosed except as authorized by law for the duration of the contract term and following the contract term if the Contractor does not transfer the records to the Public Records Custodian of the District; and
upon completion of the contract, transfer to the District. at no cost, all public records in Contractor's possession or. alternatively, keep. maintain and meet all applicable requirements for retaining public records pursuant to Florida laws. When such public records are transferred by the Contractor, the Contractor shall destroy any duplicate public records that are exempt or confidential and exempt from public records disclosure requirements. All records stored electronically must be provided to the District in a format that is compatible with Microsoft Word or Adobe PDF formats.
		IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS AGREEMENT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT 47S WEST TOWN PLACE, SUITE 114, ST. AUGUSTINE, FLORIDA 32092, TELEPHONE: (904) 940-5850,
FAX: (904) 940-5899, OR EMAIL: MGILES@GMSNF.COM.
S	Assignment of Warranties
Contractor shall assign to Owner all warranties extended to Contractor by material suppliers and subcontractors. If an assignment of warranty requires the material supplier and/or

EJCDC C S20, Agreement between Owner and Contractor for Construction Contract (Stipulated Price). Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

subcontractor to consent to same. then Contractor shall secure the material supplier's and/or subcontractor's consent to assign said warranties to Owner.
9.06 Construction Defects
A.	CLAIMS FOR  CONSTRUCTION  DEFECTS ARE  NOT SUBJECT  TO THE NOTICE AND CURE PROVISIONS OF CHAPTER 558. FLORIDA STATUTES.
9 .07 Restriction on RemowJ/ of f'.W Dirt from 'Nork Site
		CoRtFactoF aclmowleages t1'lat all s itable seil/fill FRateFial shall FeFRaiR  eR site. Fill FRateFial sl'lall Ret be FeFRevea fFeFR tl'le PFejeet site •...,itl'le t tl'le wFitteA eeRseRt eftl'le OwReF.
Public Entity Crimes
A.  Pursuant to Section 287.133(3)(a). Florida Statutes:
A person or affiliate who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid. proposal. or reply on a contract to provide any goods or services to a public entity; may not submit a bid. proposal. or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids. proposals. or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor. supplier. subcontractor. or consultant under a contract with any public entity; and may not transact business with any public entity in excess of the threshold amount provided ins. 287.017 for CATEGORY TWO for a period of 36 months following the date of being placed on the convicted vendor list.
Contractor represents that in entering into this Contract. the Contractor has not been placed on the convicted vendor list within the last 36 months and. in the event that the Contractor is placed on the convicted vendor list. the Contractor shall immediately notify the Owner whereupon this Contract may be terminated by the Owner.
Scrutinized Companies
Contractor represents that in entering into this Contract. neither it nor any of its officers. directors, executives. partners. shareholders. members. or agents is on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List. created pursuant to Section 215.473. Florida Statutes. and in the event such status changes. Contractor shall immediately notify Owner.
Counterparts; Electronic Signatures
	This Agreement may be executed in any number of counterparts. each of which when executed and delivered shall be an original; however. all such counterparts together shall constitute. but one and the same instrument. Additionally. the parties acknowledge and agree that this Agreement may be executed by electronic signature. which shall be considered as an original signature for all purposes and shall have the same force and effect as an original signature. Without limitation. "electronic signature" shall include faxed versions of an original signature.

EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price)·. Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

electronically scanned and transmitted versions (e.g. via PDF) of an original signature. or signatures created in a digital format.
E-Verify.
The Contractor shall comply with and perform all provisions of Section 448.095, Florido Stotutes. Accordingly, as a condition precedent to entering into this Agreement. Contractor shall register with and use the United States Department of Homeland Security's E-Verify system to verify the work authorization status of all newly hired employees.
If the Contractor anticipates entering into agreements with a subcontractor for the Work. Contractor will not enter into the subcontractor agreement without first receiving an affidavit from the subcontractor regarding compliance with Section 448.095 and stating that the subcontractor has registered with and uses the E-Verify system and does not employ, contract with, or subcontract with an unauthorized alien. Contractor shall maintain a copy of such affidavit for the duration of the agreement and provide a copy to the Owner upon request. Any party may terminate this Agreement or any subcontract hereunder if there is a good faith belief on the part of the terminating party that a contracting party has knowingly violated Section 448.09(1). Florida Statutes. Upon such termination, Contractor shall be liable for any additional costs incurred by Owner as a result of the termination.
In the event that the Owner has a good faith belief that a subcontractor has violated Section 448.095, but the Contractor has otherwise complied with its obligations hereunder, the Owner shall promptly notify the Contractor. The Contractor agrees to immediately terminate the agreement with the subcontractor upon notice from the Owner.
Direct Purchase of Materials
Owner represents to Contractor that Owner is a governmental entity exempt from Florida sales and use tax. and will provide Contractor with a copy of its Consumer Exemption Certificate. Owner may elect to implement a direct purchase arrangement whereby Owner will directly acquire certain materials ("Direct Purchase Materials") necessary for the
completion of the Work directly from the suppliers to take advantage of Owner's tax-exempt status.
Within 10 days of the issuance of the Notice to Proceed or other written authorization for Work. Owner shall provide Contractor with a list of materials that will be treated as Direct Purchase Materials.
Owner shall issue purchase orders directly to suppliers of Direct Purchase Materials. Such purchase orders shall include Owner's consumer certificate of exemption number and shall require that the supplier provide the required shipping and handling insurance and provide for delivery with title and risk of loss transferring upon delivery at the jobsite and after acceptance by Owner. Corresponding change orders shall be executed at the time of the direct purchase to reflect the direct purchases made by the Owner and if the original contract contemplated sale of materials and installation by same person, the change order needs to reflect sale of materials and installation by different legal entities.
Owner shall issue a Certificate of Entitlement to each supplier of Direct Purchase Materials. and furnish a copy of same to the Contractor. Each Certificate of Entitlement must have attached thereto the corresponding purchase order. Each Certificate of Entitlement shall
acknowledge that if the Department of Revenue determines the purchase is not a
	tax-exempt purchase by a governmental entity, then the governmental entity will be
EJCDCII" C-520, Agreement between Owner and Contractor for Construction Contract (Stipul"ated Price)". Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.
Page llof13

responsible for any tax, penalties and interest determined to be due. Each Certificate of Entitlement shall affirm that (1) the attached purchase order is being issued directly to the vendor supplying the tangible personal property the Contractor will use in the identified public works; (2) the vendor's invoice will be issued directly to the governmental entity; (3) payment of the vendor's invoice will be made directly by the governmental entity to the vendor from public funds; (4) the governmental entity will take title to the tangible personal property from the vendor at the time of delivery by the vendor; and (5) the governmental entity assumes the risk of damage or loss at the time of delivery by the vendor.
Upon delivery of the Direct Purchase Materials to the jobsite, the Owner, through Contractor as its agent. shall inspect the materials and invoices to determine that they
conform to the purchase order. If the materials conform. Owner shall accept and take title to the Direct Purchase Materials through its agent, which is Contractor.
Suppliers shall issue invoices directly to Owner. Owner shall process invoices and issue payment directly to the suppliers.
Upon acceptance of Direct Purchase Materials, Owner shall assume risk of loss of same until they are incorporated into the Project. Contractor, as Owner's agent. shall be responsible for safeguarding all Direct Purchase Materials and for obtaining and managing all warranties
and guarantees for all material and products as required under the Contract Documents. All warranties provided by Contractor as part of Contract shall apply to all Direct Purchase Materials, as though Contractor had purchased the Direct Purchase Materials.
[Signatures on following page]

EJCDC® C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated· Price).

IN WITNESS WHEREOF, Owner and Contractor have signed this Agreement.

This Agreement will beeffective on	f c6  1	1 Z.o 'ZL. 

(which is the Effective Date of the Contract).

Owner:	Contractor:

Rolling Hills Community De\l	It District	Pipeline Constructors, Inc.
(typ	(typed or printe

a

By:	By:		

'on)

signature)

;Individual'ssignature)

V

Date:	f e'> L	I	20  '1."L 

Date:		

/,&'	,22>2 2

(dote signed)
Name:	Shannon Jordan
(typed or printed)

Name:

(date signed)
 Ron Denmark	
(typed or printed)

Title:	Chairperson, Board of Supervisors
(typed or printed)

Title:	President

(typed or printed)

Attest:  (Y\		o/\ 
(individual's signature)
Title:	Marilee Giles, District Manager
(typed or printed)
Address for giving notices:
Governmental Management Services, LLC

{If [Type of Entity] is a corporation, a partnership, or a

:ign.)

Title:

Address for givin

Pipeline Constructors, Inc.

475 Town Center Place,.Suite 114	2117 N. Temple Avenue
St. Augustine, Florida, 32092	Starke, Florida, 32092
 	
Designated Representative:	Designated Representative:

Name:	Marilee Giles
(typed or printed}

Name:

Marney Best	
(typed or printed)

Title:

 District Manager	
(typed or printed)

Title:

Senior Project Manager
(typed or printed)

Address:
Governmental Management Services, LLC

Address:
Pipeline Constructors, Inc.	

219 East Livingston Street	2117 N. Temple Avenue
St. Augustine, Florida, 32092	 Stc1_rke_,Florida, 32092

Phone: Email:

(904) 940-5850, Ext. 412
mgiles@gmsnf.com

Phone: Email:

(904) 964-2019

marney@pipelineconstructors.com

(If [Type of Entity] is a corporation, attach evidence of authority to sign. If [Type of Entity] is a public body,

License No.:

 CUC057285	
(where applicable)

attach evidence of authority to sign and resolution or other documents authorizing execution of this Agreement.)

State:

 Florida	

EJCoc<»C-520, Agreement between Owner and Contractor for Construction Contract (Stipulated Price).

STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT
TABLE OF CONTENTS

Page
Article 1-Definitions and Terminology	l 1.01	Defined Terms	l
1.02	Terminology	6
Article 2-Preliminary Matters	7
Delivery of Performance and Payment Bonds; Evidence of Insurance	7
Copies of Documents	8
Before Starting Construction	8
Preconstruction Conference; Designation of Authorized Representatives	8
Acceptance of Schedules	8
Electronic Transmittals	9
Article 3-Contract Documents: Intent, Requirements, Reuse	9
Intent	9
Reference Standards	10
Reporting and Resolving Discrepancies	10
Requirements of the Contract Documents	11
Reuse of Documents	12
Article 4-Commencement and Progress of the Work	12
Commencement of Contract Times; Notice to Proceed	12
Starting the Work	12
Reference Points	12
Progress Schedule	12
Delays in Contractor's Progress	13
Article 5-Site; Subsurface and Physical Conditions; Hazardous Environmental Conditions	15
Availability of Lands	15
Use of Site and Other Areas	15
Subsurface and Physical Conditions	16
Differing Subsurface or Physical Conditions 	18
EJCDC® C-700, Standard General Conditions of the Construction Contract.

Underground Facilities	19
Hazardous Environmental Conditions at Site	21
Article 6-Bonds and Insurance	24
Performance, Payment, and Other Bonds	24
Insurance-General Provisions	25
Contractor's Insurance	26
Builder's Risk and Other Property lnsurance	27
Property Losses; Subrogation	28
Receipt and Application of Property Insurance Proceeds	29
Article 7-Contractor's Responsibilities	30
Contractor's Means and Methods of Construction	30
Supervision and Superintendence	30
Labor; Working Hours	30
Services, Materials, and Equipment.	31
"Or Equals"	31
Substitutes	32
Concerning Subcontractors and Suppliers	34
Patent Fees and Royalties	35
Permits	36
Taxes	36
Laws and Regulations	36
Record Documents	37
Safety and Protection	37
Hazard Communication Programs	38
Emergencies	38
Submittals	38
Contractor's General Warranty and Guarantee	41
lndemnification	42
Delegation of Professional Design Services	43
Article 8-Other Work at the Site	44
Other Work	44
Coordination	45
Legal Relationships	45

Article 9-Owner's Responsibilities	46
Communications to Contractor	46
Replacement of Engineer	47
Furnish Data	47
Pay When Due	47
Lands and Easements; Reports, Tests, and Drawings	47
lnsurance	47
Change Orders	47
Inspections, Tests, and Approvals	47
Limitations on Owner's Responsibilities	47
Undisclosed Hazardous Environmental Condition	47
Evidence of Financial Arrangements	47
Safety Programs	48
Article 10-Engineer's Status During Construction	48
Owner's Representative	48
Visits to Site	48
Resident Project Representative	48
Engineer's Authority	48
Determinations for Unit Price Work	49
Decisions on Requirements of Contract Documents and Acceptability of Work	49
Limitations on Engineer's Authority and Responsibilities	49
Compliance with Safety Program	50
Article 11-Changes to the Contract	50

11.01
11.02
11.03
11.04
11.05
11.06
11.07
11.08
11.09
11.10

Amending and Supplementi ng the Contract	50
Change Orders	50
Work Change Directives	51
Field Orders	51
Owner-Authorized Changes in the Work	51
Unauthorized Changes in the Work	52
Change of Contract Price	52
Change of Contract TImes	53
Change Proposals	53
Notification to Surety	54

Article 12-Claims	54
12.01	Claims	54
Article 13-Cost of the Work; Allowances; Unit Price Work	56
Cost of the Work	56
Allowances	59
Unit Price Work	60
Article 14-Tests and Inspections; Correction, Removal, or Acceptance of Defective Work	60

14.01
14.02
14.03
14.04
14.05
14.06
14.07

Access to Work	60
Tests, Inspections, and Approvals	61
Defective Work	61
Acceptance of Defective Work	62
Uncovering Work	62
Owner May Stop the Work	63
Owner May Correct Defective Work	63

Article 15-Payments to Contractor; Set-Offs; Completion; Correction Period	64

15.01
15.02
15.03
15.04
15.05
15.06
15.07
15.08

Progress Payments	64
Contractor's Warranty of Title	67
Substantial Completion	67
Partial Use or Occupancy	68
Final Inspection	69
Final Payment	69
Waiver of Claims	70
Correction Period	71

Article 16-Suspension of Work and Termination	72

16.01
16.02
16.03
16.04

Owner May Suspend Work	72
Owner May Terminate for Cause	72
Owner May Terminate for Convenience	73
Contractor May Stop Work or Terminate	74

Article 17-Final Resolution of Disputes	74
17.01	Methods and Procedures	74
Article 18-Miscellaneous	75

18.01
18.02

Giving Notice	75
Computation of Times	75

18.03
18.04
18.05
18.06
18.07
18.08
18.09
18.10

Cumulative Remedies	75
Limitation of Damages	76
No Waiver	76
Survival of Obligations	76
Controlling Law	76
Assignment of Contract	76
Successors and Assigns	76
Headings	76

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.
TDC Page S of 5

STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT
[COD/PROJECT NAME]

ARTICLE 1-DEFINITIONS AND TERMINOLOGY

Defined Terms
Wherever used in the Bidding Requirements or Contract Documents, a term printed with initial capital letters, including the term's singular and plural forms, will have the meaning indicated in the definitions below. In addition to terms specifically defined, terms with initial capital letters in the Contract Documents include references to identified articles and paragraphs, and the titles of other documents or forms.
Addenda-Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the proposed Contract Documents.
Agreement-The written instrument, executed by Owner and Contractor, that sets forth the Contract Price and Contract Times, identifies the parties and the Engineer, and designates the specific items that are Contract Documents.
Application for Payment-The document prepared by Contractor, in a form acceptable to Engineer, to request progress or final payments, and which is to be accompanied by such supporting documentation as is required by the Contract Documents.
Bid-The offer of a Bidder submitted on the prescribed form setting forth the prices for the Work to be performed.
Bidder-An individual or entity that submits a Bid to Owner.
Bidding Documents- The Bidding Requirements, the proposed Contract Documents, and all Addenda.
Bidding Requirements-The Advertisement or invitation to bid, the project manual and any documents included or referenced therein, including but not limited to Instructions to Bidders, Bid Bond or other Bid security, if any, the Bid Form, and the Bid with any attachments.
Change Order-A document which is signed by Contractor and Owner and authorizes an addition, deletion, or revision in the Work or an adjustment in the Contract Price or the Contract Times, or other revision to the Contract, issued on or after the Effective Date of the Contract.
Change Proposal-A written request by Contractor, duly submitted in compliance with the procedural requirements set forth herein, seeking an adjustment in Contract Price or Contract Times; contesting an initialdecision by Engineer concerning the requirements of the Contract Documents or the acceptability of Work under the Contract Documents;

EJCDC® C-700, Standard General Conditions of the Construction Contract.

challenging a set-off against payments due; or seeking other relief with respect to the terms of the Contract.
Claim
A demand or assertion by Owner directly to Contractor, duly submitted in compliance with the procedural requirements set forth herein, seeking an adjustment of Contract Price or Contract Times; contesting an initial decision by Engineer concerning the requirements of the Contract Documents or the acceptability of Work under the Contract Documents; contesting Engineer's decision regarding a Change Proposal; seeking resolution of a contractual issue that Engineer has declined to address; or seeking other relief with respect to the terms of the Contract.
A demand or assertion by Contractor directly to Owner, duly submitted in compliance with the procedural requirements set forth herein, contesting Engineer's decision regarding a Change Proposal, or seeking resolution of a contractual issue that Engineer has declined to address.
A demand or assertion by Owner or Contractor, duly submitted in compliance with the procedural requirements set forth herein, made pursuant to Paragraph 12.01.A.4, concerning disputes arising after Engineer has issued a recommendation of final payment.
A demand for money or services by a third party is not a Claim.
Constituent of Concern-Asbestos, petroleum, radioactive materials, polychlorinated biphenyls (PCBs), lead-based paint (as defined by the HUD/EPA standard), hazardous waste, and any substance, product, waste, chemical, element, compound. solution, mixture. or other material of any nature whatsoever that is or becomes listed, regulated, or addressed pursuant to Laws and Regulations regulating, relating to, or imposing liability or standards of conduct concerning, any hazardous, toxic, or dangerous waste, substance, chemical. element, compound, solution, mixture, or material.
Contract-The entire and integrated written contract between Owner and Contractor concerning the Work.
Contract Documents-Those items so designated in the Agreement, and which together comprise the Contract.
Contract Price-The money that Owner has agreed to pay Contractor for completion of the Work in accordance with the Contract Documents.
Contract Times-The number of days or the dates by which Contractor shall: (a) achieve Milestones, if any; (b) achieve Substantial Completion; and (c) complete the Work.
Contractor-The individual or entity with which Owner has contracted for performance of the Work.
Cost of the Work-See Paragraph 13.01 for definition.
Drawings-The part of the Contract that graphically shows the scope, extent, and character of the Work to be performed by Contractor.
Effective Date of the Contract-The date, indicated in the Agreement, on which the Contract becomes effective.

Electronic Document-Any Project-related correspondence, attachments to correspondence, data, documents, drawings, information, or graphics, including but not limited to Shop Drawings and other Submittals, that are in an electronic or digital format.
Electronic Meons-Electronic mail (email), upload/download from a secure Project website, or other communications methods that allow: (a) the transmission or communication of Electronic Documents; (b) the documentation of transmissions, including sending and receipt; (c) printing of the transmitted Electronic Document by the recipient; (d) the storage and archiving of the Electronic Document by sender and recipient; and (e) the use by recipient of the Electronic Document for purposes permitted by this Contract. Electronic Means does not include the use of text messaging, or of Facebook, Twitter, lnstagram, or similar social media services for transmission of Electronic Documents.
Engineer-The individual or entity named as such in the Agreement.
Field Order-A written order issued by Engineer which requires minor changes in the Work but does not change the Contract Price or the Contract Times.
Hozordous Environmental Condition- The presence at the Site of Constituents of Concern in such quantities or circumstances that may present a danger to persons or property exposed thereto.
The presence at the Site of materials that are necessary for the execution of the Work, or that are to be incorporated into the Work, and that are controlled and contained pursuant to industry practices, Laws and Regulations, and the requirements of the Contract, is not a Hazardous Environmental Condition.
The presence of Constituents of Concern that are to be removed or remediated as part of the Work is not a Hazardous Environmental Condition.
The presence of Constituents of Concern as part of the routine, anticipated, and obvious working conditions at the Site, is not a Hazardous Environmental Condition.
Laws and Regulations; Laws or Regulations-Any and all applicable laws, statutes, rules, regulations, ordinances, codes, and binding decrees, resolutions, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. Such definitions shall further include, where the context reasonably allows, compliance with any applicable permits and/or other similar approvals issued by governmental bodies, agencies, and authorities.
Liens-Charges, security interests, or encumbrances upon Contract-related funds, real property, or personal property.
Milestone-A principal event in the performance of the Work that the Contract requires Contractor to achieve by an intermediate completion date, or by a time prior to Substantial Completion of all the Work.
Notice of Award-The written notice by Owner to a Bidder of Owner's acceptance of the Bid.
Notice to Proceed-A written notice by Owner or Engineer to Contractor fixing the date on which the Contract Times will commence to run and on which Contractor shall start to perform the Work.

Owner-The individual or entity with which Contractor has contracted regarding the Work, and which has agreed to pay Contractor for the performance of the Work, pursuant to the terms of the Contract. The Owner may also be referred to as the "District."
Progress Schedule-A schedule, prepared and maintained by Contractor, describing the sequence and duration of the activities comprising Contractor's plan to accomplish the Work within the Contract Times.
Project-The total undertaking to be accomplished for Owner by engineers, contractors, and others, including planning, study, design, construction, testing, commissioning, and start-up, and of which the Work to be performed under the Contract Documents is a part.
Resident Project Representative -The authorized representative of Engineer assigned to assist Engineer at the Site. As used herein, the term Resident Project Representative (RPR) includes any assistants or field staff of Resident Project Representative.
Samples-Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and that establish the standards by which such portion of the Work will be judged.
Schedule of Submittals-A schedule, prepared and maintained by Contractor, of required submittals and the time requirements for Engineer's review of the submittals.
Schedule of Values-A schedule, prepared and maintained by Contractor, allocating portions of the Contract Price to various portions of the Work and used as the basis for reviewing Contractor's Applications for Payment.
Shop Drawings-All drawings, diagrams, illustrations, schedules, and other data or information that are specifically prepared or assembled by or for Contractor and submitted by Contractor to illustrate some portion of the Work. Shop Drawings, whether approved or not, are not Drawings and are not Contract Documents.
Site-Lands or areas indicated in the Contract Documents as being furnished by Owner upon which the Work is to be performed, including rights-of-way and easements, and such other lands or areas furnished by Owner which are designated for the use of Contractor.
Specifications-The part of the Contract that consists of written requirements for materials, equipment, systems, standards, and workmanship as applied to the Work, and certain administrative requirements and procedural matters applicable to the Work.
Subcontractor-An individual or entity having a direct contract with Contractor or with any other Subcontractor for the performance of a part of the Work.
Submittal-A written or graphic document, prepared by or for Contractor, which the Contract Documents require Contractor to submit to Engineer, or that is indicated as a Submittal in the Schedule of Submittals accepted by Engineer. Submittals may include Shop Drawings and Samples; schedules; product data; Owner-delegated designs; sustainable design information; information on special procedures; testing plans; results of tests and evaluations, source quality-control testing and inspections, and field or Site quality-control testing and inspections; warranties and certifications; Suppliers' instructions and reports; records of delivery of spare parts and tools; operations and maintenance data; Project photographic documentation; record documents; and other such documents required by the Contract Documents. Submittals, whether or not
EJCDC® C-700, Stand"ard General Conditions of the Construction Contract.

approved or accepted by Engineer, are not Contract Documents. Change Proposals, Change Orders, Claims, notices, Applications for Payment, and requests for interpretation or clarification are not Submittals.
Substantial Completion-The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of Engineer, the Work (or a specified part thereof) is sufficiently complete, in accordance with the Contract Documents, so that the Work (or a specified part thereof) can be utilized for the purposes for which it is intended. The terms "substantially complete" and "substantially completed" as applied to all or part of the Work refer to Substantial Completion of such Work. Notwithstanding anything to the contrary herein. "Substantial Completion" shall be considered to be on the date which all applicable governmental agencies having jurisdiction over the Work have issued unconditional certificates of completion and have signed off on all final inspections with respect to each portion of the work and the Owner is able to utilize each portion of the Work set forth in the Contract Documents for the intended purpose. Also notwithstanding anything to the contrary contained herein. Contractor shall be responsible for obtaining the final inspections and applicable written approvals from all governmental agencies with jurisdiction with respect to each portion of the Work. and in connection therewith. Owner and Engineer shall comply with all of its obligations required by the issuing authority in order to enable the Contractor to obtain such Certificate.
Successful Bidder-The Bidder to which the Owner makes an award of contract.
Supplementary Conditions-The part of the Contract that amends or supplements these General Conditions.
Supplier-A manufacturer, fabricator, supplier, distributor, or vendor having a direct contract with Contractor or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by Contractor or a Subcontractor.
Technical Data
Those items expressly identified as Technical Data in the Supplementary Conditions, with respect to either (1) existing subsurface conditions at or adjacent to the Site, or existing physical conditions at or adjacent to the Site including existing surface or subsurface structures (except Underground Facilities) or (2) Hazardous Environmental Conditions at the Site.
If no such express identifications of Technical Data have been made with respect to conditions at the Site, then Technical Data is defined, with respect to conditions at the Site under Paragraphs 5.03, 5.04, and 5.06, as the data contained in boring logs, recorded measurements of subsurface water levels, assessments of the condition of subsurface facilities, laboratory test results, and other factual, objective information regarding conditions at the Site that are set forth in any geotechnical, environmental, or other Site or facilities conditions report prepared for the Project and made available to Contractor.
Information and data regarding the presence or location of Underground Facilities are not intended to be categorized, identified, or defined as Technical Data, and instead Underground Facilities are shown or indicated on the Drawings.

EJCDC® C 700, Standard General Conditions of the Construction Contract.

Underground Facilities-All active or not-in-service underground lines, pipelines, conduits, ducts, encasements, cables, wires, manholes, vaults, tanks, tunnels, or other such facilities or systems at the Site, including but not limited to those facilities or systems that produce, transmit, distribute, or convey telephone or other communications, cable television, fiber optic transmissions, power, electricity, light, heat, gases, oil, crude oil products, liquid petroleum products, water, steam, waste, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. An abandoned facility or system is not an Underground Facility.
Unit Price Work-Work to be paid for on the basis of unit prices.
Work-The entire construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work indudes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction; furnishing, installing, and incorporating all materials and equipment into such construction; and may include related services such as testing, start-up, and commissioning, all as required by the Contract Documents.
Work Change Directive-A written directive to Contractor issued on or after the Effective Date of the Contract, signed by Owner and recommended by Engineer, ordering an addition, deletion, or revision in the Work.
Construction Manager- any individual, entity or firm retained by the Owner to assist the Engineer with the administration of managing. overseeing and processing construction related activities.
Terminology
The words and terms discussed in Paragraphs 1.02.B, C, D, and E are not defined terms that require initial capital letters, but, when used in the Bidding Requirements or Contract Documents, have the indicated meaning.
Intent of Certain Terms or Adjectives: The Contract Documents include the terms "as allowed," "as approved," "as ordered," "as directed" or terms of like effect or import to authorize an exercise of professional judgment by Engineer. In addition, the adjectives "reasonable," "suitable," "acceptable," "proper," "satisfactory," or adjectives of like effect or import are used to describe an action or determination of Engineer as to the Work. It is intended that such exercise of professional judgment, action, or determination will be solely to evaluate, in general, the Work for compliance with the information in the Contract Documents and with the design concept of the Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective is not intended to and shall not be effective to assign to Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility contrary to the provisions of Article 10 or any other provision of the
Contract Documents.
Doy: The word "day" means a calendar day of 24 hours measured from midnight to the next midnight.
Defective: The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it:
does not conform to the Contract Documents;

EJCDC® C-700, Standard- General Conditions ohhe Construction Contract.

does not meet the requirements of any applicable inspection, reference standard, test, or approval referred to in the Contract Documents; or
has been damaged prior to Engineer's recommendation of final payment (unless responsibility for the protection thereof has been assumed by Owner at Substantial Completion in accordance with Paragraph 15.03 or Paragraph 15.04).
Furnish, Install, Perform, Provide
The word "furnish," when used in connection with services, materials, or equipment, means to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition.
The word "install," when used in connection with services, materials, or equipment, means to put into use or place in final position said services, materials, or equipment complete and ready for intended use.
The words "perform" or "provide," when used in connection with services, materials, or equipment, means to furnish and install said services, materials, or equipment complete and ready for intended use.
If the Contract Documents establish an obligation of Contractor with respect to specific services, materials, or equipment, but do not expressly use any of the four words "furnish," "install," "perform," or "provide," then Contractor shall furnish and install said services, materials, or equipment complete and ready for intended use.
Contract Price or Contract Times: References to a change in "Contract Price or Contract Times" or "Contract Times or Contract Price" or similar, indicate that such change applies to
(1) Contract Price, (2) Contract Times, or (3) both Contract Price and Contract Times, as warranted, even if the term "or both" is not expressed.
Unless stated otherwise in the Contract Documents, words or phrases that have a well-known technical or construction industry or trade meaning are used in the Contract Documents in accordance with such recognized meaning.

ARTICLE 2-PRELIMINARY MATTERS

Delivery of Performance and Payment Bonds; Evidence of Insurance
Performance and Payment Bonds: When Contractor delivers the signed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner the performance bond and payment bond (if the Contract requires Contractor to furnish such bonds). Contractor must provide a certified copy of the recorded bonds before commencing the Work or before recommencing the Work after a default or abandonment.
Evidence of Contractor's Insurance: When Contractor delivers the signed counterparts of the Agreement to Owner, Contractor shall also deliver to Owner, with copies to each additional insured (as identified in the Contract), the certificates, endorsements, and other evidence of insurance required to be provided by Contractor in accordance with Article 6, except to the extent the Supplementary Conditions expressly establish other dates for delivery of specific insurance policies.
E>lideRce efOwRer's IRs!iraRce: .".fter receiiit efthe sigAea rn11Ateriiarts efthe .".greemeAt aAEl all re 11irea seAEls aAEI iAs11raAce Elec11meAtatieA, Ovmer shall iiremiitly Eleliver ta CeAtracter,

witR ee ies te eaeR additieAal iASHFed {as ideAtified iA tRe CeAtFaet), tRe eertifieates aAd etReF evideAee 9f iASHFaAee Fe HiFed te ee mvided B',' OwAeF l!AdeF Artiele B.
Copies of Documents
Owner shall furnish to Contractor four printed copies of the Contract (including one fully signed counterpart of the Agreement), and one copy in electronic portable document format (PDF). Additional printed copies will be furnished upon request at the cost of reproduction.
Owner shall maintain and safeguard at least one original printed record version of the Contract, including Drawings and Specifications signed and sealed by Engineer and other design professionals. Owner shall make such original printed record version of the Contract available to Contractor for review. Owner may delegate the responsibilities under this provision to Engineer.
Before Starting Construction
Preliminary Schedules: Within Ml-2 days after the Effective Date of the Contract (or as otherwise required by the Contract Documents), Contractor shall submit to Engineer for
timely review:
a preliminary Progress Schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract;
a preliminary Schedule of Submittals; and
a preliminary Schedule of Values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdivides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work.
Such schedules shall be consistent with the documents provided to the Owner as part of the Contractor's Bid.
Preconstruction Conference; Designation of Authorized Representatives
Before any Work at the Site is started, a conference attended by Owner, Contractor, Engineer, and others as appropriate will be held to establish a working understanding among the parties as to the Work, and to discuss the schedules referred to in Paragraph 2.03.A, procedures for handling Shop Drawings, Samples, and otherSubmittals, processing Applications for Payment, electronic or digital transmittals, and maintaining required records.
At this conference Owner and Contractor each shall designate, in writing, a specific individual to act as its authorized representative with respect to the services and responsibilities under the Contract. Such individuals shall have the authority to transmit and receive information, render decisions relative to the Contract, and otherwise act on behalf of each respective party.
Acceptance of Schedules
At least 10 days before submission of the first Application for Payment a conference, attended by Contractor, Engineer, and others as appropriate, will be held to review the schedules

submitted in accordance with Paragraph 2.03.A. No progress payment will be made to Contractor until acceptable schedules are submitted to Engineer.
The Progress Schedule will be acceptable to Engineer if it provides an orderly progression of the Work to completion within the Contract Times. Such acceptance will not impose on Engineer responsibility for the Progress Schedule, for sequencing, scheduling, or progress of the Work, nor interfere with or relieve Contractor from Contractor's full responsibility therefor.
Contractor's Schedule of Submittals will be acceptable to Engineer if it provides a workable arrangement for reviewing and processing the required submittals.
Contractor's Schedule of Values will be acceptable to Engineer as to form and substance if it provides a reasonable allocation of the Contract Price to the component parts of the Work.
If a schedule is not acceptable, Contractor will have an additional 10 days to revise and resubmit the schedule.
Such schedules shall be consistent with the documents provided to the Owner as part of the Contractor's Bid.
Electronic Transmittals
Except as otherwise stated elsewhere in the Contract, the Owner, Engineer, Construction Manager, and Contractor may send, and shall accept, Electronic Documents transmitted by Electronic Means.
If the Contract does not establish protocols for Electronic Means, then Owner, Engineer, Construction Manager, and Contractor shall jointly develop such protocols.
Subject to any governing protocols for Electronic Means, when transmitting Electronic Documents by Electronic Means, the transmitting party makes no representations as to long­ term compatibility, usability, or readability of the Electronic Documents resulting from the recipient's use of software application packages, operating systems, or computer hardware differing from those used in the drafting or transmittal of the Electronic Documents.

ARTICLE 3-CONTRACT DOCUMENTS: INTENT, REQUIREMENTS, REUSE

Intent
The Contract Documents are complementary; what is required by one Contract Document is as binding as if required by all.
It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Documents.
Unless otherwise stated in the Contract Documents, if there is a discrepancy between the electronic versions of the Contract Documents (including any printed copies derived from such electronic versions) and the printed record version, the printed record version will govern.
The Contract supersedes prior negotiations, representations, and agreements, whether written or oral.

Engineer will issue clarifications and interpretations of the Contract Documents as provided herein.
Any provision or part of the Contract Documents held to be void or unenforceable under any Law or Regulation will be deemed stricken, and all remaining provisions will continue to be valid and binding upon Owner and Contractor, which agree that the Contract Documents will be reformed to replace such stricken provision or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision.
Nothing in the Contract Documents creates:
any contractual relationship between Owner or Engineer or Construction Manager and any Subcontractor, Supplier, or other individual or entity performing or furnishing any of the Work, for the benefit of such Subcontractor, Supplier, or other individual or entity; or
any obligation on the part of Owner or Engineer or Construction Manager to pay orto see to the payment of any money due any such Subcontractor, Supplier, or other individual or entity, except as may otherwise be required by Laws and Regulations.
Reference Standards
Standards Specifications, Codes, laws and Regulations
Reference in the Contract Documents to standard specifications, manuals, reference standards, or codes of any technical society, organization, or association, or to Laws or Regulations, whether such reference be specific or by implication, means the standard specification, manual, reference standard, code, or Laws or Regulations in effect at the time of opening of Bids (or on the Effective Date of the Contract if there were no Bids), except as may be otherwise specifically stated in the Contract Documents.
No provision of any such standard specification, manual, reference standard, or code, and no instruction of a Supplier, will be effective to change the duties or responsibilities of Owner, Contractor, or Engineer from those set forth in the part of the Contract Documents prepared by or for Engineer. No such provision or instruction shall be effective to assign to Owner or Engineer any duty or authority to supervise or direct the performance of the Work, or any duty or authority to undertake responsibility inconsistent with the provisions of the part of the Contract Documents prepared by or for Engineer.
Reporting and Resolving Discrepancies
Reporting Discrepancies
Contractor's Verification of Figures and Field Measurements: Before undertaking each part of the Work, Contractor shall carefully study the Contract Documents, and check and verify pertinent figures and dimensions therein, particularly with respect to applicable field measurements. Contractor shall promptly report in writing to Engineer any conflict, error, ambiguity, or discrepancy that Contractor discovers, or has actual knowledge of, and shall not proceed with any Work affected thereby until the conflict, error, ambiguity, or discrepancy is resolved by a clarification or interpretation by Engineer, or by an amendment or supplement to the Contract issued pursuant to Paragraph 11.01.
Contractor's Review of Contract Documents: If, before or during the performance of the Work, Contractor discovers any conflict, error, ambiguity, or discrepancy within the

Contract Documents, or between the Contract Documents and (a) any applicable Law or Regulation, (b) actual field conditions, (c) any standard specification, manual, reference standard, or code, or (d) any instruction of any Supplier, then Contractor shall promptly report it to Engineer in writing. Contractor shall not proceed with the Work affected thereby (except in an emergency as required by Paragraph 7.15) until the conflict, error, ambiguity, or discrepancy is resolved, by a clarification or interpretation by Engineer, or by an amendment or supplement to the Contract issued pursuant to Paragraph 11.01.
CoAtractor s"1all Rot Ile liallle to o•,mer or AgiAeer Hirfaih,1re to re ort aAy coAflict, error, arnllig1,Jity, or Eliscre aAcy iA tRe CoAtract Qoc1,JFAeAts  1,JAless  CoAtractor "1aEl  act1,Jal lmowleElge t"1ereof.
Resolving Discrepancies
Except as may be otherwise specifically stated in the Contract Documents, the provisions of the part of the Contract Documents prepared by or for Engineer take precedence in resolving any conflict, error, ambiguity, or discrepancy between such provisions of the Contract Documents and:
the provisions of any standard specification, manual, reference standard, or code, or the instruction of any Supplier (whether or not specifically incorporated by reference as a Contract Document); or
the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Documents would result in violation of such Law or Regulation).
Requirements of the Contract Documents
During the performance of the Work and until final payment, Contractor and Owner shall submit to the Engineer in writing all matters in question concerning the requirements of the Contract Documents (sometimes referred to as requests for information or interpretation­ RFls), or relating to the acceptability of the Work under the Contract Documents, as soon as possible after such matters arise. Engineer will be the initial interpreter of the requirements of the Contract Documents, and judge of the acceptability of the Work.
Engineer will, with reasonable promptness, render a written clarification, interpretation, or decision on the issue submitted, or initiate an amendment or supplement to the Contract Documents. Engineer's written clarification, interpretation, or decision will be final and binding on Contractor, unless it appeals by submitting a Change Proposal, and on Owner, unless it appeals by filing a Claim.
If a submitted matter in question concerns terms and conditions of the Contract Documents that do not involve (1) the performance or acceptability of the Work under the Contract Documents, (2) the design (as set forth in the Drawings, Specifications, or otherwise), or (3) other engineering or technical matters, then Engineer will promptly notify Owner and Contractor in writing that Engineer is unable to provide a decision or interpretation. If Owner and Contractor are unable to agree on resolution of such a matter in question, either party may pursue resolution as provided in Article 12.

Reuse of Documents
Contractor and its Subcontractors and Suppliers shall not:
have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of Engineer or its consultants, including electronic media versions, or reuse any such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of Owner and Engineer and specific written verification or adaptation by Engineer; or
have or acquire any title or ownership rights in any other Contract Documents, reuse any such Contract Documents for any purpose without Owner's express written consent, or violate any copyrights pertaining to such Contract Documents.
The prohibitions of this Paragraph 3.05 will survive final payment, or termination of the Contract. Nothing herein precludes Contractor from retaining copies of the Contract Documents for record purposes.

ARTICLE 4-COMMENCEMENT AND PROGRESS OF THE WORK

Commencement of Contract Times; Notice to Proceed
The Contract Times will commence to run OR  tlie 3Qtl1 da'{ after tlie Effective Date of tlie GoRtraet or, if a Notke to Proeeea is giveR, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Contract. No Work shall be performed before the issuance of a Notice to Proceed. IA AO eve At
,,..,ill tlie GoAtraet TiFRes rnFRFReRee to  ruA later tliaA Uie 6Qtl1 aa · after tlie Ela'{ of Bia 013eAiAg or tlie 3Qtl1 aay after tlie Effeeti>;e Date oftlie GoAtraet, wl1iel1e•Jer date is earlier.
Starting the Work
Contractor shall start to perform the Work on the date when the Contract Times commence to run. No Work may be done at the Site prior to such date.
Reference Points
Owner shall provide engineering surveys to establish reference points for construction which in Engineer's judgment are necessary to enable Contractor to proceed with the Work. Contractor shall be responsible for laying out the Work, shall protect and preserve the established reference points and property monuments, and shall make no changes or relocations without the prior written approval of Owner. Contractor shall report to Engineer whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel.
Progress Schedule
Contractor shall adhere to the Progress SFhedule established in accordance with Paragraph 2.05 as it may be adjusted from time to time as provided below.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

Contractor shall submit to Engineer for acceptance (to the extent indicated in Paragraph 2.05) proposed adjustments in the Progress Schedule that will not result in changing the Contract Times.
Proposed adjustments in the Progress Schedule that will change the Contract Times must be submitted in accordance with the requirements of Article 11.
Contractor shall carry on the Work and adhere to the Progress Schedule during all disputes or disagreements with Owner. No Work will be delayed or postponed pending resolution of any disputes or disagreements, or during any appeal process, except as permitted by Paragraph 16.04, or as Owner and Contractor may otherwise agree in writing.
Delays in Contractor's Progress
If Owner, Engineer, or anyone for whom Owner is responsible, delays, disrupts, or interferes with the performance or progress of the Work, then Contractor shall be entitled to an equitable adjustment in Contract Price or Contract Times.
Contractor shall not be entitled to an adjustment in Contract Price or Contract Times for delay, disruption, or interference caused by or within the control of Contractor. Delay, disruption, andinterference attributable to and within the control of a Subcontractor or Supplier shall be deemed to be within the control of Contractor.
If Contractor's performance or progress is delayed, disrupted, or interfered with by unanticipated causes not the fault of and beyond the control of Owner, Contractor, and those for which they are responsible, then Contractor shall be entitled to an equitable adjustment in Contract Times. Such an adjustment will be Contractor's sole and exclusive remedy for the delays, disruption, and interference described in this paragraph. Causes of delay, disruption, or interference that may give rise to an adjustment in Contract Times under this paragraph include but are nat limitea ta Q!!]y the following:
Severe and unavoidable acts of God or natural catastrophes such as fires, floods, epidemics, and earthquakes;
Abnormal weather conditions;
Acts or failures to act of third-party utility owners or other third-party entities (other than those third-party utility owners or other third-party entities performing other work at or adjacent to the Site as arranged by or under contract with Owner, as contemplated in Article 8); and
Acts of war or terrorism.
Contractor must submit any Change Proposal seeking an equitable adjustment in the Contract Times under this paragraph within 15 days of the damaging, delaying, disrupting, or interfering event, or such claim shall be waived. Contractor shall be required to prove that any abnormal weather conditions are in excess of normal rainfall amounts or other normal weather conditions, and must provide such documentation of unusually severe weather as the Engineer deems reasonably necessary. Normal seasonal adverse weather typical for the area, including heavy rain shall not be deemed as causing any delays for the Project.
In no event shall Owner or Engineer be liable to Contractor, any subcontractor, any supplier, or any other person or organization, or to any surety or employee or any agent of them, for damages, including but not limited to all fees and charges of Engineers, architects, attorneys,

and other professionals and all court or arbitration or other dispute resolution costs, arising out of or resulting from:
delays caused by or within the control of Contractor (or Subcontractor or Supplier); or
delays beyond the control of both Owner and Contractor, including, but not limited to, fires, floods, epidemics, abnormal weather conditions, acts of God, or acts or neglect by utility owners or other contractors performing other work;
Nor shall Owner or Engineer of each of them be liable to Contractor for any claims, costs, losses or damages sustained by Contractor on or in connection with any other project or anticipated project.
Except for an adjustment to the Contract Times, the Contractor shall not be entitled to and hereby waives any and all damages that it may suffer by reason of delay or for any Act of God, and waives all damages that it may suffer by reason of such delay including but not limited to lost profits, overhead, and other consequential damages. No payment of any claim for damages shall be made to the Contractor as compensation for damages for any delays or hindrances that are avoidable by Contractor.
Contractor's entitlement to an adjustment of Contract Times or Contract Price is limited and conditioned as follows:
Contractor's entitlement to an adjustment of the Contract Times is conditioned on the delay, disruption, or interference adversely affecting an activity on the critical path to completion of the Work, as of the time of the delay, disruption, or interference.
Contractor shall not be entitled to an adjustment in Contract Price for any delay, disruption, or interference if such delay is concurrent with a delay, disruption, or interference caused by or within the control of Contractor. Such a concurrent delay by Contractor shall not preclude an adjustment of Contract Times to which Contractor is otherwise entitled.
Adjustments of Contract Times or Contract Price are subject to the provisions of Article 11.
The District, in its sole and absolute discretion, may additionally direct that the Project be delivered in multiple phases rather than all at once. Such option, if exercised, shall in no way impact the pricing of the Project, nor constitute a delay.
Each Contractor request or Change Proposal seeking an increase in Contract Times or Contract Price must be supplemented by supporting data that sets forth in detail the following:
The circumstances that form the basis for the requested adjustment;
The date upon which each cause of delay, disruption, or interference began to affect the progress of the Work;
The date upon which each cause of delay, disruption, or interference ceased to affect the progress of the Work;
The number of days' increase in Contract Times claimed as a consequence of each such cause of delay, disruption, or interference; and
The impact on Contract Price, in accordance with the provisions of Paragraph 11.07.

Contractor shall also furnish such additional supporting documentation as Owner or Engineer may require including, where appropriate, a revised progress schedule indicating all the activities affected by the delay, disruption, or interference, and an explanation of the effect of the delay, disruption, or interference on the critical path to completion of the Work. Such supporting documentation shall include. where appropriate. documentation of abnormal weather conditions and an explanation of their impact on Contract Price and/or Contract Times.
Delays, disruption, and interference to the performance or progress of the Work resulting from the existence of a differing subsurface or physical condition, an Underground Facility that was not shown or indicated by the Contract Documents, or not shown or indicated with reasonable accuracy, and those resulting from Hazardous Environmental Conditions, are governed by Article 5, together with the provisions of Paragraphs 4.05.D and 4.05.E.
Paragraph 8.03 addresses delays, disruption, and interference to the performance or progress of the Work resulting from the performance of certain other work at or adjacent to the Site.

ARTICLE 5-SITE; SUBSURFACE	AND	PHYSICAL	CONDITIONS;	HAZARDOUS	ENVIRONMENTAL CONDITIONS

Availability of Lands
Owner shall furnish the Site. Owner shall notify Contractor in writing of any encumbrances or restrictions not of general application but specifically related to use of the Site with which Contractor must comply in performing the Work.
lJ13aR FeasaRal31e wFitteR rnqwest, OwReF shall fwrnish CaRtFaEteF with a EllFFeRt statemeRt af FeESFB legal title aREI legal EleSEFif)tiaR af the laREIS  llj38A whiEh f)eFFRaRent iFRl3F0VCFReRtS aFe te  13e maEle aREI Owner-'s inteFest theFein as neEessaFyfaF gi'ling RatiEe af SF filiRg a meEhaRiE's SF E8RStFllctieR lieA agaiRSt SllEh laREIS in  aE€9FElaREe with a13131ieal31e  laws aREI  RegwlatiaRS.
Contractor shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment.
Use of Site and Other Areas
Limitation on Use of Site and Other Areas
Contractor shall confine construction equipment, temporary construction facilities, the storage of materials and equipment, and the operations of workers to the Site, adjacent areas that Contractor has arranged to use through construction easements or otherwise, and other adjacent areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and such other adjacent areas with construction equipment or other materials or equipment. Contractor shall assume full responsibility for (a) damage to the Site; (b) damage to any such other adjacent areas used for Contractor's operations; (c) damage to any other adjacent land or areas, or to improvements, structures, utilities, or similar facilities located at such adjacent lands or areas; and (d) for injuries and losses sustained by the owners or occupants of any such land or areas; provided that such damage or injuries result from the performance of the Work or from other actions or conduct of the Contractor or those for which Contractor is responsible.
If a damage or injury claim is made by the owner or occupant of any such land or area because of the performance of the Work, or because of other actions or conduct of the
EJCDC® C-700, Standard Generar Cond'itions of the Construction Contract.

Contractor or those for which Contractor is responsible, Contractor shall (a) take immediate corrective or remedial action as required by Paragraph 7.13, or otherwise; (b) promptly attempt to settle the claim as to all parties through negotiations with such owner or occupant, or otherwise resolve the claim by arbitration or other dispute resolution proceeding, or in a court of competent jurisdiction; and (c) to the fullest extent permitted by Laws and Regulations, indemnifv. defend and hold harmless lndemnitees (defined in Paragraph 7.18)OwAer amJ EAgiAeer, aAd the efficers, directers, FAeFAeers, 13artAers, eFA13leyees, ageAts, ceAswltaAts aAd sweceAtracters ef each aAd aA·,· ef theFA, from and against any such claim, and against all liabilities. suits. liens. demands. costs, losses, interest. expenses. penalties. fines. judgments. and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution fees and costs) whether monetary or otherwise. arising. in whole or in part. out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against Owner, Engineer, or any other party indemnified hereunder to the extent caused directly or indirectly, in whole or in part by, or based upon, Contractor's negligent. reckless or intentionally wrongful performance of the Work, or because of other negligent. reckless or intentionally wrongful actions or conduct of the Contractor or those for which Contractor is
responsible.
Removal of Debris During Performance of the Work: During the progress of the Work the Contractor shall keep the Site and other adjacent areas free from accumulations of waste materials, rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris will conform to applicable Laws and Regulations.
Cleaning: Prior to Substantial Completion of the Work Contractor shall clean the Site and the Work and make it ready for utilization by Owner. At the completion of the Work Contractor shall remove from the Site and adjacent areas all tools, appliances, construction equipment and machinery, rubbish. debris. and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents.
Loading of Structures: Contractor shall not load nor permit any part of any structure to be loaded in any manner that will endanger the structure, nor shall Contractor subject any part of the Work or adjacent structures or land to stresses or pressures that will endanger them.
Subsurface and Physical Conditions
Reports ond Drawings: The Supplementary Conditions identify:
Those reports known to Owner of explorations and tests of subsurface conditions at or adjacent to the Site that ceAtaiA TechAical Data from which the Engineer prepared the Contract Drawings and Specifications;
Those drawings of existing physical conditions at or adjacent to the Site, including those drawings depicting existing surface or subsurface structures at or adjacent to the Site (except Underground Facilities), that ceAtaiA TechAical Data from which the Engineer prepared the Contract Drawings and Specifications; and
Technical Data contained in such reports and drawings,lli!}Y.
Underground Facilities: Underground Facilities are shown or indicated on the Drawings, pursuant to Paragraph 5.05, and not in the drawings referred to in Paragraph 5.03.A.

EJCDC® C 700, Standard" General Conditions of the Construction Contract.

Information and data regarding the presence or location of Underground Facilities are not intended to be categorized, identified, or defined as Technical Data.
No Reliance by Contractor on Technical Data: Contractor may not rely upon the accuracy of the Technical Data expressly identified in the Supplementary Conditions with respect to such reports and drawings, sut such FepaFts aAd clFawiAgs aFe Rat CaAtFact 9acumeAts. If Ra such eiEpFess icleAtificatiaA has seeA made, theA CaAtFactaF may rely upaA the accuracy af the TechAical 9ata as clefiAecl iA PaFagraph 1.Q1.l\.4e.s. Instead, while the Technical Data is believed to be reliable, the Technical Data was prepared for Owner's benefit by third parties and accordingly. Owner cannot guarantee the quantity. quality. completeness or accuracy of that information.
Limitations of Other Data and Documents:  lECept faF such FeliaAce BA TechAical Data, Contractor may not rely upon or make any claim against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, with respect to:
the completeness of such reports and drawings for Contractor's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences, and procedures of construction to be employed by Contractor, and safety precautions and programs incident thereto;
other data, interpretations, opinions, and information contained in such reports or shown or indicated in such drawings;
the contents of other Site-related documents made available to Contractor, such as record drawings from other projects at or adjacent to the Site, or Owner's archival documents concerning the Site; or
any Contractor interpretation of or conclusion drawn from any Technical Data or any such other data, interpretations, opinions, or information.
Contractor expressly acknowledges that soil conditions may vary widely across the Site. and Contractor takes responsibility for any and all issues arising from unsuitable soils. including but not limited to. varying soil conditions, etc. that may make it more difficult to install the repairs or otherwise conduct the Work. Furthermore, no additional costs will be charged by Contractor for matters associated with unsuitable and/or varying soils. except that the Contractor may apply for a change order where authorized by the District Engineer and with respect to "templating."
Contractor warrants it has. by careful examination. satisfied itself as to the nature and location of the Work. the conformation of the ground, the character. quality and quantity of the materials to be encountered. the character of equipment and facilities needed preliminary to and during the prosecuting of the Work. Contractor further warrants that the Contract Price is just and reasonable compensation for all the Work, including all foreseen and unforeseen risks. hazards, and difficulties in connection therewith. including any concealed conditions encountered in the performance of the Work below the surface of the ground at variance with conditions indicated by the Contract Documents or other Bidding Documents and Bidding Requirements furnished to the Contractor for its
information.

EJCDC® C-700, Standard· General Conditions of the Construction Contract.

Differing Subsurface or Physical Conditions
Notice by Contractor: If Contractor believes that any subsurface or physical condition that is uncovered or revealed at the Site:
is of such a nature as to establish that any Technical Data an whieh Cantraetar is entitleel ta relv as flFB'lieleel in Paragraflh 5.Q3 is materially inaccurate;
is of such a nature as to require a change in the Drawings or Specifications;
differs materially from that shown or indicated in the Contract Documents; or
is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents;
then Contractor shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by Paragraph 7.15), notify Owner and Engineer in writing about such condition. Contractor shall not further disturb such condition or perform any Work in connection therewith (except with respect to an emergency) until receipt of a written statement permitting Contractor to do so.
Engineer's Review: After receipt of written notice as required by the preceding paragraph, Engineer will promptly review the subsurface or physical condition in question; determine whether it is necessary for Owner to obtain additional exploration or tests with respect to the condition; conclude whether the condition falls within any one or more of the differing site condition categories in Paragraph 5.04.A; obtain any pertinent cost or schedule information from Contractor; prepare recommendations to Owner regarding the Contractor's resumption of Work in connection with the subsurface or physical condition in question and the need for any change in the Drawings or Specifications; and advise Owner in writing of Engineer's findings, conclusions, and recommendations.
Owner's Statement to Contractor Regarding Site Condition: After receipt of Engineer's written findings, condusions, and recommendations, Owner shall issue a written statement to Contractor (with a copy to Engineer) regarding the subsurface or physical condition in question, addressing the resumption of Work in connection with such condition, indicating whether any change in the Drawings or Specifications will be made, and adopting or rejecting Engineer's written findings, conclusions, and recommendations, in whole or in part.
Early Resumption of Work: If at any time Engineer determines that Work in connection with the subsurface or physical condition in question may resume prior to completion of Engineer's review or Owner's issuance of its statement to Contractor, because the condition in question has been adequately documented, and analyzed on a preliminary basis, then the Engineer may at its discretion instruct Contractor to resume such Work.
Possible Price and Times Adjustments
Contractor shall be entitled to an equitable adjustment in Contract Price or Contract Times, to the extent that the existence of a differing subsurface or physical condition, or any related delay, disruption, or interference, causes an increase or decrease in

EJCDC® C-7001 Standard General Conditions of the Construction Contract,

Contractor's cost of, or time required for, performance of the Work; subject, however, to the following:
Such condition must fall within any one or more of the categories described in Paragraph 5.04.A;
With respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraph 13.03; and,
Contractor's entitlement to an adjustment of the Contract Times is subject to the provisions of Paragraphs 4.05.D and 4.05.E.
Contractor shall not be entitled to any adjustment in the Contract Price or Contract Times with respect to a subsurface or physical condition if:
Contractor knew of the existence of such condition at the time Contractor made a commitment to Owner with respect to Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract, or otherwise;
The existence of such condition reasonably could have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and contiguous areas expressly required by the Bidding Requirements or Contract Documents to be conducted by or for Contractor prior to Contractor's making such commitment; or
Contractor failed to give the written notice required by Paragraph 5.04.A.
If Owner and Contractor agree regarding Contractor's entitlement to and the amount or extent of any adjustment in the Contract Price or Contract Times, then any such adjustment will be set forth in a Change Order.
Contractor may submit a Change Proposal regarding its entitlement to or the amount or extent of any adjustment in the Contract Price or Contract Times, no later than 30 days after Owner's issuance of the Owner's written statement to Contractor regarding the subsurface or physical condition in question.
Underground Facilities; Hazardous Environmental Conditions: Paragraph 5.05 governs rights and responsibilities regarding the presence or location of Underground Facilities. Paragraph 5.06 governs rights and responsibilities regarding Hazardous Environmental Conditions. The provisions of Paragraphs 5.03 and 5.04 are not applicable to the presence or location of Underground Facilities, or to Hazardous Environmental Conditions.
Underground Facilities
Contractor's Responsibilities: Owner and Engineer do not warrant or guarantee the accuracy or completeness of any information or data regarding underground facilities provided by others. Unless it is otherwise expressly provided in the Supplementary Conditions, the cost of all of the following are included in the Contract Price, and Contractor shall have full responsibility for, without additional compensation from the Owner:
reviewing and checking all information and data regarding existing Underground Facilities at the Site;
complying with applicable state and local utility damage prevention Laws and Regulations, including but not limited to notification of and cooperation with utility

EJCDC®" c 700, Standard General Conditions of the Construction Contract.

companies and agencies when the Contractor's operations are close to existing facilities in order to provide time for the utilities to stake the location of their existing facilities. This coordination effort shall be done in compliance with Florida Statutes Chapter 556, "Underground Facility Damage Prevention and Safety Act." latest revision.;
locating or verifying the actual location of those Underground Facilities shown or indicated in the Contract Documents as being within the area affected by the Work, by exposing such Underground Facilities during the course of construction;
coordination of the Work with the owners (including Owner) of such Underground Facilities, during construction; and
the safety and protection of all existing Underground Facilities at the Site, and repairing any damage thereto resulting from the Work.
Notice by Contractor: If Contractor believes that an Underground Facility that is uncovered or revealed at the Site was not shown or indicated on the Drawings, or was not shown or indicated on the Drawings with reasonable accuracy, then Contractor shall, promptly after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by Paragraph 7.15), notify Owner and Engineer in writing regarding such Underground Facility.
Engineer's Review: Engineer will:
promptly review the Underground Facility and conclude whether such Underground Facility was not shown or indicated on the Drawings, or was not shown or indicated with reasonable accuracy;
identify and communicate with the owner of the Underground Facility; prepare recommendations to Owner (and if necessary issue any preliminary instructions to Contractor) regarding the Contractor's resumption of Work in connection with the Underground Facility in question;
obtain any pertinent cost or schedule information from Contractor; determine the extent, if any, to which a change is required in the Drawings or Specifications to reflect and document the consequences of the existence or location of the Underground Facility; and
advise Owner in writing of Engineer's findings, conclusions, and recommendations.
During such time, Contractor shall be responsible for the safety and protection of such Underground Facility.
Owner's Statement to Contractor Regarding Underground Facility: After receipt of Engineer's written findings, conclusions, and recommendations, Owner shall issue a written statement to Contractor (with a copy to Engineer) regarding the Underground Facility in question addressing the resumption of Work in connection with such Underground Facility, indicating whether any change in the Drawings or Specifications will be made, and adopting or rejecting Engineer's written findings, conclusions, and recommendations in whole or in part.
Early Resumption of Work: If at any time Engineer determines that Work in connection with the Underground Facility may resume prior to completion of Engineer's review or Owner's issuance of its statement to Contractor, because the Underground Facility in question and conditions affected by its presence have been adequately documented, and analyzed on a

preliminary basis, then the Engineer may at its discretion instruct Contractor to resume such Work.
Possible Price and Times Adjustments
Contractor shall be entitled to an equitable adjustment in the Contract Price or Contract Times, to the extent that any existing Underground Facility at the Site that was not shown or indicated on the Drawings, or was not shown or indicated with reasonable accuracy, or any related delay, disruption, or interference, causes an increase or decrease in Contractor's cost of, or time required for, performance of the Work; subject, however, to the following:
With respect to Work that is paid for on a unit price basis, any adjustment in Contract Price will be subject to the provisions of Paragraph 13.03;
Contractor's entitlement to an adjustment of the Contract Times is subject to the provisions of Paragraphs 4.05.D and 4.05.E; and
Contractor gave the notice required in Paragraph 5.05.B.
If Owner and Contractor agree regarding Contractor's entitlement to and the amount or extent of any adjustment in the Contract Price or Contract Times, then any such adjustment will be set forth in a Change Order.
Contractor may submit a Change Proposal regarding its entitlement to or the amount or extent of any adjustment in the Contract Price or Contract Times, no later than 30 days after Owner's issuance of the Owner's written statement to Contractor regarding the Underground Facility in question.
The information and data shown or indicated on the Drawings with respect to existing Underground Facilities at the Site is based on information and data (a) furnished by the owners of such Underground Facilities, or by others, (b) obtained from available records, or (c) gathered in an investigation conducted in accordance with the current edition of ASCE 38, Standard Guideline for the Collection and Depiction of Existing Subsurface Utility Data, by the American Society of Civil Engineers. If such information or data is incorrect or incomplete, Contractor's remedies are limited to those set forth in this Paragraph 5.05.F.
Hazardous Environmental Conditions at Site
Reports flRfi Drew-iRgs: TRe SupplemeRtary CoRElitioRS iEleRtify:
tRose reports lmowR to OwRer relatiRg to Hazarsous eR'JiroRmeRtal CoRElitioRs tRat Rave lleeR iEleRtifleEI at or aEljaeeRt to tRe Site
ElrawiRgs lmowR to OwRer relatiRg to Hazarsous eRviroRmeRtal CoRElitioRs tRat Rave lleeR iseRtifleEI at or asjaEeRt to tRe Site, if aRy; aREI
TeERRiEal Data EORtaiReEI iR SUER  reports aRB ElrawiRgS.
f!:!:.Q_Re.foRce by CoRtreetor OR TeGhRirn! Dow A!ltllorizefi: CoRtraEtor may rely upoR tRe aEEuraEy of tRe TeERRiEal Data ei,pressly iEleRtifleEI iR tRe SupplemeRtary CoRElitioRs witR respeEt to SUER  reports aREI  ElrawiRgs. llut suER  reports aREI  ElrawiRgs are Rot CoRtraet DoeumeRts. If RO SUER ei,press iseRtifiEatioR Ras lleeR mase, tReR CoRtraEtor may rely OR tRe aeeuraey of tRe TeERRieal Data as ElefiReEI  iR ParagrapR 1.Ql.A.46.ll. lnctoarl, •rrbile tRe

Te€RAi£al Data is llelie\•eEI ta Be reliaBle, tRe TeERAiEal Data was prepares far tRe O•,mer's BeRefit B'f tRirEI parties aAEI aEEarEliRgly, tRe O'lmer EaRRat guaraRtee tRe quaAtity, quality, rnmpleteRess er aEEuraEy af tRat iRfarmatiaA. Eii£e13t far  SUER  reliaAEe aR TeERAi£al Data, CaAtFaEtar may Rat rely u13an er mal,e aRy daim agaiRst 01Jmer er ERgiReer, er any af tReir affiEers, ElireEtars, memllers, 13artReFs, em13layees, ageRts, ESRsultaRts, SF sullEaRtFactaFs, witR Fes13eEtta:
tRe Eam13leteRess af suER rn13aFts ana arawings far CaAtFactaF's 13uF13ases, iAEluEliAg, BUt Rat limiteEI ta, aRy as13eEts aftRe meaRs, metRaEls, te€RAi ues, se ueREes aREI 13Fa€eEluFes af  €8RstruEtiaR ta Be em13layeEI BY CaRtractaF, aAEI  safety 13FeEautiaAs aREI 13FagFams iREiEleRt tRereta;
atRer Elata, iRteF13FetatiaRs, a13iRiaRs, aREI iRfaFmatiaR ESRtaiReEI iR SUER Fe13aFts aF sRawR SF iREli€ateEI iR SUER BFaWiRgs; 9F
aRy CeRtra£teF iRteF13rntatieR ef eF E9RElusieR ElrawR frem aRy Te€RRiEal Data eF aA•,• SUER etRer Elata, iRteF13Fetati0Rs, 013iRi0As er iRfaFmatieR.
Contractor shall not be responsible for removing or remediating any Hazardous Environmental Condition encountered, uncovered, or revealed at the Site unless such removal or remediation is expressly identified in the Contract Documents to be within the scope of the Work.
Contractor shall be responsible for controlling, containing, and duly removing all Constituents of Concern brought to the Site by Contractor, Subcontractors, Suppliers, or anyone else for whom Contractor is responsible, and for any associated costs; and for the costs of removing and remediating any Hazardous Environmental Condition created by the presence of any such Constituents of Concern. Neither Contractor nor any of its successors, assigns, agents, employees, contractors. subcontractors. materialmen, officers. invitees, and representatives shall store, place, generate. manufacture, refine, handle, or locate on the Site a Constituent
of Concern.
If Contractor encounters, uncovers, or reveals a Hazardous Environmental Condition whose removal or remediation is not expressly identified in the Contract Documents as being within the scope of the Work, or if Contractor or anyone for whom Contractor is responsible creates a Hazardous Environmental Condition, then Contractor shall immediately: (1) secure or otherwise isolate such condition; (2) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by Paragraph 7.15); and (3) notify Owner and Engineer (and promptly thereafter confirm such notice in writing). Owner shall promptly consult with Engineer concerning the necessity for Owner to retain a qualified expert to evaluate such condition or take corrective action, if any. Promptly after consulting with Engineer, Owner shall take such actions as are necessary to permit Owner to timely obtain required permits and provide Contractor the written notice required by Paragraph 5.06.F. If Contractor or anyone for whom Contractor is responsible created the Hazardous Environmental Condition in question, then Owner may remove and remediate the Hazardous Environmental Condition, and impose a set-off against payments to account for the associated costs.
Contractor shall not resume Work in connection with such Hazardous Environmental Condition or in any affected area until after Owner has obtained any required permits related thereto, and delivered written notice to Contractor either (1) specifying that such condition

and any affected area is or has been rendered safe for the resumption of Work, or (2) specifying any special conditions under which such Work may be resumed safely.
If Owner and Contractor cannot agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, as a result of such Work stoppage, such special conditions under which Work is agreed to be resumed by Contractor, or any costs or expenses incurred in response to the Hazardous Environmental Condition, then within 30 days of Owner's written notice regarding the resumption of Work, Contractor may submit a Change Proposal, or Owner may impose a set-off. Entitlement to any such adjustment is subject to the provisions of Paragraphs 4.05.D, 4.05.E, 11.07, and 11.08.
If, after receipt of such written notice, Contractor does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then Owner may order the portion of the Work that is in the area affected by such condition to be deleted from the Work, following the contractual change procedures in Article 11. Owner may have such deleted portion of the Work performed by Owner's own forces or others in accordance with Article 8.
Te the fwllest eiEteAt pern1ittea ey Laws aAa RegwlatieAs, 0•1mer shall iAaeFAAify aAa hale harFAless CeAtraeter, SweeaAtraeters, aAa eAgiAeer, aAa the effieers, aireeters, FAeFAeers, partAers, eFApleyees, age Ats, eeAswltaAts, aRa sweeaAtraeters ef eaeh aRa aA•,· ef  theFA, fraFA aAa agaiAst all elaiFAs, eests, lesses, aAa aaFAages (iAelwaiAg ewt Aet liFAitea te all fees aAa eharges afeAgiAeers, arehiteets, atterne•ts, aAa ether prafessieAals, aAa all eawrt, areitratiaA, er ether aispwte reselwtieA eests) arisiAg ewt ef er relatiAg te a Mazaraews eA'JiraAFAeAtal CeAaitieA, previaea that sweh Mazaraews eA•,•ireAFAeAtal CeAaitieA (1) was Aet shewA er iAaieatea iA the Qra•,viAgs,  SpeeificatieAs, ar ether CeAtract QeewFAeAts,  iaeAtifiea as TecRAical Qata eAtitlea te liFAitea reliaAce pwrswaAt te Paragraph S.Qe.B, er iaeAtifiea iA the CeAtract QecwFAeAts ta lie iAclwaea witRiA the scepe ef the Werk, aAa (2) was Aet createa ll•,• CeAtracter er IJy aA'feAe fer wheFA CaAtracter is respeAsillle. NethiAg iA this Paragraph S.Qe.l ellligates OwAer te iAaeFAAify aRy iAaiviawal er eAtity freFA aAa agaiAst the ceAseEJweAces ef that iAai•Jiawal's er eAtity's e•.YA  AegligeAce.
To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify, defend and hold harmless lndemnitees OwAer aAa eAgiAeer, aAa the effieers, airectars, FAeFAllers, partAers, eFAplayees, age Ats, ceAswltaAts, aAa swlleaAtracters ef each aRa aRy ef theFA, from and against all claims, liabilities, suits, liens, demands, costs, losses, interest. expenses, penalties, fines, judgments, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution fees and costs) arising out of or relating to the wholly or partially negligent. reckless, or intentionally wrongful failure to control, contain, or remove a Constituent of Concern brought to the Site by Contractor or by anyone for whom Contractor is responsible, including without limitation, Contractor's successors, assigns, agents, employees, contractors, subcontractors, materialmen, officers, invitees, and representatives, or to a Hazardous Environmental Condition created in whole or in part by Contractor or by anyone for whom Contractor is responsible. Nothing in this Paragraph 5.06.J obligates Contractor to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence.
The provisions of Paragraphs 5.03, 5.04, and 5.05 do not apply to the presence of Constituents of Concern or to a Hazardous Environmental Condition uncovered or revealed at the Site.

ARTICLE 6-BONDS AND INSURANCE

Performance, Payment, and Other Bonds
Contractor shall furnish a performance bond and a payment bond, each in an amount at least equal to the Contract Price, as security for the faithful performance and payment of Contractor's obligations under the Contract. These bonds must remain in effect until one year (for the payment bond) and two years (for the performance bond) after the date when final payment becomes due or until completion of the correction period specified in Paragraph 15.08, whichever is later, except as provided otherwise by Laws or Regulations, the terms of a prescribed bond form, the Supplementary Conditions, or other provisions of the Contract.
Contractor shall also furnish such other bonds (if any) as are required by the Supplementary Conditions or other provisions of the Contract.
All bonds must be in the form included in the Bidding Documents or otherwise specified by Owner prior to execution of the Contract, except as provided otherwise by Laws or Regulations, and must be issued and signed by a surety named in "Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies" as published in Department Circular 570 (as amended and supplemented) by the Bureau of the Fiscal Service, U.S. Department of the Treasury. A bond signed by an agent or attorney-in-fact must be accompanied by a certified copy of that individual's authority to bind the surety. The evidence of authority must show that it is effective on the date the agent or attorney-in-fact signed the accompanying bond. In addition. each bond shall be on an Owner-approved form and the payment bond shall contain the following language: "This Bond is hereby amended so that the provisions and limitations of Section 255.05, including without limitation subsection (6) and the notice and time limitation provisions in subsections (2) and (10). or Sections 713.23 and 713.245. Florida Statutes, whichever are applicable. are incorporated by reference herein."
Contractor shall obtain the required bonds from surety companies that are duly licensed or authorized, in the state or jurisdiction in which the Project is located, to issue bonds in the required amounts.
If the surety on a bond furnished by Contractor is declared bankrupt or becomes insolvent, or the surety ceases to meet the requirements above, then Contractor shall promptly notify Owner and Engineer in writing and shall, within 20 days after the event giving rise to such notification, provide another bond and surety, both of which must comply with the bond and surety requirements above.
If Contractor has failed to obtain a required bond, Owner may exclude the Contractor from the Site and exercise Owner's termination rights under Article 16.
Upon request to Owner from any Subcontractor, Supplier, or other person or entity claiming to have furnished labor, services, materials, or equipment used in the performance of the Work, Owner shall provide a copy of the payment bond to such person or entity.
Upon request to Contractor from any Subcontractor, Supplier, or other person or entity claiming to have furnished labor, services, materials, or equipment used in the performance of the Work, Contractor shall provide a copy of the payment bond to such person or entity.

Insurance-General Provisions
Owner and Contractor shall obtain and maintain insurance as required in this article and in the Supplementary Conditions.
All insurance required by the Contract to be purchased and maintained by Owner or Contractor shall be obtained from insurance companies that are duly licensed or authorized in the state or jurisdiction in which the Project is located to issue insurance policies for the required limits and coverages. Unless a different standard is indicated in the Supplementary Conditions, all companies that provide insurance policies required under this Contract shall have an A.M. Best rating of A-VII or better.
Alternative forms of insurance coverage, including but not limited to self-insurance a-nd "Occupational Accident and Excess Employer's Indemnity Policies," are not sufficient to meet the insurance requirements of this Contract, unless expressly allowed in the Supplementary Conditions.
Prior to commencing the Work and entering any lands upon which the Work shall be performed, Contractor shall deliver to Owner, with copies to each additional insured identified in the Contract, certificates of insurance and endorsements establishing that Contractor has obtained and is maintaining the policies and coverages required by the Contract. Upon request by Owner or any other insured, Contractor shall also furnish other evidence of such required insurance, including but not limited to copies of policies, documentation of applicable self-insured retentions (if allowed) and deductibles, full disclosure of all relevant exclusions, and evidence of insurance required to be purchased and maintained by Subcontractors or Suppliers. In any documentation furnished under this provision, Contractor, Subcontractors, and Suppliers may block out (redact) (1) any confidential premium or pricing information and (2) any wording specific to a project or jurisdiction other than those applicable to this Contract.
Owner shall deliver to Contractor, with copies to each additional insured identified in the Contract, certificates of insurance and endorsements establishing that Owner has obtained and is maintaining the policies and coverages required of Owner by the Contract (if any). Upon request by Contractor or any other insured, Owner shall also provide other evidence of such required insurance (if any), including but not limited to copies of policies, documentation of applicable self-insured retentions (if allowed) and deductibles, and full disclosure of all relevant exclusions. In any documentation furnished under this provision, and subject to Florida's Public Records Law, Owner may block out (redact) (1) any confidential premium or pricing information and (2) any wording specific to a project or jurisdiction other than those relevant to this Contract.
Failure of Owner or Contractor to demand such certificates or other evidence of the other party's full compliance with these insurance requirements, or failure of Owner or Contractor to identify a deficiency in compliance from the evidence provided, will not be construed as a waiver of the other party's obligation to obtain and maintain such insurance.
In addition to the liability insurance required to be provided by Contractor, the Owner, at Owner's option, may purchase and maintain Owner's own liability insurance. Owner's liability policies, if any, operate separately and independently from policies required to be provided by Contractor, and Contractor cannot rely upon Owner's liability policies for any of Contractor's obligations to the Owner, Engineer, or third parties.

EJCDC®" C 700, Standard· General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved.
Page ZS o/77

Contractor shall require:
Subcontractors to purchase and maintain worker's compensation, commercial general liability, and other insurance that is appropriate for their participation in the Project, and to name as additional insureds Owner and Engineer (and any other individuals or entities identified in the Supplementary Conditions as additional insureds on Contractor's liability policies) on each Subcontractor's commercial general liability insurance policy; and
Suppliers to purchase and maintain insurance that is appropriate for their participation in the Project.
If either party does not purchase or maintain the insurance required of such party by the Contract, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage.
If Contractor has failed to obtain and maintain required insurance, Contractor's entitlement to enter or remain at the Site will end immediately, and Owner may impose an appropriate set-off against payment for any associated costs (including but not limited to the cost of purchasing necessary insurance coverage), and exercise Owner's termination rights under Article 16.
Without prejudice to any other right or remedy, if a party has failed to obtain required insurance, the other party may elect (but is in no way obligated) to obtain equivalent insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and the Contract Price will be adjusted accordingly.
Owner does not represent that insurance coverage and limits established in this Contract necessarily will be adequate to protect Contractor or Contractor's interests. Contractor is responsible for determining whether such coverage and limits are adequate to protect its interests, and for obtaining and maintaining any additional insurance that Contractor deems necessary.
The insurance and insurance limits required herein will not be deemed as a limitation on Contractor's liability, or that of its Subcontractors or Suppliers, under the indemnities granted to Owner and other individuals and entities in the Contract or otherwise.
All the policies of insurance required to be purchased and maintained under this Contract will contain a provision or endorsement that the coverage afforded will not be canceled, or renewal refused, until at least W 30 days prior written notice has been given to the purchasing policyholder. Within three days of receipt of any such written notice, the purchasing policyholder shall provide a copy of the notice to each other insured and Engineer.
0. The fact that an entity or individual is named as an additional insured on a particular insurance policy required under this Contract is not intended to constitute a waiver of any rights of any kind, including subrogation rights, claims for indemnification or any other rights or claims.

Contractor's Insurance
Required Insurance: Contractor shall purchase and maintain Worker's Compensation, Commercial General Liability, and other insurance pursuant to the specific requirements of the Supplementary Conditions.

EJCDC® C-700, Stand"ard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved.

General Provisions: The policies ofinsurance required by this Paragraph 6.03 as supplemented must:
include at least the specific coverages required;
be written for not less than the limits provided, or those required by Laws or Regulations, whichever is greater;
remain in effect at least until the Work is complete {as set forth in Paragraph 15.06.D), and longer if expressly required elsewhere in this Contract, and at all times thereafter when Contractor may be correcting, removing, or replacing defective Work as a warranty or correction obligation, or otherwise, or returning to the Site to conduct other tasks arising from the Contract;
apply with respect to the performance of the Work, whether such performance is by Contractor, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable; and
include all necessary endorsements to support the stated requirements.
Additional Insureds: The Contractor's commercial general liability, automobile liability, employer's liability, umbrella or excess, pollution liability, and unmanned aerial vehicle liability policies, if required by this Contract, must:
include and list as additional insureds Owner and Engineer, and any individuals or entities identified as additional insureds in the Supplementary Conditions;
include coverage for the respective supervisors, professional staff, officers, directors, members, partners, employees, agents, subcontractors, and consultants of all such additional insureds;
afford primary coverage to these additional insureds for all claims covered thereby (including as applicable those arising from both ongoing and completed operations);
not seek contribution from insurance maintained by the additional insured; and
as to commercial general liability insurance, apply to additional insureds with respect to liability caused in whole or in part by Contractor's acts or omissions, or the acts and omissions of those working on Contractor's behalf, in the performance of Contractor's operations.
Builder's Risk and Other Property Insurance
Builder's Risk: Unless otherwise provided in the Supplementary Conditions, Contractor shall purchase and maintain builder's risk insurance upon the Work on a completed value basis, in the amount of the Work's full insurable replacement cost (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). The specific requirements applicable to the builder's risk insurance are set forth in the Supplementary Conditions.
Property Insurance for Facilities of Owner Where Work Will Occur: Owner is responsible for obtaining and maintaining property insurance covering each existing structure, building, or facility in which any part of the Work will occur, or to which any part of the Work will attach or be adjoined. Such property insurance will be written on a special perils (all-risk) form, on a

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

replacement cost basis, providing coverage consistent with that required for the builder's risk insurance, and will be maintained until the Work is complete, as set forth in Paragraph 15.06.D.
/2re(i!erty  lns1Hence }er Sull5tent.'elly CafR-(i!lete f'eE.'lities: PFBmptly after Suestantial Campletien, anEI eefere aet1rnl eccupancy er use sf the suestantially cempleteEI Werk, Owner will eetain preperty insurance fer such suestantiall•t cempleteEI Werl1, anEI maintain such prsperty ins1;rance at least 1;ntil the Werk is cemplete, as set ferth in Paragraph 15.Ge.D. Such pFBperty insurance will ee written en a special perils (all risk) farm, en a replacement cest easis, anEI pre11iEle ce11erage censistent •Nith that reeiuireEI fer the euileer's risk insurance. The euilEler's risk insurance may terminate upen written cenfirmatien sf Owner's precurement sf such preperW insurance.
Partial Occupancy ar Use by Owner: If Owner will occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work, as provided in Paragraph 15.04, then Owner (directly, if it is the purchaser of the builder's risk policy, or through Contractor) will provide advance notice of such occupancy or use to the builder's risk insurer, and obtain an endorsement consenting to the continuation of coverage prior to commencing such partial occupancy or use.
Insurance of Other Property; Additional Insurance: If the express insurance provisions of the Contract do not require or address the insurance of a property item or interest, then the entity or individual owning such property item will be responsible for insuring it. If Contractor elects to obtain other special insurance to be included in or supplement the builder's risk or property insurance policies provided under this Paragraph 6.04, it may do so at Contractor's expense.
Property Losses; Subrogation
The builder's risk insurance policy purchased and maintained in accordance with Paragraph 6.04 (or an installation floater policy if authorized by the Supplementary Conditions), will contain provisions to the effect that in the event of payment of any loss or damage the insurer will have no rights of recovery against any insureds thereunder, or against Engineer or its consultants, or their officers, directors, members, partners, employees, agents, consultants, or subcontractors.
Owner anEI Contractor wawe--waives all rights against each ether anEI the respective Owner and its officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages caused by, arising out of, or resulting from any of the perils, risks, or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive-waives all such rights against Engineer and/or Construction Manager, its consultants, all individuals or entities identified in the Supplementary Conditions as builder's risk or installation floater insureds, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, under such policies for losses and damages so caused.
None of the above waivers extends to the rights that any party making such waiver may have to the proceeds of insurance held by Owner or Contractor as trustee or fiduciary, or otherwise payable under any policy so issued.
Any pFBperty insurance pelicy maintaineEI ey O•,vner ce•,ering any less, Elamage, er censeeiuential less ts Owner's ei,isting struetures, euilElings, er facilities in which an · part sf
EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved.

tile 'A'ork will OEEur, or to wlliER an · part of tile Worn will attaER or aEljoin; to aEljaEent struEtures, iluilElings, or fadlities of Owner; or to part or all of tile EOmpleteEI or suilstantially EOmpleteEI Work, Eluring partial OEEUpanEy  or use pursuant to Paragrapll 1§.04, after Suilstantial Completion pursuant to Paragrapll 1§.03, or after final pa•1ment pursuant to Paragrapll 1§.De, •,•,•ill EOntain provisions to tile effoEt that in tile event of payment of any loss or Elamage tile insurer will lla\'e no rights of reEOvery against any insureEls tllereunEler, or against ContraEtor, SuilEOntraEtors, or Engineer, or tile offiEers, ElireEtors, memllers, partners, employees, agents, Eonsultants, or suilEontraEtors of eaER anEI any of them, anel that tile insureel is alloweel to wai\•e tile insurer's rigl<lts of sullrogation in a written EontraEt eimEuteel prior to tile loss, elamage, or EOnseE1uential loss.
Owner wai•1es all rights against ContraEtor, SuilEontraEtors, anel Engineer, anel tl<le offiEers, elireEtors, memilers, partners, emplo·,ees, agents, Eonsultants anel suilEOntraEtors of eaER anel any of tl<lem, for all losses anel elamages Eauseel ily, arising out of, or resulting from fire or any of tile perils, risl1s, or Eauses of loss EovereEI ily suER poliEies.
The waivers in this Paragraph 6.05 include the waiver of rights due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to Owner's property or the Work caused by, arising out of, or resulting from fire or other insured peril, risk, or cause of loss.
Contractor shall be responsible for assuring that each Subcontract contains provisions whereby the Subcontractor waives all rights against Owner, Contractor, all individuals or entities identified in the Supplementary Conditions as insureds, the Engineer and its consultants, and the officers, directors, members, partners, employees, agents, consultants, and subcontractors of each and any of them, for all losses and damages caused by, arising out of, relating to, or resulting from fire or other peril, risk, or cause of loss covered by builder's risk insurance, installation floater, and any other property insurance applicable to the Work.
Receipt and Application of Property Insurance Proceeds
Any insured loss under the builder's risk and other policies of property insurance required by Paragraph 6.04 will be adjusted and settled with the named insured that purchased the policy. Such named insured shall act as fiduciary for the other insureds, and give notice to such other insureds that adjustment and settlement of a claim is in progress. Any other insured may state its position regarding a claim for insured loss in writing within 15 days after notice of such
claim.
Proceeds for such insured losses may be made payable by the insurer either jointly to multiple insureds, or to the named insured that purchased the policy in its own right and as fiduciary for other insureds, subject to the requirements of any applicable mortgage clause. A named insured receiving insurance proceeds under the builder's risk and other policies of insurance required by Paragraph 6.04 shall maintain such proceeds in a segregated account, and distribute such proceeds in accordance with such agreement as the parties in interest may reach, or as otherwise required under the dispute resolution provisions of this Contract or applicable Laws and Regulations.
If no other special agreement is reached, Contractor shall repair or replace the damaged Work, using allocated insurance proceeds.

EJCDC C 700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

ARTICLE 7-CONTRACTOR'S RESPONSIBILITIES

Contractor's Means and Methods of Construction
Contractor shall be solely responsible for the means, methods, techniques, sequences, and procedures of construction.
If the Contract Documents note, or Contractor determines, that professional engineering or other design services are needed to carry out Contractor's responsibilities for construction means, methods, techniques, sequences, and procedures, or for Site safety, then Contractor shall cause such services to be provided by a properly licensed design professional, at Contractor's expense. Such services are not Owner-delegated professional design services under this Contract, and neither Owner nor Engineer has any responsibility with respect to
Contractor's determination of the need for such services, (2) the qualifications or licensing of the design professionals retained or employed by Contractor, (3) the performance of such services, or (4) any errors, omissions, or defects in such services.
Supervision and Superintendence
Contractor shall supervise, inspect, and direct the Work competently and efficiently, devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Contract Documents.
At all times during the progress of the Work, Contractor shall assign a competent resident superintendent who will not be replaced without written notice to Owner and Engineer except under extraordinary circumstances.
Labor; Working Hours
Contractor shall provide competent, suitably qualified personnel to survey and lay out the Work and perform construction as required by the Contract Documents. Contractor shall maintain good discipline and order at the Site.
Contractor shall be fully responsible to Owner and Engineer for all acts and omissions of Contractor's employees; of Suppliers and Subcontractors, and their employees; and of any other individuals or entities performing or furnishing any of the Work, just as Contractor is responsible for Contractor's own acts and omissions.
Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site will-may be performed during regular working hours, Monday through GaRtraEtar will Rat 13erferffi 'Nark aR a Sat11raay, Sunday, er aRy legal including any holiday as Contractor may choose to do so. Contractor may perform Work outside regular working hours or on Saturdays, Sundays, or legal holidays only with Owner's written consent, which will not be unreasonably withheld.
The Contractor shall be responsible. whether previously scheduled or not. for the payment of Owner's cost of overtime inspection outside of the working hours described above. The Contractor will be required to pay for overtime inspection services on unscheduled work, work which is delayed by the Contractor's suppliers or subcontractors and any other work performed for the convenience of the Contractor as he deems necessary to meet the schedule.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright@ 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

Services, Materials, and Equipment
Unless otherwise specified in the Contract Documents, Contractor shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start up, and completion of the Work, whether or not such items are specifically called for in the Contract Documents.
All materials and equipment incorporated into the Work must be new and of good quality, except as otherwise provided in the Contract Documents. All special warranties and guarantees required by the Specifications will expressly run to the benefit of Owner. If required by Engineer, Contractor shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment.
All materials and equipment must be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Documents.
"Or Equals"
Contractor's Request; Governing Criteria: Whenever an item of equipment or material is specified or described in the Contract Documents by using the names of one or more proprietary items or specific Suppliers, the Contract Price has been based upon Contractor furnishing such item as specified. The specification or description of such an item is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or equal" item is permitted, Contractor may request that Engineer authorize the use of other items of equipment or material, or items from other proposed Suppliers, under the circumstances described below.
If Engineer in its sole discretion determines that an item of equipment or material proposed by Contractor is functionally equal to that named and sufficiently similar so that no change in related Work will be required, Engineer will deem it an "or equal" item. For the purposes of this paragraph, a proposed item of equipment or material will be considered functionally equal to an item so named if:
in the exercise of reasonable judgment Engineer determines that the proposed item:
is at least equal in materials of construction, quality, durability, appearance, strength, and design characteristics;
will reliably perform at least equally well the function and achieve the results imposed by the design concept of the completed Project as a functioning whole;
has a proven record of performance and availability of responsive service; and
is not objectionable to Owner.
Contractor certifies that, if the proposed item is approved and incorporated into the Work:
there will be no increase in cost to the Owner or increase in Contract Times; and

the item will conform substantially to the detailed requirements of the item named in the Contract Documents.
Contractor's Expense: Contractor shall provide all data in support of any proposed "or equal" item at Contractor's expense.
Engineer's Evaluation and Determination: Engineer will be allowed a reasonable time to evaluate each "or-equal" request. Engineer may require Contractor to furnish additional data about the proposed "or-equal" item. Engineer will be the sole judge of acceptability. No "or­ equal" item will be ordered, furnished, installed, or utilized until Engineer's review is complete and Engineer determines that the proposed item is an "or-equal," which will be evidenced by an approved Shop Drawing or other written communication. Engineer will advise Contractor in writing of any negative determination.
Effect af Engineer's Determination: Neither approval nor denial of an "or-equal" request will result in any change in Contract Price. The Engineer's denial of an "or-equal" request will be final and binding, and may not be reversed through an appeal under any provision of the Contract.
Treatment as a Substitution Request: If Engineer determines that an item of equipment or material proposed by Contractor does not qualify as an "or-equal" item, Contractor may request that Engineer consider the item a proposed substitute pursuant to Paragraph 7.06.
Substitutes
Contractor's Request; Governing Criteria: Unless the specification or description of an item of equipment or material required to be furnished under the Contract Documents contains or is followed by words reading that no substitution is permitted, Contractor may request that Engineer authorize the use of other items of equipment or material under the circumstances described below. To the extent possible such requests must be made before commencement of related construction at the Site.
Contractor shall submit sufficient information as provided below to allow Engineer to determine if the item of material or equipment proposed is functionally equivalent to that named and an acceptable substitute therefor. Engineer will not accept requests for review of proposed substitute items of equipment or material from anyone other than Contractor.
The requirements for review by Engineer will be as set forth in Paragraph 7.06.B, as supplemented by the Specifications, and as Engineer may decide is appropriate under the circumstances.
Contractor shall make written application to Engineer for review of a proposed substitute item of equipment or material that Contractor seeks to furnish or use. The application:
will certify that the proposed substitute item will:
perform adequately the functions and achieve the results called for by the general design;
be similar in substance to the item specified; and
be suited to the same use as the item specified.

will state:
the extent, if any, to which the use of the proposed substitute item will necessitate a change in Contract Times;
whether use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any other direct contract with Owner for other work on the Project) to adapt the design to the proposed substitute item; and
whether incorporation or use of the proposed substitute item in connection with the Work is subject to payment of any license fee or royalty.
will identify:
all variations of the proposed substitute item from the item specified; and
available engineering, sales, maintenance, repair, and replacement services.
will contain an itemized estimate of all costs or credits that will result directly or indirectly from use of such substitute item, including but not limited to changes in Contract Price, shared savings, costs of redesign, and claims of other contractors affected by any resulting change.
Engineer's Evaluation and Determination: Engineer will be allowed a reasonable time to evaluate each substitute request, and to obtain comments and direction from Owner. Engineer may require Contractor to furnish additional data about the proposed substitute item. Engineer will be the sole judge of acceptability. No substitute will be ordered, furnished, installed, or utilized until Engineer's review is complete and Engineer determines that the proposed item is an acceptable substitute. Engineer's determination will be evidenced by a Field Order or a proposed Change Order accounting for the substitution itself and all related impacts, including changes in Contract Price or Contract Times. Engineer will advise Contractor in writing of any negative determination.
Special Guarantee: Owner may require Contractor to furnish at Contractor's expense a special performance guarantee or other surety with respect to any substitute.
Reimbursement of Engineer's Cost: Engineer will record Engineer's costs in evaluating a substitute proposed or submitted by Contractor. Whether or not Engineer approves a substitute so proposed or submitted by Contractor, Contractor shall reimburse Owner for the reasonable charges of Engineer for evaluating each such proposed substitute. Contractor shall also reimburse Owner for the reasonable charges of Engineer for making changes in the Contract Documents (or in the provisions of any other direct contract with Owner) resulting from the acceptance of each proposed substitute.
Contractor's Expense: Contractor shall provide all data in support of any proposed substitute at Contractor's expense.
Effect of Engineer's Determination: If Engineer approves the substitution request, Contractor shall execute the proposed Change Order and proceed with the substitution. The Engineer's denial of a substitution request will be final and binding, and may not be reversed through an appeal under any provision of the Contract. Contractor may challenge the scope of reimbursement costs imposed under Paragraph 7.06.D, by timely submittal of a Change Proposal.

Concerning Subcontractors and Suppliers
Contractor may retain Subcontractors and Suppliers for the performance of parts of the Work. Such Subcontractors and Suppliers must be acceptable to Owner. The Contractor's retention of a Subcontractor or Supplier for the performance of parts of the Work will not relieve Contractor's obligation to Owner to perform and complete the Work in accordance with the Contract Documents.
Contractor shall retain specific Subcontractors and Suppliers for the performance of designated parts of the Work if required by the Contract to do so.
Subsequent to the submittal of Contractor's Bid or final negotiation of the terms of the Contract, Owner may not require Contractor to retain any Subcontractor or Supplier to furnish or perform any of the Work against which Contractor has reasonable objection.
Prior to entry into any binding subcontract or purchase order, Contractor shall submit to Owner the identity of the proposed Subcontractor or Supplier (unless Owner has already deemed such proposed Subcontractor or Supplier acceptable during the bidding process or otherwise). Such proposed Subcontractor or Supplier shall be deemed acceptable to Owner unless Owner raises a substantive, reasonable objection within 5 days.
Owner may require the replacement of any Subcontractor or Supplier. Owner also may require Contractor to retain specific replacements; provided, however, that Owner may not require a replacement to which Contractor has a reasonable objection. If Contractor has submitted the identity of certain Subcontractors or Suppliers for acceptance by Owner, and Owner has accepted it (either in writing or by failing to make written objection thereto), then Owner may subsequently revoke the acceptance of any such Subcontractor or Supplier so identified solely on the basis of substantive, reasonable objection after due investigation. Contractor shall submit an acceptable replacement for the rejected Subcontractor or
Supplier.
If Owner requires the replacement of any Subcontractor or Supplier retained by Contractor to perform any part of the Work, then Contractor shall be entitled to an adjustment in Contract Price or Contract Times, with respect to the replacement; and Contractor shall initiate a Change Proposal for such adjustment within 30 days of Owner's requirement of replacement.
No acceptance by Owner of any such Subcontractor or Supplier, whether initially or as a replacement, will constitute a waiver of the right of Owner to the completion of the Work in accordance with the Contract Documents.
On a monthly basis, Contractor shall submit to Engineer a complete list of all Subcontractors and Suppliers having a direct contract with Contractor, and of all other Subcontractors and Suppliers known to Contractor at the time of submittal.
Contractor shall be solely responsible for scheduling and coordinating the work of Subcontractors and Suppliers.
The divisions and sections of the Specifications and the identifications of any Drawings do not control Contractor in dividing the Work among Subcontractors or Suppliers, or in delineating the Work to be performed by any specific trade.

EJCOC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

All Work performed for Contractor by a Subcontractor or Supplier must be pursuant to an appropriate contractual agreement that specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract for the benefit of Owner and Engineer.
Owner may furnish to any Subcontractor or Supplier, to the extent practicable, information about amounts paid to Contractor for Work performed for Contractor by the Subcontractor or Supplier.
Contractor shall restrict all Subcontractors and Suppliers from communicating with Engineer or Owner, except through Contractor or in case of an emergency, or as otherwise expressly allowed in this Contract.
Patent Fees and Royalties
Contractor shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If an invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if, to the actual knowledge of Owner or Engineer, its use is subject to patent rights or copyrights calling for the payment of any license fee or royalty to others, the existence of such rights will be disclosed in the Contract Documents.
Te tile hillest eiaent 13eFA1itteel  lly  Laws aRel RegtilatieRs, O'lmer shall iReleA1Rify aRel llelel llarA1less CeRtracter, aRa its efi'iEers, aireeters, A1eA1llers, 13artRers, eA113leyees,  ageRts, eORSIJltaRtS,  aRa SIJBeORtraetoFS, fFOA1  aRa agaiRst all daiA1S, easts, losses, aRa aaA1ages (iRd1JaiRg Bllt Rot 1iA1iteel to all fees aRel ellarges of eRgiReers, arelliteets, attemeys, aRel other 13rofessi0Rals, aRel all eotirt or arllitratioR or other elis131Jte  resol1JtioR easts) arisiRg 0llt ef er relatiRg to any iRfriRgeA1eRt of 13ateRt  rights or 60fi)'frigllts iReieleRt to  tile 1Jse  iR tile 13erforA1aRee of tile 'Nork er res1JltiRg freA1 tile iReer13eratieR iR tile WerlE ef aRy iR•;eRtieR, elesigR, 13reeess, 13rea1Jet, er ele•Jiee s13edfieel iR tile CeRtraet Dee1JA1eRts, llllt Rat ieleRtifieel as lleiRg st1lljeet te 13ayA1eRt ef  aRy lieeRse fee er reyalty te others re llired lly 13ateRt rights or
60fil'1'rigllts.
To the fullest extent permitted by Laws and Regulations, Contractor shall indemnify, defend and hold harmless lndemnitees OwRer aRel fRgineer, aRd tile o#ieers, elireetors, A1eA1llers, 13artRers, eA113leyees, ageRts, eoRs1JltaRts ana st1lle0Rtraetors of eaell aRd aRy of tlleA1, from and against all claims, liabilities. suits. liens. demands. costs, losses, interest. expenses. penalties. fines. judgments. and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution fees or costs) whether monetary or otherwise. arising. in whole or in part. out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents, to the extent such infringement is caused in whole or in part by the negligent. reckless. or intentionally wrongful actions of the Contractor or those for which Contractor is responsible including without limitation. Contractor's successors. assigns. agents. employees. contractors. subcontractors. materialmen. officers. invitees. and representatives.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Ptofessional Engineers, American Council of Engineering Companies,

Permits
Unless otherwise provided in the Contract Documents, Contractor shall obtain and pay for all construction permits, licenses, and certificates of occupancy. Owner shall assist Contractor, when necessary, in obtaining such permits and licenses. Contractor shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of the submission of Contractor's Bid (or when Contractor became bound under a negotiated contract). Owner CeAtracter shall pay all charges and fees of utility owners for connections for providing permanent service to the Work, iAcludiAg witReut limitatieA water aAd electrical meters {if applicalJlel. iAstallatieA fees, electrical iAspectieA fees, aAd temperary ser•;ices aAd utilities. CeAtracter sRall additieAally pre>Jide all sigAage reauired IJy applicalJle permits aAd gevemmeAtal autRerities.
Owner and Contractor acknowledge and agree that Owner intends to turn over all.or a portion of the Work upon completion to Clay County, Florida, for ownership and maintenance. To the extent that Owner intends to turn over any portion of the Work to another governmental entity for ownership or other purposes. Contractor agrees at its sole expense to take all actions necessary (including but not limited to providing all warranties, improvement bonds, and close-out documents required by the governmental entity even if such requirements are beyond what is required herein) to ensure that the recipient governmental entity accepts the Work.
Taxes
A. Contractor shall pay all sales, consumer, use, and other similar taxes and assessments required to be paid by Contractor in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work.
Laws and Regulations
Contractor shall give all notices required by and shall comply with all Laws and Regulations applicable to the performance of the Work. Neither Owner nor Engineer shall be responsible for monitoring Contractor's compliance with any Laws or Regulations.
If Contractor or those for whom Contractor is responsible performs any Work or takes any other action knowing or having reason to know that it is contrary to Laws or Regulations, Contractor shall bear all resulting costs and losses, and shall indemnify. defend, and hold harmless lndemnitees O·1mer aAd EAgiAeer, aAd tRe efficers, direEters, memlJers, 13artAers, em13leyees, ageAts, ceAsultaAts, aAd sulJceAtracters ef eacR aAd aA'f ef tRem, from and against all claims, liabilities. suits. liens, demands, costs, losses, interest. expenses. penalties, fines. judgments. and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution fees or costs) whether monetary or otherwise arising, in whole or in part. out of or relating to such Work or other action. It is Rat CeAtraEter's respeAsillility te mal1e certaiA \Rat
\Re Werl( descrilJed iA \Re CeAtraEt DecumeAts is iA accerdaAce witR La'.',!5 aAd RegulatieAs, IJut tRis dees Rat relieve CeAtracter ef its elJligatieAs uAder ParagrapR 3.Q3.
Owner or Contractor may give written notice to the other party of any changes after the submission of Contractor's Bid (or after the date when Contractor became bound under a negotiated contract) in Laws or Regulations having an effect on the cost or time of performance of the Work, including but not limited to changes in Laws or Regulations having an effect on procuring permits and on sales, use, value-added, consumption, and other similar

taxes. If Owner and Contractor are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times resulting from such changes, then within 30 days of such written notice Contractor may submit a Change Proposal, or Owner may initiate a Claim.
Record Documents
Contractor shall maintain in a safe place at the Site one printed record copy of all Drawings, Specifications, Addenda, Change Orders, Work Change Directives, Field Orders, written interpretations and clarifications, and approved Shop Drawings. Contractor shall keep such record documents in good order and annotate them to show changes made during construction. These record documents, together with all approved Samples, will be available to Engineer for reference. Upon completion of the Work, Contractor shall deliver these record documents to Engineer.
Safety and Protection
Contractor shall be solely responsible for initiating, maintaining, and supervising all safety precautions and programs in connection with the Work. Such responsibility does not relieve Subcontractors of their responsibility for the safety of persons or property in the performance of their work, nor for compliance with applicable safety Laws and Regulations.
Contractor shall designate a qualified and experienced safety representative whose duties and responsibilities are the prevention of Work-related accidents and the maintenance and supervision of safety precautions and programs.
Contractor shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury, or loss to:
all persons on the Site or who may be affected by the Work;
all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and
other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, other work in progress, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction.
All damage, injury, or loss to any property referred to in Paragraph 7.13.C.2 or 7.13.C.3 caused, directly or indirectly, in whole or in part, by Contractor, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by Contractor at its expense (except damage or loss attributable to the fault of Drawings or Specifications or to the acts or omissions of Owner or Engineer or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of Contractor or any Subcontractor, Supplier, or other individual or entity directly or indirectly employed by any of them).
Contractor shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persons or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. Among other requirements, the Contractor or Subcontractor performing trench excavation work on
	the Project shall comply with the applicable trench safety standards.	

Contractor shall notify Owner; the owners of adjacent property; the owners of Underground Facilities and other utilities (if the identity of such owners is known to Contractor); and other contractors and utility owners performing work at or adjacent to the Site, in writing, when Contractor knows that prosecution of the Work may affect them, and shall cooperate with them in the protection, removal, relocation, and replacement of their property or work in progress.
Contractor shall comply with the applicable requirements of Owner's safety programs, if any. Any Owner's safety programs that are applicable to the Work are identified or included in the Supplementary Conditions or Specifications.
Contractor shall inform Owner and Engineer of the specific requirements of Contractor's safety program with which Owner's and Engineer's employees and representatives must comply while at the Site.
Contractor's duties and responsibilities for safety and protection will continue until all the Work is completed, Engineer has issued a written notice to Owner and Contractor in accordance with Paragraph 15.06.C that the Work is acceptable, and Contractor has left the Site (except as otherwise expressly provided in connection with Substantial Completion).
Contractor's duties and responsibilities for safety and protection will resume whenever Contractor or any Subcontractor or Supplier returns to the Site to fulfill warranty or correction obligations, or to conduct other tasks arising from the Contract Documents.
Hazard Communication Programs
Contractor shall be responsible for coordinating any exchange of safety data sheets (formerly known as material safety data sheets) or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations.
Emergencies
In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, Contractor is obligated to act to prevent damage, injury, or loss. Contractor shall give Engineer prompt written notice if Contractor believes that any significant changes in the Work or variations from the Contract Documents have been caused by an emergency, or are required as a result of Contractor's response to an emergency. If Engineer determines that a change in the Contract Documents is required because of an emergency or Contractor's response, a Work Change Directive or Change Order will be issued.
Submittals
Shop Drawing and Sample Requirements
Before submitting a Shop Drawing or Sample, Contractor shall:
review and coordinate the Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Documents;
determine and verify:
1} all field measurements, quantities, dimensions, specified performance and design criteria, installation requirements, materials, catalog numbers, and similar information with respect to the Submittal;

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reseNed.

the suitability of all materials and equipment offered with respect to the indicated application, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; and
all information relative to Contractor's responsibilities for means, methods, techniques, sequences, and procedures of construction, and safety precautions and programs incident thereto;
confirm that the Submittal is complete with respect to all related data included in the Submittal.
Each Shop Drawing or Sample must bear a stamp or specific written certification that Contractor has satisfied Contractor's obligations under the Contract Documents with respect to Contractor's review of that Submittal, and that Contractor approves the Submittal.
With each Shop Drawing or Sample, Contractor shall give Engineer specific written notice of any variations that the Submittal may have from the requirements of the Contract Documents. This notice must be set forth in a written communication separate from the Submittal; and, in addition, in the case of a Shop Drawing by a specific notation made on the Shop Drawing itself.
Submittal Procedures for Shop Drawings and Samples: Contractor shall label and submit Shop Drawings and Samples to Engineer for review and approval in accordance with the accepted Schedule of Submittals.
Shop Drawings
Contractor shall submit the number of copies required in the Specifications.
Data shown on the Shop Drawings must be complete with respect to quantities, dimensions, specified performance and design criteria, materials, and similar data to show Engineer the services, materials, and equipment Contractor proposes to provide, and to enable Engineer to review the information for the limited purposes required by Paragraph 7.16.C.
Samples
Contractor shall submit the number of Samples required in the Specifications.
Contractor shall clearly identify each Sample as to material, Supplier, pertinent data such as catalog numbers, the use for which intended and other data as Engineer may require to enable Engineer to review the Submittal for the limited purposes required by Paragraph 7.16.C.
Where a Shop Drawing or Sample is required by the Contract Documents or the Schedule of Submittals, any related Work performed prior to Engineer's review and approval of the pertinent submittal will be at the sole expense and responsibility of Contractor.
Engineer's Review of Shop Drawings and Samples
Engineer will provide timely review of Shop Drawings and Samples in accordance with the accepted Schedule of Submittals. Engineer's review and approval will be only to determine if the items covered by the Submittals will, after installation or incorporation in the Work, comply with the requirements of the Contract Documents, and be

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved.

compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents.
Engineer's review and approval will not extend to means, methods, techniques, sequences, or procedures of construction, or to safety precautions or programs incident thereto.
Engineer's review and approval of a separate item as such will not indicate approval of the assembly in which the item functions.
Engineer's review and approval of a Shop Drawing or Sample will not relieve Contractor from responsibility for any variation from the requirements of the Contract Documents unless Contractor has complied with the requirements of Paragraph 7.16.A.3 and Engineer has given written approval of each such variation by specific written notation thereof incorporated in or accompanying the Shop Drawing or Sample. Engineer will document any such approved variation from the requirements of the Contract Documents in a Field Order or other appropriate Contract modification.
Engineer's review and approval of a Shop Drawing or Sample will not relieve Contractor from responsibility for complying with the requirements of Paragraphs 7.16.A and B.
Engineer's review and approval of a Shop Drawing or Sample, or of a variation from the requirements of the Contract Documents, will not, under any circumstances, change the Contract Times or Contract Price, unless such changes are included in a Change Order.
Neither Engineer's receipt, review, acceptance, or approval of a Shop Drawing or Sample will result in such item becoming a Contract Document.
Contractor shall perform the Work in compliance with the requirements and commitments set forth in approved Shop Drawings and Samples, subject to the provisions of Paragraph 7.16.C.4.
Resubmitta/ Procedures for Shop Drawings and Samples
Contractor shall make corrections required by Engineer and shall return the required number of corrected copies of Shop Drawings and submit, as required, new Samples for review and approval. Contractor shall direct specific attention in writing to revisions other than the corrections called for by Engineer on previous Submittals.
Contractor shall furnish required Shop Drawing and Sample submittals with sufficient information and accuracy to obtain required approval of an item with no more than two resubmittals. Engineer will record Engineer's time for reviewing a third or subsequent resubmittal of a Shop Drawing or Sample, and Contractor shall be responsible for Engineer's charges to Owner for such time. Owner may impose a set-off against payments due Contractor to secure reimbursement for such charges.
If Contractor requests a change of a previously approved Shop Drawing or Sample, Contractor shall be responsible for Engineer's charges to Owner for its review time, and Owner may impose a set-off against payments due Contractor to secure reimbursement for such charges, unless the need for such change is beyond the control of Contractor.

EJCDC® C 700, Standard General Conditions of the Construction Contract.

Submittals Other than Shop Drawings, Samples, and Owner-Delegated Designs
The following provisions apply to all Submittals other than Shop Drawings, Samples, and Owner-delegated designs:
Contractor shall submit all such Submittals to the Engineer in accordance with the Schedule of Submittals and pursuant to the applicable terms of the Contract Documents.
Engineer will provide timely review of all such Submittals in accordance with the Schedule of Submittals and return such Submittals with a notation of either Accepted or Not Accepted. Any such Submittal that is not returned within the time established in the Schedule of Submittals will be deemed accepted.
Engineer's review will be only to determine if the Submittal is acceptable under the requirements of the Contract Documents as to general form and content of the Submittal.
If any such Submittal is not accepted, Contractor shall confer with Engineer regarding the reason for the non-acceptance, and resubmit an acceptable document.
Procedures for the submittal and acceptance of the Progress Schedule, the Schedule of Submittals, and the Schedule of Values are set forth in Paragraphs 2.03. 2.04, and 2.05.
Owner-delegated Designs: Submittals pursuant to Owner-delegated designs are governed by the provisions of Paragraph 7.19.
Contractor's General Warranty and Guarantee
Contractor warrants and guarantees to Owner that all Work will be in accordance with the Contract Documents and will not be defective. Engineer is entitled to rely on Contractor's warranty and guarantee.
Owner's rights under this warranty and guarantee are in addition to, and are not limited by, Owner's rights under the correction period provisions of Paragraph 15.08. The time in which Owner may enforce its warranty and guarantee rights under this Paragraph 7.17 is limited only by applicable Laws and Regulations restricting actions to enforce such rights; provided, however, that after the end of the correction period under Paragraph 15.08:
Owner shall give Contractor written notice of any defective Work within 60 days of the discovery that such Work is defective; and
Such notice will be deemed the start of an event giving rise to a Claim under Paragraph 12.01.B, such that any related Claim must be brought within 30 days of the notice.
Contractor's warranty and guarantee hereunder excludes defects or damage caused by:
abuse, or improper modification, maintenance, or operation, by persons other than Contractor, Subcontractors, Suppliers, or any other individual or entity for whom Contractor is responsible; or
normal wear and tear under normal usage.
Contractor's obligation to perform and complete the Work in accordance with the Contract Documents is absolute. None of the following will constitute an acceptance of Work that is

EJCDC® C-700, Standard General Conditions of the Construction Contract.

not in accordance with the Contract Documents, a release of Contractor's obligation to perform the Work in accordance with the Contract Documents, or a release of Owner's warranty and guarantee rights under this Paragraph 7.17:
Observations by Engineer;
Recommendation by Engineer or payment by Owner of any progress or final payment;
The issuance of a certificate of Substantial Completion by Engineer or any payment related thereto by Owner;
Use or occupancy of the Work or any part thereof by Owner;
Any review and approval of a Shop Drawing or Sample submittal;
The issuance of a notice of acceptability by Engineer or other similar acceptance by Owner;
The end of the correction period established in Paragraph 15.08;
Any inspection, test, or approval by others; or
Any correction of defective Work by Owner.
If the Contract requires the Contractor to accept the assignment of a contract entered into by Owner, then the specific warranties, guarantees, and correction obligations contained in the assigned contract will govern with respect to Contractor's performance obligations to Owner for the Work described in the assigned contract.
Contractor shall assign to Owner all warranties extended to Contractor by material suppliers and subcontractors. If an assignment of warranty requires the material supplier or subcontractor to consent to same. then Contractor shall secure the material supplier's or subcontractor's consent to assign said warranties to Owner.
The warranties provided in this Contract shall be in addition to and not in limitation of any other warranty or remedy required by law.

Indemnification
To Hie fullest ei(teAt permittea by ba·....s aAa RegulatioAs, aAa iA aaaitioA to aAy other obligatioAs of CoAtraetor UAaer tile CoAtraet or otherwise, CoAtraetor shall iAaemAify ana llola harmless OwAer aAa eAgiAeer, aAa tile offieers, elireetors, members, partAers, emplo·,·ees, ageAts, eoAsultaAts aAel subeoAtraetors of eaei'l aAel aAy of ti'lem, from losses, elamages, easts, aRel juelgmeAts (iAelueliAg but Rot limiteel to all fees aRel ei'larges of eAgiAeers, are"1iteets, attorneys, aAel oti'ler professioAals, aAel all eourt or arbitratioA or oti'ler aispute resolutioA easts) arisiAg from ti'lirel party elaims or aetioAs relatiAg to or resultiAg from ti'le performaAee or fumisi'liAg of ti'le '.6/orl(, pro,·ielea ti'lat aAy suei'l elaim, aetion, loss, east, juelgmeAt or elamage is attrisutable to soelily iAjury, sielrness, elisease, or eleati'l, or to elamage to or elestruetioA of taAgible property (oti'ler ti'laA ti'le 'Nori( itself), iAelueliAg ti'le loss of use resultiAg ti'lerefrom, sut oAly to ti'le e1(teAt eauseel B'f any AegligeAt aet or omissioA of CoAtraetor, aAy SuseoAtraetor, aAy Supplier, or aAy iAai·Jielual or eAtity elireetly or iAelireetly employee! sy JA'f of ti'lem to perform aRy of ti'le Worl(, or JA'f0Ae for wl'lose aets aAy of tl'lem
ma·t se liable.

To the fullest extent permitted by Laws and Regulations, and in addition to any other obligations of Contractor under the Contract or otherwise. Contractor shall indemnify, hold harmless. and defend Owner. Engineer,	[Landowner) and their respective members. parents. partners, subsidiaries. affiliates. officers. directors. supervisors, managers. attorneys. engineers. consultants. agents. subcontractors and employees, of each and any of all of the foregoing entities and individuals (together, "lndemnitees") from all claims. liabilities, damages. losses, fees. and costs, including, but not limited to, reasonable attorney's fees. to the extent caused, in part or in whole. by the negligence. recklessness. or intentionally wrongful misconduct of the Contractor. or any Subcontractor, any Supplier. or any individual or entity directly or indirectly employed or used by any of them to perform any of the Work.
With respect to any indemnification, defense. and hold harmless provision in this Contract. nothing in this Contract shall be construed to require Contractor to indemnify the District for the District's percentage of fault if the District is adjudged to be more than 50% at fault for any claims against the District and Contractor as jointly liable parties; however. Contractor shall indemnify the District for any and all percentage of fault attributable to Contractor for claims against the District, regardless whether the District is adjudged to be more or less than 50% at fault.
To the extent required by Florida law to make the provisions of any indemnification. defense or hold harmless provision of this Contract enforceable (and otherwise this sentence does not apply). such indemnification. hold harmless and defense obligation shall be $10.000.000.00 (or the amount of any applicable insurance coverage. if such amount is greater). the amount of which bears a reasonable commercial relationship to the Contract and was part of the project specifications or bid documents. In the event that any indemnification, defense or hold harmless provision of this Contract is determined to be unenforceable. the provision shall be reformed to give the provision the maximum effect allowed by Florida law and for the benefit of the lndemnitees. The Contractor shall ensure that any and all Subcontractors. and Suppliers. include this express paragraph for the benefit of the lndemnitees.
In any and all claims against Owner or Engineer, or any of their officers, directors, members, partners, employees, agents, consultants, or subcontractors, by any employee (or the survivor or personal representative of such employee) of Contractor, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under Paragraph 7.18.A will not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for Contractor or any such Subcontractor, Supplier, or other individual or entity under workers' compensation acts, disability benefit acts, or other employee benefit acts.
Delegation of Professional Design Services
Owner may require Contractor to provide professional design services for a portion of the Work by express delegation in the Contract Documents. Such delegation will specify the performance and design criteria that such services must satisfy, and the Submittals that Contractor must furnish to Engineer with respect to the Owner-delegated design.
Contractor shall cause such Owner-delegated professional design services to be provided pursuant to the professional standard of care by a properly licensed design professional, whose signature and seal must appear on all drawings, calculations, specifications,

certifications, and Submittals prepared by such design professional. Such design professional must issue all certifications of design required by Laws and Regulations.
If a Shop Drawing or other Submittal related to the Owner-delegated design is prepared by Contractor, a Subcontractor, or others for submittal to Engineer, then such Shop Drawing or other Submittal must bear the written approval of Contractor's design professional when submitted by Contractor to Engineer.
Owner and Engineer shall be entitled to rely upon the adequacy, accuracy, and completeness of the services, certifications, and approvals performed or provided by the design professionals retained or employed by Contractor under an Owner-delegated design, subject to the professional standard of care and the performance and design criteria stated in the Contract Documents.
Pursuant to this Paragraph 7.19, Engineer's review, approval, and other determinations regarding design drawings, calculations, specifications, certifications, and other Submittals furnished by Contractor pursuant to an Owner-delegated design will be only for the following limited purposes:
Checking for conformance with the requirements of this Paragraph 7.19;
Confirming that Contractor (through its design professionals) has used the performance and design criteria specified in the Contract Documents; and
Establishing that the design furnished by Contractor is consistent with the design concept expressed in the Contract Documents.
Contractor shall not be responsible for the adequacy of performance or design criteria specified by Owner or Engineer.
Contractor is not required to provide professional services in violation of applicable Laws and Regulations.

ARTICLE 8-OTHER WORK AT THE SITE

Other Work
In addition to and apart from the Work under the Contract Documents, the Owner may perform other work at or adjacent to the Site. Such other work may be performed by Owner's employees, or through contracts between the Owner and third parties. Owner may also arrange to have third-party utility owners perform work on their utilities and facilities at or adjacent to the Site.
If Owner performs other work at or adjacent to the Site with Owner's employees, or through contracts for such other work, then Owner shall give Contractor written notice thereof prior to starting any such other work. If Owner has advance information regarding the start of any third-party utility work that Owner has arranged to take place at or adjacent to the Site, Owner shall provide such information to Contractor.
Contractor shall afford proper and safe access to the Site to each contractor that performs such other work, each utility owner performing other work, and Owner, if Owner is performing other work with Owner's employees, and provide a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work.

Contractor shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise make its several parts come together and properly integrate with such other work. Contractor shall not endanger any work of others by cutting, excavating, or otherwise altering such work; provided, however, that Contractor may cut or alter others' work with the written consent of Engineer and the others whose work will be affected.
If the proper execution or results of any part of Contractor's Work depends upon work performed by others, Contractor shall inspect such other work and promptly report to Engineer in writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and results of Contractor's Work. Contractor's failure to so report will constitute an acceptance of such other work as fit and proper for integration with Contractor's Work except for latent defects and deficiencies in such other work.
The provisions of this article are not applicable to work that is performed by third-party utilities or other third-party entities without a contract with Owner, or that is performed without having been arranged by Owner. If such work occurs, then any related delay, disruption, or interference incurred by Contractor is governed by the provisions of Paragraph 4.05.C.3.
Coordination
If Owner intends to contract with others for the performance of other work at or adjacent to the Site, to perform other work at or adjacent to the Site with Owner's employees, or to arrange to have utility owners perform work at or adjacent to the Site, the following will be set forth in the Supplementary Conditions or provided to Contractor prior to the start of any such other work:
The identity of the individual or entity that will have authority and responsibility for coordination of the activities among the various contractors;
An itemization of the specific matters to be covered by such authority and responsibility; and
The extent of such authority and responsibilities.
Unless otherwise provided in the Supplementary Conditions, Owner shall have sole authority and responsibility for such coordination.
Legal Relationships
If, in the course of performing other work for Owner at or adjacent to the Site, the Owner's employees, any other contractor working for Owner, or any utility owner that Owner has arranged to perform work, causes damage to the Work or to the property of Contractor or its Subcontractors, or delays, disrupts, interferes with, or increases the scope or cost of the performance of the Work, through actions or inaction, then Contractor shall be entitled to an equitable adjustment in the Contract Price or the Contract Times. Contractor must submit any Change Proposal seeking an equitable adjustment in the Contract Price or the Contract Times under this paragraph within 30 days of the damaging, delaying, disrupting, or interfering event. The entitlement to, and extent of, any such equitable adjustment will take into account information (if any) regarding such other work that was provided to Contractor in the Contract Documents prior to the submittal of the Bid or the final negotiation of the terms of the

Contract, and any remedies available to Contractor under Laws or Regulations concerning utility action or inaction. When applicable, any such equitable adjustment in Contract Price will be conditioned on Contractor assigning to Owner all Contractor's rights against such other contractor or utility owner with respect to the damage, delay, disruption, or interference that is the subject of the adjustment. Contractor's entitlement to an adjustment of the Contract Times or Contract Price is subject to the provisions of Paragraphs 4.05.D and 4.05.E.
Contractor shall take reasonable and customary measures to avoid damaging, delaying, disrupting, or interfering with the work of Owner, any other contractor, or any utility owner performing other work at or adjacent to the Site.
If Contractor fails to take such measures and as a result damages, delays, disrupts, or interferes with the work of any such other contractor or utility owner, then Owner may impose a set-off against payments due Contractor, and assign to such other contractor or utility owner the Owner's contractual rights against Contractor with respect to the breach of the obligations set forth in this Paragraph 8.03.B.
When Owner is performing other work at or adjacent to the Site with Owner's employees, Contractor shall be liable to Owner for damage to such other work, and for the reasonable direct delay, disruption, and interference costs incurred by Owner as a result of Contractor's failure to take reasonable and customary measures with respect to Owner's other work. In response to such damage, delay, disruption, or interference, Owner may impose a set-off against payments due Contractor.
If Contractor damages, delays, disrupts, or interferes with the work of any other contractor, or any utility owner performing other work at or adjacent to the Site, through Contractor's failure to take reasonable and customary measures to avoid such impacts, or if any claim arisin . in whole or in part. out of Contractor's actions, inactions, Sf negligence, recklessness, or intentional misconduct in performance of the Work at or adjacent to the Site is made by any such other contractor or utility owner against Contractor, Owner, or Engineer, then Contractor shall (1) promptly attempt to settle the claim as to all parties through negotiations with such other contractor or utility owner, or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law, and (2) indemnify. defend. and hold harmless lndemnitees Ov,rner aRa eAgiAeer, aRa tl<le affieers, aireetars, memeers, artAers, em layees, age Ats, rnAsultaAts aRa suernAtraetars af eael<l aRa aAy af tl<lem from and against any such claims, and against all costs, liabilities. suits. liens. demands. interest. expenses. penalties, fines, judgments. costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution fees and costs) whether monetary or otherwise, arising out of or relating to such damage, delay, disruption, or interference.

ARTICLE 9-0WNER'S RESPONSIBILITIES

Communications to Contractor
Except as otherwise provided in these General Conditions, Owner shall issue all communications to Contractor through Engineer.

Replacement of Engineer
Owner may at its discretion appoint an engineer to replace Engineer, provided Contractor makes no reasonable objection to the replacement engineer. The replacement engineer's status under the Contract Documents will be that of the former Engineer.
Furnish Data
Owner shall promptly furnish the data required of Owner under the Contract Documents.
Pay When Due
Owner shall make payments to Contractor when they are due as provided in the Agreement.
Lands and Easements; Reports, Tests, and Drawings
Owner's duties with respect to providing lands and easements are set forth in Paragraph 5.01.
Owner's duties with respect to providing engineering surveys to establish reference points are set forth in Paragraph 4.03.
Article 5 refers to Owner's identifying and making available to Contractor copies of reports of explorations and tests of conditions at the Site, and drawings of physical conditions relating to existing surface or subsurface structures at the Site.
Insurance
Owner's responsibilities, if any, with respect to purchasing and maintaining liability and property insurance are set forth in Article 6.
Change Orders
Owner's responsibilities with respect to Change Orders are set forth in Article 11.
Inspections, Tests, and Approvals
Owner's responsibility with respect to certain inspections, tests, and approvals is set forth in Paragraph 14.02.B.
Limitations on Owner's Responsibilities
The Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract
Documents.
Undisclosed Hazardous Environmental Condition
A. Owner's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in Paragraph 5.06.
Evidence of Financial Arrangements
Upon request of Contractor, Owner shall furnish Contractor reasonable evidence that financial arrangements have been made to satisfy Owner's obligations under the Contract (including obligations under proposed changes in the Work).

EJCDC® C 700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Safety Programs
While at the Site, Owner's employees and representatives shall comply with the specific applicable requirements of Contractor's safety programs of which Owner has been informed.
Owner shall furnish copies of any applicable Owner safety programs to Contractor.

ARTICLE 10-ENGINEER'S STATUS DURING CONSTRUCTION

Owner's Representative
Engineer and the Construction Manager. if any. will be Owner's representative during the construction period. The duties and responsibilities and the limitations of authority of Engineer as Owner's representative during construction are set forth in the Contract.
Visits to Site
Engineer will make visits to the Site at intervals appropriate to the various stages of construction as Engineer deems necessary in order to observe, as an experienced and qualified design professional, the progress that has been made and the quality of the various aspects of Contractor's executed Work. Based on information obtained during such visits and observations, Engineer, for the benefit of Owner, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. Engineer will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. Engineer's efforts will be directed toward providing for Owner a greater degree of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, Engineer will keep Owner informed of the progress of the Work and will endeavor to guard Owner against defective Work.
Engineer's visits and observations are subject to all the limitations on Engineer's authority and responsibility set forth in Paragraph 10.07. Particularly, but without limitation, during or as a result of Engineer's visits or observations of Contractor's Work, Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work.
Resident Project Representative
If Owner and Engineer have agreed that Engineer will furnish a Resident Project Representative to represent Engineer at the Site and assist Engineer in observing the progress and quality of the Work, then the authority and responsibilities of any such Resident Project Representative will be as provided in the Supplementary Conditions, and limitations on the responsibilities thereof will be as provided in the Supplementary Conditions and in Paragraph 10.07.
If Owner designates an individual or entity who is not Engineer's consultant, agent, or employee to represent Owner at the Site, then the responsibilities and authority of such individual or entity will be as provided in the Supplementary Conditions.
Engineer's Authority
Engineer has the authority to reject Work in accordance with Article 14.

EJCDC® C 7Q0, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Engineer's authority as to Submittals is set forth in Paragraph 7.16.
Engineer's authority as to design drawings, calculations, specifications, certifications and other Submittals from Contractor in response to Owner's delegation (if any) to Contractor of professional design services, is set forth in Paragraph 7.19.
Engineer's authority as to changes in the Work is set forth in Article 11.
Engineer's authority as to Applications for Payment is set forth in Article 15.
Determinations for Unit Price Work
Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor as set forth in Paragraph 13.03.
Decisions on Requirements of Contract Documents and Acceptability of Work
Engineer will render decisions regarding the requirements of the Contract Documents, and judge the acceptability of the Work, pursuant to the specific procedures set forth herein for initial interpretations, Change Proposals, and acceptance of the Work. In rendering such decisions and judgments, Engineer will not show partiality to Owner or Contractor, and will not be liable to Owner, Contractor, or others in connection with any proceedings, interpretations, decisions, or judgments conducted or rendered in good faith.
Limitations on Engineer's Authority and Responsibilities
Neither Engineer's authority or responsibility under this Article 10 or under any other provision of the Contract, nor any decision made by Engineer in good faith either to exercise or not exercise such authority or responsibility or the undertaking, exercise, or performance of any authority or responsibility by Engineer, will create, impose, or give rise to any duty in contract, tort, or otherwise owed by Engineer to Contractor, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them.
Engineer will not supervise, direct, control, or have authority over or be responsible for Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Engineer will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents.
Engineer will not be responsible for the acts or omissions of Contractor or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work.
Engineer's review of the final Application for Payment and accompanying documentation, and all maintenance and operating instructions, schedules, guarantees, bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by Contractor under Paragraph 15.06.A, will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals, that the results certified indicate compliance with the Contract Documents.
The limitations upon authority and responsibility set forth in this Paragraph 10.07 also apply to the Resident Project Representative, if any.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National society of Professional Engineers, American Council of Engineering Companies,

Compliance with Safety Program
While at the Site, Engineer's employees and representatives will comply with the specific applicable requirements of Owner's and Contractor's safety programs of which Engineer has been informed.

ARTICLE 11-CHANGES TO THE CONTRACT

Amending and Supplementing the Contract
The Contract may be amended or supplemented by a Change Order, a Work Change Directive, or a Field Order.
If an amendment or supplement to the Contract includes a change in the Contract Price or the Contract Times, such amendment or supplement must be set forth in a Change Order.
All changes to the Contract that involve (1) the performance or acceptability of the Work,
the design (as set forth in the Drawings, Specifications, or otherwise), or (3) other engineering or technical matters, must be supported by Engineer's recommendation. Owner and Contractor may amend other terms and conditions of the Contract without the recommendation of the Engineer. Such an amendment shall be set forth in a Change Order or a Work Change Directive.
Change Orders
Owner and Contractor shall execute appropriate Change Orders covering:
Changes in Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in accordance with a Work Change Directive;
Changes in Contract Price resulting from an Owner set-off, unless Contractor has duly contested such set-off;
Changes in the Work which are: (a) ordered by Owner pursuant to Paragraph 11.05,
(b) required because of Owner's acceptance of defective Work under Paragraph 14.04 or Owner's correction of defective Work under Paragraph 14.07, or (c) agreed to by the parties, subject to the need for Engineer's recommendation if the change in the Work involves the design (as set forth in the Drawings, Specifications, or otherwise) or other engineering or technical matters; such requests for Change Orders may be submitted by Construction Manager in consultation with the Contractor; however, all Change Orders must be reviewed and approved by the Engineer prior to final sign off by the Owner and implementation of the same; and
Changes that embody the substance of any final and binding results under: Paragraph 11.03.B, resolving the impact of a Work Change Directive; Paragraph 11.09, concerning Change Proposals; Article 12, Claims; Paragraph 13.02.D, final adjustments resulting from allowances; Paragraph 13.03.D, final adjustments relating to determination of quantities for Unit Price Work; and similar provisions.
If O·,•,·Aer  or GoAtraetor refuses to ei1eetJte a GhaAge Order that is re tJired to ee ei1eetJted tJAder the terFAs of Paragraph 11.Q2.A, it will ee deeFAed to ee of ftJII foree aAd effeet, as if fully eimetJted.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Work Change Directives
A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the modification ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order, following negotiations by the parties as to the Work Change Directive's effect, if any, on the Contract Price and Contract Times; or, if negotiations are unsuccessful, by a determination under the terms of the Contract Documents governing adjustments, expressly including Paragraph 11.07 regarding change of Contract Price.
If Owner has issued a Work Change Directive and:
Contractor believes that an adjustment in Contract Times or Contract Price is necessary, then Contractor shall submit any Change Proposal seeking such an adjustment no later than 30 days after the completion of the Work set out in the Work Change Directive.
Owner believes that an adjustment in Contract Times or Contract Price is necessary, then Owner shall submit any Claim seeking such an adjustment no later than 60 days after issuance of the Work Change Directive.
Field Orders
Engineer may authorize minor changes in the Work if the changes do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. Such changes will be accomplished by a Field Order and will be binding on Owner and also on Contractor, which shall perform the Work involved promptly.
If Contractor believes that a Field Order justifies an adjustment in the Contract Price or Contract Times, then before proceeding with the Work at issue, Contractor shall submit a Change Proposal as provided herein.
Owner-Authorized Changes in the Work
Without invalidating the Contract and without notice to any surety, Owner may, at any time or from time to time, order additions, deletions, or revisions in the Work including but not limited to for the purposes of achieving cost savings, and Owner reserves the right to delete portions of the Work and contract with third parties to provide any such deleted Work. Changes involving the design (as set forth in the Drawings, Specifications, or otherwise) or other engineering or technical matters will be supported by Engineer's recommendation.
Such changes in the Work may be accomplished by a Change Order, if Owner and Contractor have agreed as to the effect, if any, of the changes on Contract Times or Contract Price; or by a Work Change Directive. Upon receipt of any such document, Contractor shall promptly proceed with the Work involved; or, in the case of a deletion in the Work, promptly cease construction activities with respect to such deleted Work. Added or revised Work must be performed underthe applicable conditions of the Contract Documents.
Nothing in this Paragraph 11.05 obligates Contractor to undertake work that Contractor reasonably concludes cannot be performed in a manner consistent with Contractor's safety obligations under the Contract Documents or Laws and Regulations.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reseNed.

Unauthorized Changes in the Work
Contractor shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents, as amended, modified, or supplemented, except in the case of an emergency as provided in Paragraph 7.15 or in the case of uncovering Work as provided in Paragraph 14.05.C.2.
Change of Contract Price
The Contract Price may only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Price must comply with the provisions of Paragraph 11.09. Any Claim for an adjustment of Contract Price must comply with the provisions of Article 12.
An adjustment in the Contract Price will be determined as follows:
Where the Work involved is covered by unit prices contained in the Contract Documents, then by application of such unit prices to the quantities of the items involved (subject to the provisions of Paragraph 13.03);
Where the Work involved is not covered by unit prices contained in the Contract Documents, then by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with Paragraph 11.07.C.2); or
'A'here the Werk iR •elvea is Rat rnverea by 1mit wiees EORtaiRea iR the CeRtract DernmeRts aRa the 13arties Ela RGt reach m1,1t11al  agreemeRt te a l11m13  s11m, theR GR  the sasis ef the Cast ef the Werk {aetermiRea as 13reviaea iR Paragra13h 13.Qlj 13l11s  a CeRtracter's fee fer e•1erheaa aREI 13refit {aetermiRea as 13reviaea iR Paragra13h ll.Q7.Cj.
Contractor's Fee: When applicable, the Contractor's fee for overhead and profit will be determined as follows:
A mutually acceptable fixed fee; or
If a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work:
For costs incurred under Paragraphs 13.01.B.l and 13.01.B.2, the Contractor's fee will be 15 percent;
For costs incurred under Paragraph 13.01.B.3, the Contractor's fee will be 5 percent;
Where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of Paragraphs 11.07.C.2.a and 11.07.C.2.b is that the Contractor's fee will be based on: (1) a fee of 15 percent of the costs incurred under Paragraphs 13.01.B.l and 13.01.B.2 by the Subcontractor that actually performs the Work, at whatever tier, and (2) with respect to Contractor itself and to any Subcontractors of a tier higher than that of the Subcontractor that actually performs the Work, a fee of 5 percent of the amount (fee plus underlying costs incurred) attributable to the next lower tier Subcontractor; provided, however, that for any such subcontracted Work the maximum total fee to be paid by Owner will be no greater than 27 percent of the costs incurred by the Subcontractor that actually
performs the Work;

No fee will be payable on the basis of costs itemized under Paragraphs 13.01.B.4, 13.01.B.5, and 13.01.C;
The amount of credit to be allowed by Contractor to Owner for any change which results in a net decrease in Cost of the Work will be the amount of the actual net decrease in Cost of the Work and a deduction of an additional amount equal to 5 percent of such actual net decrease in Cost of the Work; and
When both additions and credits are involved in any one change or Change Proposal, the adjustment in Contractor's fee will be computed by determining the sum of the costs in each of the cost categories in Paragraph 13.01.B (specifically, payroll costs, Paragraph 13.01.B.1;  incorporated  materials  and  equipment  costs, Paragraph 13.01.B.2; Subcontract costs, Paragraph 13.01.B.3; special consultants costs, Paragraph 13.01.B.4; and other costs, Paragraph 13.01.B.5) and applying to each such cost category sum the appropriate fee from Paragraphs 11.07.C.2.a through 11.07.C.2.e, inclusive.
Change of Contract Times
The Contract Times may only be changed by a Change Order. Any Change Proposal for an adjustment in the Contract Times must comply with the provisions of Paragraph 11.09. Any Claim for an adjustment in the Contract Times must comply with the provisions of Article 12.
Delay, disruption, and interference in the Work, and any related changes in Contract Times, are addressed in and governed by Paragraph 4.05.
Change Proposals
Purpose and Content: Contractor shall submit a Change Proposal to Engineer to request an adjustment in the Contract Times or Contract Price; contest an initial decision by Engineer concerning the requirements of the Contract Documents or relating to the acceptability of the Work under the Contract Documents; challenge a set-off against payment due; or seek other relief under the Contract. The Change Proposal will specify any proposed change in Contract Times or Contract Price, or other proposed relief, and explain the reason for the proposed change, with citations to any governing or applicable provisions of the Contract Documents. Each Change Proposal will address only one issue, or a set of closely related
issues.
Change Proposal Procedures
Submittal: Contractor shall submit each Change Proposal to Engineer within 30 days after the start of the event giving rise thereto, or after such initial decision.
Supporting Data: The Contractor shall submit supporting data, including the proposed change in Contract Price or Contract Time (if any), to the Engineer and Owner within 15 days after the submittal of the Change Proposal.
Change Proposals based on or related to delay, interruption, or interference must comply with the provisions of Paragraphs 4.05.D and 4.05.E.
Change proposals related to a change of Contract Price must include full and detailed accounts of materials incorporated into the Work and labor and equipment used for the subject Work.

The supporting data must be accompanied by a written statement that the supporting data are accurate and complete, and that any requested time or price adjustment is the entire adjustment to which Contractor believes it is entitled as a result of said event.
Engineer's Initial Review: Engineer will advise Owner regarding the Change Proposal, and consider any comments or response from Owner regarding the Change Proposal. If in its discretion Engineer concludes that additional supporting data is needed before conducting a full review and making a decision regarding the Change Proposal, then Engineer may request that Contractor submit such additional supporting data by a date specified by Engineer, prior to Engineer beginning its full review of the Change Proposal.
Engineer's Full Review and Action on the Change Proposal: Upon receipt of Contractor's supporting data (including any additional data requested by Engineer), Engineer will conduct a full review of each Change Proposal and, within 30 days after such receipt of the Contractor's supporting data, either approve the Change Proposal in whole, deny it in whole, or approve it in part and deny it in part. Such actions must be in writing, with a copy provided to Owner and Contractor. If Engineer does not take action on the Change Proposal within 30 days, then either Owner or Contractor may at any time thereafter submit a letter to the other party indicating that as a result of Engineer's inaction the Change Proposal is deemed denied, thereby commencing the time for appeal of the denial under Article 12.
Binding Decision: Engineer's decision is final and binding upon Owner and Contractor, unless Owner or Contractor appeals the decision by filing a Claim under Article 12.
Resolution of Certain Change Proposals: If the Change Proposal does not involve the design (as set forth in the Drawings, Specifications, or otherwise), the acceptability of the Work, or other engineering or technical matters, then Engineer will notify the parties in writing that the Engineer is unable to resolve the Change Proposal. For purposes of further resolution of such a Change Proposal, such notice will be deemed a denial, and Contractor may choose to seek resolution under the terms of Article 12.
Post-Completion: Contractor shall not submit any Change Proposals after Engineer issues a written recommendation of final payment pursuant to Paragraph 15.06.B.
11.10  Notification to Surety
A. If the provisions of any bond require notice to be given to a surety of any change affecting the general scope of the Work or the provisions of the Contract Documents (including, but not limited to, Contract Price or Contract Times), the giving of any such notice will be Contractor's responsibility. The amount of each applicable bond will be adjusted to reflect the effect of any such change.

ARTICLE 12-CLAIMS

Claims
Claims Process: The following disputes between Owner and Contractor are subject to the Claims process set forth in this article:
Appeals by Owner or Contractor of Engineer's decisions regarding Change Proposals;

Owner demands for adjustments in the Contract Price or Contract Times, or other relief under the Contract Documents;
Disputes that Engineer has been unable to address because they do not involve the design (as set forth in the Drawings, Specifications, or otherwise), the acceptability of the Work, or other engineering or technical matters; and
Subject to the waiver provisions of Paragraph 15.07, any dispute arising after Engineer has issued a written recommendation of final payment pursuant to Paragraph 15.06.B.
Submittal of Claim: The party submitting a Claim shall deliver it directly to the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto; in the case of appeals regarding Change Proposals within 30 days of the decision under appeal. The party submitting the Claim shall also furnish a copy to the Engineer, for its information only. The responsibility to substantiate a Claim rests with the party making the Cla_im. In the case of a Claim by Contractor seeking an increase in the Contract Times or Contract Price, Contractor shall certify that the Claim is made in good faith, that the supporting data are accurate and complete, and that to the best of Contractor's knowledge and belief the amount of time or money requested accurately reflects the full amount to which Contractor is entitled.
Review and Resolution: The party receiving a Claim shall review it thoroughly, giving full consideration to its merits. The two parties shall seek to resolve the Claim through the exchange of information and direct negotiations. The parties may extend the time for resolving the Claim by mutual agreement. All actions taken on a Claim will be stated in writing and submitted to the other party, with a copy to Engineer.
Mediation
At any time after initiation of a Claim, Owner and Contractor may mutually agree to mediation of the underlying dispute. The agreement to mediate will stay the Claim submittal and response process.
If Owner and Contractor agree to mediation, then after 60 days from such agreement, either Owner or Contractor may unilaterally terminate the mediation process, and the Claim submittal and decision process will resume as of the date of the termination. If the mediation proceeds but is unsuccessful in resolving the dispute, the Claim submittal and decision process will resume as of the date of the conclusion of the mediation, as determined by the mediator.
Owner and Contractor shall each pay one-half of the mediator's fees and costs.
Partial Approval: If the party receiving a Claim approves the Claim in part and denies it in part, such action will be final and binding unless within 30 days of such action the other party invokes the procedure set forth in Article 17 for final resolution of disputes.
Denial of Claim: If efforts to resolve a Claim are not successful, the party receiving the Claim may deny it by giving written notice of denial to the other party. If the receiving party does not take action on the Claim within 90 days, then either Owner or Contractor may at any time thereafter submit a letter to the other party indicating that as a result of the inaction, the Claim is deemed denied, thereby commencing the time for appeal of the denial. A denial of the Claim will be final and binding unless within 30 days of the denial the other party invokes the procedure set forth in Article 17 for the final resolution of disputes.

Final and Binding Results: If the parties reach a mutual agreement regarding a Claim, whether through approval of the Claim, direct negotiations, mediation, or otherwise; or if a Claim is approved in part and denied in part, or denied in full, and such actions become final and binding; then the results of the agreement or action on the Claim will be incorporated in a Change Order or other written document to the extent they affect the Contract, including the Work, the Contract Times, or the Contract Price.

ARTICLE 13-COST OF THE WORK; ALLOWANCES; UNIT PRICE WORK

Cost of the Work
Purposes for Determination of Cost of the Work: The term Cost of the Work means the sum of all costs necessary for the proper performance of the Work at issue, as further defined below. The provisions of this Paragraph 13.01are used far two eistinEt purposes:
To eeterrnine Cost of Hie Work when Cost of the Work is a rnrnponent of the ContraEt PriEe, uneer Eost plus fee, tirne ane rnaterials, or other EOSt  basee terrns; or
When needed to determine the value of a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price. When the value of any such adjustment is determined on the basis of Cost of the Work, Contractor is entitled only to those additional or incremental costs required because of the change in the Work or because of the event giving rise to the adjustment.
Costs Included: Except as otherwise may be agreed to in writing by Owner, costs included in the Cost of the Work will be in amounts no higher than those commonly incurred in the locality of the Project, will not include any of the costs itemized in Paragraph 13.01.C, and will include only the following items:
Payroll costs for employees in the direct employ of Contractor in the performance of the Work under schedules of job classifications agreed upon by Owner and Contractor in advance of the subject Work. Such employees include, without limitation, superintendents, foremen, safety managers, safety representatives, and other personnel employed full time on the Work. Payroll costs for employees not employed full time on the Work will be apportioned on the basis of their time spent on the Work. Payroll costs include, but are not limited to, salaries and wages plus the cost of fringe benefits, which include social security contributions, unemployment, excise, and payroll taxes, workers' compensation, health and retirement benefits, sick leave, and vacation and holiday pay applicable thereto. The expenses of performing Work outside of regular working hours, on Saturday, Sunday, or legal holidays, will be included in the above to the extent authorized by Owner.
Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts accrue to Contractor unless Owner deposits funds with Contractor with which to make payments, in which case the cash discounts will accrue to Owner. All trade discounts, rebates, and refunds and returns from sale of surplus materials and equipment will accrue to Owner, and Contractor shall make provisions so that they may be obtained.
Payments made by Contractor to Subcontractors for Work performed by Subcontractors. If required by Owner, Contractor shall obtain competitive bids from subcontractors

acceptable to Owner and Contractor and shall deliver such bids to Owner, which will then determine, with the advice of Engineer, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee will be determined in the same manner as Contractor's Cost of the Work and fee as provided in this Paragraph 13.01.
Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed or retained for services specifically related to the Work.
Other costs consisting of the following:
The prnpartieR ef Reeessary traRspertatieR, travel, aREI  sYbsisteRce mEpeRses ef CeRtracter's eFRple•rees iRcYrrea iR aischarge ef aYties caRRectea with the Werle
Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facilities at the Site, which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of Contractor.
5) 1)  In establishing included costs for materials such as scaffolding, plating, or sheeting, consideration will be given to the actual or the estimated life of the material for use on other projects; or rental rates may be established on the basis of purchase or salvage value of such items, whichever is less. Contractor will not be eligible for compensation for such items in an amount that exceeds the purchase cost of such item.
Construction Equipment Rental
6} 1)  Rentals of all construction equipment and machinery, and the parts thereof, in accordance with rental agreements approved by Owner as to price (including any surcharge or special rates applicable to overtime use of the construction equipment or machinery), and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof. All such costs will be in accordance with the terms of said rental agreements. The rental of any such equipment, machinery, or parts must cease when the use thereof is no longer necessary for the Work.
2)  Costs for equipment and machinery owned by Contractor or a Contractor-related entity will be paid at a rate shown for such equipment in the equipment rental rate book specified in the Supplementary Conditions, or if none is specified, in a rate book mutually acceptable to both parties. An hourly rate will be computed by dividing the monthly rates by 176. These computed rates will include all operating costs.
3)  With respect to Work that is the result of a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price ("changed Work"), included costs will be based on the time the equipment or machinery is in use on the changed Work and the costs of transportation, loading, unloading, assembly, dismantling, and removal when directly attributable to the changed Work. The cost of any such equipment or machinery, or parts thereof, must cease to accrue when the use thereof is no longer necessary for the changed Work.

	·consumer, use, and other similar taxes related to the Work, and for which Contractor is liable, as imposed by Laws and Regulations.
Deposits lost for causes other than negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses.
Losses and damages {and related expenses) caused by damage to the Work, not compensated by insurance or otherwise, sustained by Contractor in connection with the performance of the Work {except losses and damages within the deductible amounts of builder's risk or other property insurance established in accordance with Paragraph 6.04}, provided such losses and damages have resulted from causes other than the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses include settlements made with the written consent and approval of Owner. No such losses, damages, and expenses will be included in the Cost of the Work for the purpose of determining Contractor's fee.
The cost of utilities, fuel, and sanitary facilities at the Site.
MiRar m113eRses  sueA as eammuRieatiaR serviee at tAe Site, ei113ress  aREI  eaurier serviees, aRa similar fjetty easA items iR eaRReetiaR witA tAe Werle
The costs of premiums for all bonds and insurance that Contractor is required by the Contract Documents to purchase and maintain.
Costs Excluded: The term Cost of the Work does not include any of the following items:
Payroll costs and other compensation of Contractor's officers, executives, principals, general managers, engineers, architects, estimators, attorneys, auditors, accountants, purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by Contractor, whether at the Site or in Contractor's principal or branch office for general administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to in Paragraph 13.01.B.1 or specifically covered by Paragraph 13.01.B.4. The payroll costs and other compensation excluded here are to be considered administrative costs covered by the Contractor's fee.
The cost of purchasing, renting, or furnishing small tools and hand tools.
Expenses of Contractor's principal and branch offices other than Contractor's office at the Site.
Any part of Contractor's capital expenses, including interest on Contractor's capital employed for the Work and charges against Contractor for delinquent payments.
Costs due to the negligence of Contractor, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property.
Expenses incurred in preparing and advancing Claims.
Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in Paragraph 13.01.B.

Contractor's Fee
WheR the Wark as a whale is perfermes BR the l:lasis af east pli;s a fee, the A:
CaRtraetar's fee far the '.'lark set farth iR the CaRtraet DarnmeRts as af the ffeeti'le Date af the CaRtraet •Nill Be determiRed as set farth iR the AgreemeRt.
l:l. far aR'f Vierk e011eres b•t a ChaRge Order, ChaRge Prapasal, Claim, set aff, er ether aaji;stment in Centraet Priee on tRe basis of Cast sf the Werk, Cantraeter's fee will be determines as fallows:
1) WheR the fee for the Work as a whole is a pereentage of the Cost of the Worl1, the fee will ai;tomatieally adji;st as the Cost of the Work eRaRges.
2) When the fee for the Work as a ,...,Role  is a fines fee, the fee for aR•,· assitions or seletioRs will be setermines iR aeeorsaRee with Paragraph 11.07.C.2.
When the Work as a whole is performed on the basis of a stipulated sum, or any other basis other than cost-plus-a-fee, then Contractor's fee for any Work covered by a Change Order, Change Proposal, Claim, set-off, or other adjustment in Contract Price on the basis of Cost of the Work will be determined in accordance with Paragraph 11.07.C.2.
Documentation ond Audit: Whenever the Cost of the Work for any purpose is to be determined pursuant to this Article 13, Contractor and pertinent Subcontractors will establish and maintain records of the costs in accordance with generally accepted accounting practices. Subject to prior written notice, Owner will be afforded reasonable access, during normal business hours, to all Contractor's accounts, records, books, correspondence, instructions, drawings, receipts, vouchers, memoranda, and similar data relating to the Cost of the Work and Contractor's fee. All such documentation may be considered public records under Florida Law as set forth in the Contract Documents and shall be maintained in accordance with Florida Law. CoRtraetor shall preserve all si;eh aoei;ments for a period of three years after the final pa•tment by Owner. Pertinent Subcontractors will afford such access to Owner, and preserve such documents, to the same extent required of Contractor.
Allowances
It is understood that Contractor has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums and by such persons or entities as may be acceptable to Owner and Engineer.
Cosh Allowances: Contractor agrees that:
the cash allowances include the cost to Contractor (less any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and
Contractor's costs for unloading and handling on the Site, labor, installation, overhead, profit, and other expenses contemplated for the cash allowances have been included in the Contract Price and not in the allowances, and no demand for additional payment for any of the foregoing will be valid.
Owner's Contingency Allowance: Contractor agrees that an Owner's contingency allowance, if any, is for the sole use of Owner to cover unanticipated costs.

Prior to final payment, an appropriate Change Order will be issued as recommended by Engineer to reflect actual amounts due Contractor for Work covered by allowances, and the Contract Price will be correspondingly adjusted.
Unit Price Work
Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement and/or the Contract Documents.
The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Payments to Contractor for Unit Price Work will be based on actual quantities.
Each unit price will be deemed to include an amount considered by Contractor to be adequate to cover Contractor's overhead and profit for each separately identified item.
Engineer will determine the actual quantities and classifications of Unit Price Work performed by Contractor. Engineer will review with Contractor the Engineer's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). Engineer's written decision thereon will be final and binding (except as modified by Engineer to reflect changed factual conditions or more accurate data) upon Owner and Contractor, and the final adjustment of Contract Price will be set forth in a Change Order, subject to the provisions of the following paragraph.
Adjustments in Unit Price
Contractor or Owner shall be entitled to an adjustment in the unit price with respect to an item of Unit Price Work if:
the quantity of the item of Unit Price Work performed by Contractor differs materially and significantly from the estimated quantity of such item indicated in the Agreement; and
Contractor's unit costs to perform the item of Unit Price Work have changed materially and significantly as a result of the quantity change.
The adjustment in unit price will account for and be coordinated with any related changes in quantities of other items of Work, and in Contractor's costs to perform such other Work, such that the resulting overall change in Contract Price is equitable to Owner and Contractor.
Adjusted unit prices will apply to all units of that item.

ARTICLE 14-TESTS AND INSPECTIONS; CORRECTION, REMOVAL, OR ACCEPTANCE OF DEFECTIVE WORK

Access to Work
Owner, Engineer, their consultants and other representatives and personnel of Owner, independent testing laboratories, and authorities having jurisdiction have access to the Site and the Work at reasonable times for their observation, inspection, and testing. Contractor

shall provide them proper and safe conditions for such access and advise them of Contractor's safety procedures and programs so that they may comply with such procedures and programs as applicable.
Tests, Inspections, and Approvals
Contractor shall give Engineer timely notice of readiness of the Work (or specific parts thereof) for all required inspections and tests, and shall cooperate with inspection and testing personnel to facilitate required inspections and tests.
Owner shall retain and pay for the services of an independent inspector, testing laboratory, or other qualified individual or entity to perform all inspections and tests expressly required by the Contract Documents to be furnished and paid for by Owner, except that costs incurred in connection with tests or inspections of covered Work will be governed by the provisions of Paragraph 14.05.
If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, tested, or approved by an employee or other representative of such public body, Contractor shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all costs in connection therewith, and furnish Engineer the required certificates of inspection or approval.
Contractor shall be responsible for arranging, obtaining, and paying for all inspections and tests required:
by the Contract Documents, unless the Contract Documents expressly allocate responsibility for a specific inspection or test to Owner;
to attain Owner's and Engineer's acceptance of materials or equipment to be incorporated in the Work;
by manufacturers of equipment furnished under the Contract Documents;
for testing, adjusting, and balancing of mechanical, electrical, and other equipment to be incorporated into the Work; and
for acceptance of materials, mix designs, or equipment submitted for approval prior to Contractor's purchase thereof for incorporation in the Work.
Such inspections and tests will be performed by independent inspectors, testing laboratories, or other qualified individuals or entities acceptable to Owner and Engineer.
If the Contract Documents require the Work (or part thereof) to be approved by Owner, Engineer, or another designated individual or entity, then Contractor shall assume full responsibility for arranging and obtaining such approvals.
If any Work (or the work of others) that is to be inspected, tested, or approved is covered by Contractor without written concurrence of Engineer, Contractor shall, if requested by Engineer, uncover such Work for observation. Such uncovering will be at Contractor's expense unless Contractor had given Engineer timely notice of Contractor's intention to cover the same and Engineer had not acted with reasonable promptness in response to such notice.
Defective Work
Contractor's Obligation: It is Contractor's obligation to assure that the Work is not defective.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Engineer's Authority: Engineer has the authority to determine whether Work is defective, and to reject defective Work.
Notice of Defects: Prompt written notice of all defective Work of which Owner or Engineer has actual knowledge will be given to Contractor.
Correction, or Removal and Replacement: Promptly after receipt of written notice of defective Work, Contractor shall correct all such defective Work, whether or not fabricated, installed, or completed, or, if Engineer has rejected the defective Work, remove it from the Project and replace it with Work that is not defective.
Preservation of Warranties: When correcting defective Work, Contractor shall take no action that would void or otherwise impair Owner's special warranty and guarantee, if any, on said Work.
Costs and Damages: In addition to its correction, removal, and replacement obligations with respect to defective Work, Contractor shall pay all claims, costs, losses, and damages arising out of or relating to defective Work, including but not limited to the cost of the inspection, testing, correction, removal, replacement, or reconstruction of such defective Work, fines levied against Owner by governmental authorities because the Work is defective, and the costs of repair or replacement of work of others resulting from defective Work. Prior to final payment, if Owner and Contractor are unable to agree as to the measure of such claims, costs, losses, and damages resulting from defective Work, then Owner may impose a reasonable set-off against payments due under Article 15.
Acceptance of Defective Work
If, instead of requiring correction or removal and replacement of defective Work, Owner prefers to accept it, Owner may do so (subject, if such acceptance occurs prior to final payment, to Engineer's confirmation that such acceptance is in general accord with the design intent and applicable engineering principles, and will not endanger public safety). Contractor shall pay all claims, costs, losses, and damages attributable to Owner's evaluation of and determination to accept such defective Work (such costs to be approved by Engineer as to reasonableness), and for the diminished value of the Work to the extent not otherwise paid by Contractor. If any such acceptance occurs prior to final payment, the necessary revisions in the Contract Documents with respect to the Work will be incorporated in a Change Order. If the parties are unable to agree as to the decrease in the Contract Price, reflecting the diminished value of Work so accepted, then Owner may impose a reasonable set-off against payments due under Article 15. If the acceptance of defective Work occurs after final payment, Contractor shall pay an appropriate amount to Owner.
Uncovering Work
Engineer and/or Construction Manager has the authority to require additional inspection or testing of the Work, whether or not the Work is fabricated, installed, or completed. Engineer shall review each such additional inspection or testing of the Work.
If any Work is covered contrary to the written request of Engineer, then Contractor shall, if requested by Engineer, uncover such Work for Engineer's observation, and then replace the covering, all at Contractor's expense.
If Engineer considers it necessary or advisable that covered Work be observed by Engineer or inspected or tested by others, then Contractor, at Engineer's request, shall uncover, expose,

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies,

or otherwise make available for observation, inspection, or testing as Engineer may require, that portion of the Work in question, and provide all necessary labor, material, and equipment.
If it is found that the uncovered Work is defective, Contractor shall be responsible for all claims, costs, losses, and damages arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and pending Contractor's full discharge of this responsibility the Owner shall be entitled to impose a reasonable set-off against payments due under Article 15.
If the uncovered Work is not found to be defective, Contractor shall be allowed an increase in the Contract Price or an extension of the Contract Times, directly attributable to such uncovering, exposure, observation, inspection, testing, replacement, and reconstruction. If the parties are unable to agree as to the amount or extent thereof, then Contractor may submit a Change Proposal within 30 days of the determination that the Work is not defective.
Owner May Stop the Work
If the Work is defective, or Contractor fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Documents, then Owner may order Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of Owner to stop the Work will not give rise to any duty on the part of Owner to exercise this right for the benefit of Contractor, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them.
Owner May Correct Defective Work
If Contractor fails within a reasonable time after written notice from Engineer to correct defective Work, or to remove and replace defective Work as required by Engineer, then Owner may, after 7 days' written notice to Contractor, correct or remedy any such deficiency.
In exercising the rights and remedies under this Paragraph 14.07, Owner shall proceed expeditiously. In connection with such corrective or remedial action, Owner may exclude Contractor from all or part of the Site, take possession of all or part of the Work and suspend Contractor's services related thereto, and incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere. Contractor shall allow Owner, Owner's representatives, agents and employees, Owner's other contractors, and Engineer and Engineer's consultants access to the Site to enable Owner to exercise the rights and remedies under this paragraph.
All claims, costs, losses, and damages incurred or sustained by Owner in exercising the rights and remedies under this Paragraph 14.07 will be charged against Contractor as set-offs against payments due under Article 15. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of Contractor's defective Work.
Contractor shall not be allowed an extension of the Contract Times because of any delay in the performance of the Work attributable to the exercise by Owner of Owner's rights and remedies under this Paragraph 14.07.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies,

ARTICLE 15-PAYMENTS TO CONTRACTOR; SET-OFFS; COMPLETION; CORRECTION PERIOD

Progress Payments
Basis far Progress Payments: The Schedule of Values established as provided in Article 2 will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to Engineer. Progress payments for Unit Price Work will be based on the number of units completed during the pay period, as determined under the provisions of Paragraph 13.03. Progress payments for cost-based Work will be based on Cost of the Work completed by Contractor during the pay period.
Applications for Payments
At least 20 days before the date established in the Agreement for each progress payment (but not more often than once a month), Contractor shall submit to Engineer for review an Application for Payment filled out and signed by Contractor covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. The typical date of submission of Application for Payment will be the 30th of each month.
If 13ayment is Fe€jt1estea on Hie llasis of mateFials ana e€jt1i13ment not incoF130Fatea in Hie WoFk llt1t seliveFea ana st1itallly stores at the Site or at another location agrees to in wFiting, the .'\13131ication  for  Payment mt1st also Ile accom13aniea lly: (a) a llill of sale, im1oice, co13ies  of st11lcontract or JlllFchase orser 13a•1ments,  or other aoCllmentation estalllisRing ft1II 13a ·ment lly Contractor for tRe materials ans e€jt1i13ment; (ll) at Owner's Fe€jt1est,  soct1mentation waFFanting tRat Owner has receives the materials ana e€jt1i13ment free ans clear of all biens; ana (c) e•,·iaence tRat the mateFials ana e€jt1i13ment are co•,·eres  by a1313ro13riate  13ro13erty inst1Fance,  a wareRot1se bona, or otheF aFFangements to 13rotect Owner's internst tRerein, all of whicR mt1st be satisfactory to o,,..,ner. Progress payments are to be made only on installed material, and no payments shall be made on stored material. whetheF on or off site. unless prior written arrangements are made with Owner. This contract acknowledges that materials will be bulked purchased and stored on-site to avoid material increases, and those stored on-site materials can be included in Applications for Payment.
Beginning with the second Application for Payment, each Application must include an affidavit of Contractor stating that all previous progress payments received by Contractor have been applied to discharge Contractor's legitimate obligations associated with prior Applications for Payment.
The amount of retainage with respect to progress payments will be as stipulated in the Agreement.
Review of Applications
Engineer will, within 10 days after receipt of each Application for Payment, including each resubmittal, either indicate in writing a recommendation of payment and present the Application to Owner, or return the Application to Contractor indicating in writing Engineer's reasons for refusing to recommend payment. In the latter case, Contractor may make the necessary corrections and resubmit the Application.
Engineer's recommendation of any payment requested in an Application for Payment will constitute a representation by Engineer to Owner, based on Engineer's observations of

the executed Work as an experienced and qualified design professional, and on Engineer's review of the Application for Payment and the accompanying data and schedules, that to the best of Engineer's knowledge, information and belief:
the Work has progressed to the point indicated;
the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, the results of any subsequent tests called for in the Contract Documents, a final determination of quantities and classifications for Unit Price Work under Paragraph 13.03, and any other qualifications stated in the recommendation); and
the conditions precedent to Contractor's being entitled to such payment appear to have been fulfilled in so far as it is Engineer's responsibility to observe the Work.
By recommending any such payment Engineer will not thereby be deemed to have represented that:
inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to Engineer in the Contract; or
there may not be other matters or issues between the parties that might entitle Contractor to be paid additionally by Owner or entitle Owner to withhold payment to Contractor.
Neither Engineer's review of Contractor's Work for the purposes of recommending payments nor Engineer's recommendation of any payment, including final payment, will impose responsibility on Engineer:
to supervise, direct, or control the Work;
for the means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto;
for Contractor's failure to comply with Laws and Regulations applicable to Contractor's performance of the Work;
to make any examination to ascertain how or for what purposes Contractor has used the money paid by Owner; or
to determine that title to any of the Work, materials, or equipment has passed to Owner free and clear of any Liens.
Engineer may refuse to recommend the whole or any part of any payment if, in Engineer's opinion, it would be incorrect to make the representations to Owner stated in Paragraph 15.01.C.2.
Engineer will recommend reductions in payment (set-offs) necessary in Engineer's opinion to protect Owner from loss because:
the Work is defective, requiring correction or replacement;
the Contract Price has been reduced by Change Orders;

Owner has been required to correct defective Work in accordance with Paragraph 14.07, or has accepted defective Work pursuant to Paragraph 14.04;
Owner has been required to remove or remediate a Hazardous Environmental Condition for which Contractor is responsible; or
Engineer has actual knowledge of the occurrence of any of the events that would constitute a default by Contractor and therefore justify termination for cause under the Contract Documents.
Payment Becomes Due
TeR days after i,reseRtatioR of U1e l\i,i,licatioR for PayFReRt to  OwRer with !CRgiReer's recoFRFReRdatioR, the aFRO Rt recoFRFReRded  (s l3ject to any OwRer set offsj will eecoFRe d e, aRd wheR d e will ee i,aid ey OwRer to CoRtractor. Owner shall make payment to the Contractor in the amount recommended by Engineer (subject to the provisions of this Contract) in accordance with the prompt payment provisions contained in Sections 218.70 et seq.• Florida Statutes. Contractor shall make payments due to subcontractors and suppliers within ten (10) days in accordance with the prompt payment provisions contained in Section 218.735{6}. 218.735/7), and 218.74. Florida Statutes.
Reductions in Payment by Owner
In addition to any reductions in payment (set-offs) recommended by Engineer, Owner is entitled to impose a set-off against payment based on any of the following:
Claims have been made against Owner based on Contractor's conduct in the performance or furnishing of the Work, or Owner has incurred costs, losses, or damages resulting from Contractor's conduct in the performance or furnishing of the Work, including but not limited to claims, costs, losses, or damages from workplace injuries, adjacent property damage, non-compliance with Laws and Regulations, and patent infringement;
Contractor has failed to take reasonable and customary measures to avoid damage, delay, disruption, and interference with other work at or adjacent to the Site;
Contractor has failed to provide and maintain required bonds or insurance;
Owner has been required to remove or remediate a Hazardous Environmental Condition for which Contractor is responsible;
Owner has incurred extra charges or engineering costs related to submittal reviews, evaluations of proposed substitutes, tests and inspections, or return visits to manufacturing or assembly facilities;
The Work is defective, requiring correction or replacement;
Owner has been required to correct defective Work in accordance with Paragraph 14.07, or has accepted defective Work pursuant to Paragraph 14.04;
The Contract Price has been reduced by Change Orders;
An event has occurred that would constitute a default by Contractor and therefore justify a termination for cause;

Liquidated or other damages have accrued as a result of Contractor's failure to achieve Milestones, Substantial Completion, or final completion of the Work;
Liens have been filed in connection with the Work, except where Contractor has delivered a specific bond satisfactory to Owner to secure the satisfaction and discharge of such Liens; or
Other items entitle Owner to a set-off against the amount recommended.
If Owner imposes any set-off against payment, whether based on its own knowledge or on the written recommendations of Engineer, Owner will give Contractor immediate written notice (with a copy to Engineer) stating the reasons for such action and the specific amount of the reduction, and promptly pay Contractor any amount remaining after deduction of the amount so withheld. Owner shall promptly pay Contractor the amount so withheld, or any adjustment thereto agreed to by Owner and Contractor, if Contractor remedies the reasons for such action. The reduction imposed will be binding on Contractor unless it duly submits a Change Proposal contesting the reduction.
Upon a subsequent determination that Owner's refusal of payment was not justified, the amount wrongfully withheld will be treated as an amount due as determined by Paragraph 15.01.D.1 and subject to interest as provided in the Agreement.
Contractor's Warranty ofTitle
Contractor warrants and guarantees that title to all Work, materials, and equipment furnished under the Contract will pass to Owner free and clear of (1) all Liens and other title defects, and (2) all patent, licensing, copyright, or royalty obligations, no later than 7 days after the time of payment by Owner.
Substantial Completion
When Contractor considers the entire Work ready for its intended use Contractor shall notify Owner and Engineer in writing that the entire Work is substantially complete and request that Engineer issue a certificate of Substantial Completion. Contractor shall at the same time submit to Owner and Engineer an initial draft of punch list items to be completed or corrected before final payment.
Promptly after Contractor's notification, Owner, Contractor, and Engineer shall make an inspection of the Work to determine the status of completion. If Engineer does not consider the Work substantially complete, Engineer will notify Contractor in writing giving the reasons therefor.
If Engineer considers the Work substantially complete, Engineer will deliver to Owner a preliminary certificate of Substantial Completion which will fix the date of Substantial Completion. Engineer shall attach to the certificate a punch list of items to be completed or corrected before final payment. Owner shall have 7 days after receipt of the preliminary certificate during which to make written objection to Engineer as to any provisions of the certificate or attached punch list. If, after considering the objections to the provisions of the preliminary certificate, Engineer concludes that the Work is not substantially complete, Engineer will, within 14 days after submission of the preliminary certificate to Owner, notify Contractor in writing that the Work is not substantially complete, stating the reasons therefor. If Owner does not object to the provisions of the certificate, or if despite consideration of Owner's objections Engineer concludes that the Work is substantially complete, then

Engineer will, within said 14 days, execute and deliver to Owner and Contractor a final certificate of Substantial Completion (with a revised punch list of items to be completed or corrected) reflecting such changes from the preliminary certificate as Engineer believes justified after consideration of any objections from Owner.
At the time of receipt of the preliminary certificate of Substantial Completion, Owner and Contractor will confer regarding Owner's use or occupancy of the Work following Substantial Completion, review the builder's risk insurance policy with respect to the end of the builder's risk coverage, and confirm the transition to coverage of the Work under a permanent property insurance policy held by Owner. Unless Owner and Contractor agree otherwise in writing, Owner shall bear responsibility for security, operation, protection of the Work, property insurance, maintenance, heat, and utilities upon Owner's use or occupancy of the Work.
After Substantial Completion the Contractor shall promptly begin work on the punch list of items to be completed or corrected prior to final payment. In appropriate cases Contractor may submit monthly Applications for Payment for completed punch list items, following the progress payment procedures set forth above.
Owner shall have the right to exclude Contractor from the Site after the date of Substantial Completion subject to allowing Contractor reasonable access to remove its property and complete or correct items on the punch list.
To the extent this paragraph 15.03 is inconsistent in any way with Florida's Local Government Prompt Payment Act, sections 218.70 et seq., Florida Statutes, such Act shall control, and this Contract shall be construed to allow for the maximum amount of time allowable under the Act in order to review any punch lists and make payment.
Partial Use or Occupancy
Prior to Substantial Completion of all the Work, Owner may use or occupy any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which Owner, Engineer, and Contractor agree constitutes a separately functioning and usable part of the Work that can be used by Owner for its intended purpose without significant interference with Contractor's performance of the remainder of the Work, subject to the following conditions:
At any time, Owner may request in writing that Contractor permit Owner to use or occupy any such part of the Work that Owner believes to be substantially complete. If and when Contractor agrees that such part of the Work is substantially complete, Contractor, Owner, and Engineer will follow the procedures of Paragraph 15.03.A through 15.03.E for that part of the Work.
At any time, Contractor may notify Owner and Engineer in writing that Contractor considers any such part of the Work substantially complete and request Engineer to issue a certificate of Substantial Completion for that part of the Work.
Within a reasonable time after either such request, Owner, Contractor, and Engineer shall make an inspection of that part of the Work to determine its status of completion. If Engineer does not consider that part of the Work to be substantially complete, Engineer will notify Owner and Contractor in writing giving the reasons therefor. If Engineer considers that part of the Work to be substantially complete, the provisions of

Paragraph 15.03 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto.
No use or occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of Paragraph 6.04 regarding builder's risk or other property insurance.
Final Inspection
Upon written notice from Contractor that the entire Work or an agreed portion thereof is complete, Engineer will promptly make a final inspection with Owner and Contractor and will notify Contractor in writing of all particulars in which this inspection reveals that the Work, or agreed portion thereof, is incomplete or defective. Contractor shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies.
Final Payment
Application far Payment
After Contractor has, in the opinion of Engineer, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all maintenance and operating instructions, schedules, guarantees, bonds, certificates or other evidence of insurance, certificates of inspection, annotated record documents (as provided in Paragraph 7.12), and other documents, Contractor may make application for final payment.
The final Application for Payment must be accompanied (except as previously delivered) by:
all documentation called for in the Contract Documents;
consent of the surety, if any, to final payment;
satisfactory evidence that all title issues have been resolved such that title to all Work, materials, and equipment has passed to Owner free and clear of any Liens or other title defects, or will so pass upon final payment.
a list of all duly pending Change Proposals and Claims; and
complete and legally effective releases or waivers (satisfactory to Owner) of all Lien rights arising out of the Work, and of Liens filed in connection with the Work.
In lieu of the releases or waivers of Liens specified in Paragraph 15.06.A.2 and as approved by Owner, Contractor may furnish receipts or releases in full and an affidavit of Contractor that: (a) the releases and receipts include all labor, services, material, and equipment for which a Lien could be filed; and (b) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which Owner might in any way be responsible, or which might in any way result in liens or other burdens on Owner's property, have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, Contractor may furnish a bond or other collateral satisfactory to Owner to indemnify Owner against any Lien, or Owner at its option may issue joint checks payable to Contractor and specified Subcontractors and Suppliers.
Engineer's Review af Final Application and Recammendatian af Payment: If, on the basis of Engineer's observation of the Work during construction and final inspection, and Engineer's

review of the final Application for Payment and accompanying documentation as required by the Contract Documents, Engineer is satisfied that the Work has been completed and Contractor's other obligations under the Contract have been fulfilled, Engineer will, within 10 days after receipt of the final Application for Payment, indicate in writing Engineer's recommendation of final payment and present the final Application for Payment to Owner for payment. Such recommendation will account for any set-offs against payment that are necessary in Engineer's opinion to protect Owner from loss for the reasons stated above with respect to progress payments. Otherwise, Engineer will return the Application for Payment to Contractor, indicating in writing the reasons for refusing to recommend final payment, in which case Contractor shall make the necessary corrections and resubmit the Application for Payment.
Notice of Acceptability: In support of its recommendation of payment of the final Application for Payment, Engineer will also give written notice to Owner and Contractor that the Work is acceptable, subject to stated limitations in the notice and to the provisions of Paragraph 15.07.
Completion of Work: The Work is complete (subject to surviving obligations) when it is ready for final payment as established by the Engineer's written recommendation of final payment and issuance of notice of the acceptability of the Work. Without intending to limit any other requirements set forth herein for final payment, the Work shall not be deemed complete until the Engineer has certified that, among any other requirements herein, the Contractor has completed all of the Work; there is satisfactory operation of all equipment, by means of acceptance tests; all punch list items has been corrected to the satisfaction of Owner and Engineer: the Contractor has provided all evidence of all releases of all mechanics', materialmen's and like liens; all warranties, equipment operation and maintenance manuals, As-Built Drawings and other required documents have been delivered: all other required approvals and acceptances by city, county and state governments, or other authority having jurisdiction have been provided; all rubbish, tools. and surplus materials and equipment from the Project Site have been removed; and a final affidavit and release of claims has been provided.
Final Payment Becomes Due: Upon receipt from Engineer of the final Application for Payment and accompanying documentation, Owner shall set off against the amount recommended by Engineer for final payment any further sum to which Owner is entitled, including but not limited to set-offs for liquidated damages and set-offs allowed under the provisions of this Contract with respect to progress payments. Owner shall pay the resulting balance due to Contractor within 30 days of Owner's receipt of the final Application for Payment from Engineer.
Waiver of Claims
The making of final payment will not constitute a waiver by Owner of claims or rights against Contractor. Owner expressly reserves claims and rights arising from unsettled Liens, from defective Work appearing after final inspection pursuant to Paragraph 15.05, from Contractor's failure to comply with the Contract Documents or the terms of any special guarantees specified therein, from outstanding Claims by Owner, or from Contractor's continuing obligations under the Contract Documents. By maldRg RRal paymeRt, Ovmer
',Yaives its elaim er rigtlt ta liEjllidateEI Elamages er ettler damages fer late eempletieR b•r
GeRtraeter, eneept as set ferttl iR  aR  01JtstaRdiRg Claim, appeal llREler ttle previsieRs ef

Artiele 17, set eff, er el!press reser\'atieA ef rights b•t 0•1mer. OwAer reser\'es all ether elaiffis er rights after fiAal payffieAt.
The acceptance of final payment by Contractor will constitute a waiver by Contractor of all claims and rights against Owner other than those pending matters that have been duly submitted as a Claim, or appealed under the provisions of Article 17.
Correction Period
If within eAe '(ear two years after the date of Substantial Completion (or such longer period of time as may be prescribed by the Supplementary Conditions or the terms of any applicable special guarantee required by the Contract Documents), Owner gives Contractor written notice that any Work has been found to be defective, or that Contractor's repair of any damages to the Site or adjacent areas has been found to be defective, then after receipt of such notice of defect Contractor shall promptly, without cost to Owner and in accordance with Owner's written instructions:
correct the defective repairs to the Site or such adjacent areas;
correct such defective Work;
remove the defective Work from the Project and replace it with Work that is not defective, if the defective Work has been rejected by Owner, and
satisfactorily correct or repair or remove and replace any damage to other Work, to the work of others, or to other land or areas resulting from the corrective measures.
Owner shall give any such notice of defect within 60 days of the discovery that such Work or repairs is defective. If such notice is given within such 60 days but after the end of the correction period, the notice will be deemed a notice of defective Work under Paragraph 7.17.B.
If, after receipt of a notice of defect within 60 days and within the correction period, Contractor does not promptly comply with the terms of Owner's written instructions, or in an emergency where delay would cause serious risk of loss or damage, Owner may have the defective Work corrected or repaired or may have the rejected Work removed and replaced. Contractor shall pay all costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such correction or repair or such removal and replacement (including but not limited to all costs of repair or replacement of work of others). Contractor's failure to pay such costs, losses, and damages within 10 days of invoice from Owner will be deemed the start of an event giving rise to a Claim under Paragraph 12.01.B, such that any related Claim must be brought within 30 days of the failure
to pay.
In special circumstances where a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the correction period for that item may start to run from an earlier date if so provided in the Specifications.
Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this paragraph, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed.

EJCDC® CM700, Standard General Conditions of the Construction Contract.
Copyright@ 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Contractor's obligations under this paragraph are in addition to all other obligations and warranties. The provisions of this paragraph are not to be construed as a substitute for, or a waiver of, the provisions of any applicable statute of limitation or repose.

ARTICLE 16-SUSPENSION OF WORK AND TERMINATION

Owner May Suspend Work
At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 90 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times directly attributable to any such suspension. Any Change Proposal seeking such adjustments must be submitted no later than 30 days after the date fixed for resumption of Work.
When all or a portion of the Work is suspended for any reason, Contractor shall securely fasten down all coverings and other protections necessary to protect the Work and the Site from injury by the elements or otherwise.
Owner May Terminate for Cause
The occurrence of any one or more of the following events will constitute a default by Contractor and justify termination for cause:
Contractor's persistent failure to perform the Work in accordance with the Contract Documents (including, but not limited to, failure to supply sufficient skilled workers or suitable materials or equipment, or failure to adhere to the Progress Schedule);
Failure of Contractor to perform or otherwise to comply with a fil!Y_material term of the Contract Documents;
Contractor's disregard of Laws or Regulations of any public body having jurisdiction; or
Contractor's repeated disregard of the authority of Owner or Engineer.
If one or more of the events identified in Paragraph 16.02.A occurs, then after giving Contractor (and any surety) 10 days' written notice that Owner is considering a declaration that Contractor is in default and termination of the Contract, Owner may proceed to:
declare Contractor to be in default, and give Contractor (and any surety) written notice that the Contract is terminated; and
enforce the rights available to Owner under any applicable performance bond.
Subject to the terms and operation of any applicable performance bond, if Owner has terminated the Contract for cause, Owner may exclude Contractor from the Site, take possession of the Work, incorporate in the Work all materials and equipment stored at the Site or for which Owner has paid Contractor but which are stored elsewhere, and complete the Work as Owner may deem expedient.
Owner may not proceed with termination of the Contract under Paragraph 16.02.B if Contractor within 7 days of receipt of notice of intent to terminate begins to correct its failure to perform and proceeds diligently to cure such failure.

EJCDC® C-700, Standard General Conditions of the Construction Contract.
Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies,

If Owner proceeds as provided in Paragraph 16.02.B, Contractor shall not be entitled to receive any further payment until the Work is completed. If the unpaid balance of the Contract Price exceeds the cost to complete the Work, including all related claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals) sustained by Owner, such excess will be paid to Contractor. If the cost to complete the Work including such related claims, costs, losses, and damages exceeds such unpaid balance, Contractor shall pay the difference to Owner. Such claims, costs, losses, and damages incurred by Owner will be reviewed by Engineer as to their reasonableness and, when so approved by Engineer, incorporated in a Change Order. When exercising any rights or remedies under this paragraph, Owner shall not be required to obtain the lowest price for the Work performed.
Where Contractor's services have been so terminated by Owner, the termination will not affect any rights or remedies of Owner against Contractor then existing or which may thereafter accrue, or any rights or remedies of Owner against Contractor or any surety under any payment bond or performance bond. Any retention or payment of money due Contractor by Owner will not release Contractor from liability.
If and to the extent that Contractor has provided a performance bond under the provisions of Paragraph 6.01.A, the provisions of that bond will govern over any inconsistent provisions of Paragraphs 16.02.B and 16.02.D.
Owner May Terminate for Convenience
Upon 7 days' written notice to Contractor and Engineer, Owner may, without cause and without prejudice to any other right or remedy of Owner, terminate the Contract. In such case, Owner will pay to Contractor all amounts due and not previously paid to Contractor for Work completed in accordance with the Contract prior to such notice, as well as the cost of reasonably protecting Work in place, and for Work thereafter completed as specified in such notice, as well as release and payment to Contractor of all retainage held by Owner related to the portion of the Work completed. No payments will be made for any potential costs of settling or paying claims arising out of termination of the Work under subcontracts, equipment leases. orders or other related arrangements. IR SllCA case, CoRtractor stiall be paiel for (witAOllt dltplicatioR of aR'f iteFRs):
coFRpleteel aRel acceptable Work enecltteel iR accorelaRce ·Nitti ttie CoRtract 9ocltFReRts prior to ttie effecti>,e date of terFRiRatioR, iRCllldiRg fair aRel reasoRable SllFRS for  overtieael aRd profit OR SllCA Work;
ei(peRses SltstaiReel prior to ttle effecti',•e date of terFRiRatioR iR perforFRiRg services aRd fomistliRg labo , FRaterials, or e llipFReRt as re ltired by ttle CoRtract 9owFReRts iR coRRectioR wittl ltRCOFRpleted Work, pills fair aRel reasoRable SltFRS  for  overtiead aRel profit OR SllCA el(peRses; aRel
ottler reasoRable ei(peRses elirectly attriblttable to terFRiRatioR, iRclltdiRg costs iRwrred to prepare a terFRiRatioR for coRveRieRce cost proposal.
Contractor shall not be paid for any loss of anticipated profits or revenue, post-termination overhead costs, consequential damages of any kind, or other economic loss arising out of or resulting from such termination.
Upon any such termination, Contractor shall:

Immediately discontinue Work on the date and to the extent specified in the notice except to the extent necessary to protect Work in place;
Place no further orders for materials, services, or facilities, other than as may be necessary or required for completion of such portion of Work under the Contract that is not terminated;
Promptly make every reasonable effort to obtain cancellation upon terms reasonably satisfactory to District of all purchase orders and Subcontracts to the extent they relate to the performance of Work terminated or assign to District those orders and Subcontracts and revoke agreements specified in such notice;
Reasonably assist District. as specifically requested in writing, in the maintenance, protection and disposition of property acquired by District under the Contract. as may be necessary;
Complete performance of any Work which is not terminated; and
Deliver to District an affidavit regarding the identity of unpaid potential lienors and the amounts due to each.
Contractor May Stop Work or Terminate
If, through no act or fault of Contractor, (1) the Work is suspended for more than 90 consecutive days by Owner or under an order of court or other public authority, or (2) Engineer fails to act on any Application for Payment within 30 days after it is submitted, or (3) Owner fails for 30 days to pay Contractor any sum finally determined to be due, then Contractor may, upon 7 days' written notice to Owner and Engineer, and provided Owner or Engineer do not remedy such suspension or failure within that time, terminate the rnntraEtContract and recover from Owner payment on the same terms as provided in Paragraph 16.03.
In lieu of terminating the Contract and without prejudice to any other right or remedy, if Engineer has failed to act on an Application for Payment within 30 days after it is submitted, or Owner has failed for 30 days to pay Contractor any sum finally determined to be due, Contractor may, 7 days after written notice to Owner and Engineer, stop the Work until payment is made of all such amounts due Contractor, including interest thereon. The provisions of this paragraph are not intended to preclude Contractor from submitting a Change Proposal for an adjustment in Contract Price or Contract Times or otherwise for expenses or damage directly attributable to Contractor's stopping the Work as permitted by this paragraph.

ARTICLE 17-FINAL RESOLUTION OF DISPUTES

Methods and Procedures
Disputes Subject to Final Resolution: The following disputed matters are subject to final resolution under the provisions of this article:
A timely appeal of an approval in part and denial in part of a Claim, or of a denial in full, pursuant to Article 12; and
Disputes between Owner and Contractor concerning the Work, or obligations under the Contract Documents, that arise after final payment has been made.

Final Resalutian of Disputes: For any dispute subject to resolution under this article, Owner or Contractor may:
elect in writing to invoke the dispute resolution process provided for in the Supplementary Conditions;
agree with the other party to submit the dispute to another dispute resolution process; or
if no dispute resolution process is provided for in the Supplementary Conditions or mutually agreed to, give written notice to the other party of the intent to submit the dispute to a court of competent jurisdiction.
In the event Owner or Contractor is required to enforce this Contract by court proceedings, alternative dispute resolution, appellate proceedings or otherwise, then the exclusive venue for any such legal action shall be in a court of appropriate jurisdiction in Clay County, Florida, and the prevailing party shall be entitled to recover from the other party all fees and costs, including reasonable attorney's fees and costs, paralegal fees. and expert witness fees, incurred in bringing or defending such action and/or enforcing any judgment granted in such action.

ARTICLE 18-MISCELLANEOUS

Giving Notice
Whenever any provision of the Contract requires the giving of written notice to Owner, Engineer, or Contractor, it will be deemed to have been validly given only if delivered:
in person, by a commercial courier service or otherwise, to the recipient's place of business;
by registered or certified mail, postage prepaid, to the recipient's place of business; or
by e-mail to the recipient, with the words "Formal Notice" or similar in the e-mail's subject line.
Computation of Times
When any period of time is referred to in the Contract by days, it will be computed te based on calendar days and shall exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation.
Cumulative Remedies
The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract. The provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation, right, and remedy to which they apply.

EJCDC® C 700, Standard General Conditions of the Construction Contract.
Copyright® 2018 National Society of Professional Engineers, American Council of Engineering Companies,

Limitation of Damages
With respect to any and all Change Proposals, Claims, disputes subject to final resolution, and other matters at issue, neither Owner nor Engineer, nor any of their officers, directors, members, partners, employees, supervisors. staff. agents, consultants, or subcontractors, shall be liable to Contractor for any claims, costs, losses, or damages sustained by Contractor on or in connection with any other project or anticipated project.
No Waiver
A party's non-enforcement of any provision will not constitute a waiver of that provision, nor will it affect the enforceability of that provision or of the remainder of this Contract.
Survival of Obligations
All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract, as well as all continuing obligations indicated in the Contract, will survive final payment, completion, and acceptance of the Work or termination of the Contract or of the services of Contractor.
Controlling Law
This Contract is to be governed by the law of the state in which the Project is located.
Assignment of Contract
Unless expressly agreed to elsewhere in the Contract, no assignment by a party to this Contract of any rights under or interests in the Contract will be binding on the other party without the written consent of the party sought to be bound; and, specifically but without limitation, money that may become due and money that is due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract.
Successors and Assigns
Owner and Contractor each binds itself, its successors, assigns, and legal representatives to the other party hereto, its successors, assigns, and legal representatives in respect to all covenants, agreements, and obligations contained in the Contract Documents.
Headings
A. Article and paragraph headings are inserted for convenience only and do not constitute parts of these General Conditions.
Sovereign Immunity
Contractor and Owner agree that nothing in this Contract shall be deemed as a waiver of the Owner's sovereign immunity or the Owner's limits of liability as set forth in Section 768.28. Florida Statutes, or other statute or law. and nothing in this Contract shall inure to the benefit of any third party for the purpose of allowing any claim which would otherwise be barred under such limitations of liability or by operation of law.
No Third-Party Beneficiaries

Except with respect to Contractor's indemnification of the lndemnitees as set forth herein, and except as otherwise specifically provided herein, this Contract is solely for the benefit of Owner and Contractor and no right or cause of action shall accrue upon or by reason, to or for the benefit of any third party not a formal party to this Contract (specifically including but not limited to any design professionals, subcontractors, or material suppliers directly engaged by Contractor). Nothing in this Contract expressed or implied is intended or shall be construed to confer upon any person or corporation other than Owner and Contractor any right, remedy, or claim under or by reason of this Contract or any of the provisions or conditions of this Contract; and all of the provisions, representations, covenants, and conditions contained in this Contract shall inure to the sole benefit of and shall be binding upon Owner and Contractor and their respective partners, representatives, successors, and assigns.

SUPPLEMENTARY CONDITIONS

ROLLING HILLS CDD- SHADOW CREST AT ROLLING HILLS

The following supplements establish information supplementary to the Standard General Conditions of the Construction Contract, EJCDC Document No. C-700, 2018 Edition (the "General Conditions"), including establishing insurance limits and other requirements pursuant to Article 6, and identifying certain reports relating to subsurface conditions and hazardous conditions at the site pursuant to Article 5.

Other changes have been marked directly in underlined and strike-through text on the Standard Form of Agreement and the General Conditions. The terms used in these Supplementary Conditions have the meanings stated in the General Conditions. Additional terms used in these Supplementary Conditions have the meanings stated below, which are applicable to both the singular and plural thereof.

SC-5.03 SUBSURFACE AND PHYSICAL CONDITIONS

l. Reports. Pursuant to Paragraph 5.03.A.l. of the General Conditions, the following reports of explorations and tests of subsurface conditions at or adjacent to the Site are known to Owner and were used by Engineer in the preparation of the Contract Drawings and Specifications:

Report of Exploratory Borings - Rolling Hills Section B, prepared by AGES of JAX, Inc., dated November 13, 2017.

Report of Exploratory Borings - Rolling Hills Section C, prepared by AGES of JAX, Inc., dated November 13, 2017.

Drawings. Pursuant to Paragraph 5.03.A.2. of the General Conditions, the following drawings of physical conditions relating to existing surface or subsurface structures at or adjacent to the Site (except Underground Facilities) are known to Owner and were used by Engineer in the preparation of the Contract Drawings and Specifications:

No drawings related to physical conditions and subsurface structures at the Site are known to the Owner.

Technical Data. Pursuant to Paragraph 5.03.A.3. of the General Conditions, the following Technical Data is contained in the reports and drawings of subsurface and physical conditions:

No reports or drawings related to physical conditions and subsurface structures at the Site are known to the Owner.

SC-5.06 HAZARDOUS ENVIRONMENTAL CONDITIONS AT SITE

l. Reports. Pursuant to Paragraph 5.06.A.l. of the General Conditions, the following reports of Hazardous Environmental Conditions at or adjacent to the Site are known to Owner:

No reports or drawings related to Hazardous Environmental Conditions at the Site are known to Owner.

Drawings. Pursuant to Paragraph 5.06.A.2. of the General Conditions, the following drawings of Hazardous Environmental Conditions at or adjacent to the Site are known to Owner:

No reports or drawings related to Hazardous Environmental Conditions at the Site are known to Owner.

Technical Data. Pursuant to Paragraph 5.06.A.3. of the General Conditions, the following Technical Data is contained in the reports and drawings of Hazardous Environmental Conditions:

No reports or drawings related to Hazardous Environmental Conditions at the Site are known to Owner.

SC-6.01 PERFORMANCE, PAYMENT, AND OTHER BONDS

Contractor must provide the required Payment and Performance Bonds as required in the General Conditions. Pursuant to Paragraph 6.01.B. ofthe General Conditions, the following additional bonds are required:

N/A

SC-6.03 CONTRACTOR'S INSURANCE

Pursuant to Paragraph 6.03.A. of the General Conditions, the limits of Contractor's required insurance shall be as follows.

Contractor shall provide coverage for not less than the following amounts, or greater where required by Laws and Regulations:

Workers' Compensation and Employer's Liability

Workers' Compensation	Statutory	
Employer's Liability	
Each Accident	$1,000,000	
Each Employee	$1,000,000	
Policy Limit	$1,000,000	

Commercial General Liability

General Aggregate	$2,000,000	
Products - Completed Operations Aggregate	$3,000,000	
Personal and Advertising Injury	$3,000,000	
Bodily Injury and Property Damage*-Each Occurrence	$1,000,000	

*Property Damage liability shall pravide explasian, ca/lapse, and under-graund coverages where applicable.

Automobile Liability*

Bodily Injury	
Each Person	I $1,000,000	
Each Accident	I $1,000,000	
Property Damage	
Each Accident	I $1,000,000	
[OR]	
Combined Single Limit (Bodily Injury and Property Damage) I $2,000,000	

Automobile liability insurance shall include coverage for all owned, non-owned, and hired vehicles

d.	Excess or Umbrella Liability•		
	Per Occurrence	$3,000,000	
	General Aggregate	$5,000,000	

e.	

I Eash GccurrnRce/Claim GeReFal Aggregate

I $1,Q00,00Q
$2,0Q0,00Q

*Polltit.'rm 1/abi.lity s/Ja/1 eo1-er t/JirrJ party in}!lr)' anrJ property rJamaye elaims, ine.l!lr#ny dean !ip easts.
B!li.irier's Risk

Amo!lnt	upon the Wo,k on a completeel •,alue Basis, in Hie amount of the full insu,aBle replacement cost thereof)

,'{.

Form must Be written on a Buileler's risk "all risk" policy farm Hiat shall at least incluele insurance fsF ph•tsical loss or samage to the Worl(, temporary Builelings, falseworl(, ans materials ans CE!Uipment in trnnsit, anel shall insure against at least the fellowing pe,ils or causes of loss: fire; lightning; winelstorm; Fist; civil commotion; te,rorism; •,chicle impact; airc,aft; smol(e; theft; vansalism anel malicious mischief; mechanical Breal(sown, Baile, CJEplosion,  anel a,tificiall\' generateel electric current; earthEjual1e; volcanic activity, anel  other eartl'l movement; floes; collapse; eJEplosion; eleBris removal; elemolition occasiones BV enfsrcement of Laws ans Regulations; water elamage (other than that causes By flooel); ans sucl'l other perils or causes of loss as ma',' BC specifically FCEjuires B',' the Supplementary Consitions. If insurance against mechanical Breal(elown, Boiler eJEplosion, ans artificially generateel electric cu,rent; earthEjual(e; volcanic activity, anel other earth movement; or flooel, are not commerciall\' availaBle uneler Buileler's risk policies, By ensorsement or otherwise, sucl'l insurance may Be provieleel tl'lrough other insurance policies acceptaBle to Owner anel Contractor.

£cape eover, as insureel property, at least tile fallowing: {a) tile '.',1ork and all rnaterials, supplies, rnaelliner,, apparatus, e!juiprnent, fottures, anel  otller property of a sirnilar nature tllat are to ee ineorporated into or used in tile preparation, faerieation, eonstruetion, ereetion, or eornpletion of tile Worl1, ineluding Owner furnislled or assigned propert','; {l:l) spare parts in ·entor,· re!juired witllin tile seope of tile Contra et; and {e) ternporary worl1s wlliell are not inteneled to forrn part of tile perrnanent eonstrueted V.'ork eut wlliell are inteneled to proviele working aeeess  to tile Site, or to tile Work uneler eonstruetion, or wlliell are inteneled to proviele ternporar',' support far tile VVork under eonstruetion, inelueling seaffoleling, farrn work, fenees, slloring, falseworl1, and ternporary struetures;

eover ei1penses ineurreel in tile repair or replaeernent of any insureel property
{inelueling eut not lirniteel to fees and ellarges of engineers and arelliteets);

ei1tend to eover darnage or loss to insured propert',' wllile in ternporar,· storage at tile Site or in a storage loeation outside tile Site {eut not ineluding property storeel at tile prernises of a rnanufaeturer or Supplier);

mttenel to eover darnage or loss to insureel property \\'Aile in transit;

allow for partial oeeupation or use of tile Work ey Owner, suell tllat tllose portions of tile Work tllat are not yet oeeupieel or used ey Owner sllall rernain eovered ey tile euileler's risk insuranee;

allow for tile '#aiver of tile insurer's suerogation rigllts, as set fortll eelow;

pro•Jiele prirnary eoverage for all losses anel elarnages eauseel B',' tile perils or eauses of loss eovereel;

not ineluele a eo insuranee elause;

ineluele an mmeption for ensuing losses frorn pll','sieal darnage or loss witll respeet to any elefeetive workrnansllip, elesign, or rnaterials ei1elusions;

ineluele perforrnanee,'llot testing anel start up; anel

ee maintained in effeet, suejeet to tile pro•Jisions llerein regarding Suestantial Gornpletion and partial oeeupaney or use of tile Work B'f  Owner, until tile Work is eomplete.
All insurance policies required to be purchased and maintained will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days after notice has been received by the purchasing policyholder. Within three days of receipt of any such notice, the purchasing policyholder shall provide a copy of the notice to each other insured and Engineer.
Automobile liability insurance provided by Contractor will be written on an occurrence basis and provide coverage against claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance, or use of any motor vehicle.

Contractor's commercial general liability policy will be written on a 1996 or later ISO commercial general liability occurrence form and include the following coverages and endorsements:
Products and completed operations coverage maintained for three (3) years after final payment;
Blanket contractual liability coverage to the extent permitted by law;
Broad form property damage coverage; and
Severability of interest; underground, explosion, and collapse coverage; personal injury coverage.
The Contractor's commercial general liability and automobile liability, umbrella or excess, f)eih,itieA liaeility aAEI  euilaer's risk fJOliEies will include and list Owner, Engineer, Garden Street Communities Southeast, LLC. [Landowner] and the respective supervisors, subsidiaries, affiliates, professional staff, officers, directors, members, partners, employees, agents, consultants, and subcontractors of each as additional insureds; and the insurance afforded to these additional insureds will provide primary coverage for all claims covered thereby (including, as applicable, those arising from both ongoing and completed operations) on a non-contributory basis.
Additional insured endorsements will include both ongoing operations and products and completed operations coverage through ISO Endorsements CG 20 10 10 01 and CG 20 37 10 01 (together). If Contractor demonstrates to Owner that the specified ISO endorsements are not commercially available, then Contractor may satisfy this requirement by providing equivalent endorsements.
CeAtractor shall f)reviae ISO  EAElersemeAt CG 2Q 32 07 04, "/\EIElitieAal IAsurea EAgiAeers, l\rEhiteEts er Sur-,eyors Net EAgagea e · the Namea IAsurea" or its eE!uivaleAt fer ElesigA tirefessieAal aaelitieAal iAsureels.
Umbrella or excess liability insurance will be written over the underlying employer's liability, commercial general liability, and automobile liability insurance. The coverage afforded must be at least as broad as that of each and every one of the underlying policies. Contractor may meet the policy limits specified for employer's liability, commercial general liability, and automobile liability through the primary policies alone, or through combinations of the primary insurance policy's policy limits and partial attribution of the policy limits of an umbrella or excess liability policy that is at least as broad in coverage as that of the underlying policy.
The CeAtracter shall fJFeviele tirof)erty iAsuraAEe EoveriAg flhysiEal loss er Elamage eluriAg EOAstruEtieA to structures, materials, fo1tures, aAEl  eE1Uif)meAt, iAElueliAg these materials, ii1tures, or eE1Uif)meAt iA sterage or traAsit.
If Contractor has failed to obtain and maintain required insurance, Owner may exclude the Contractor from the Site, impose an appropriate set-off against payment, and exercise Owner's termination rights under Article 15. Alternatively, the Owner has the right but not the obligation to secure such required insurance in which event Contractor shall pay the cost for that required insurance and shall furnish, upon demand, all information that may be required in connection with the Owner's obtaining the required insurance.

SC-8.0Z COORDINATION

Pursuant to Paragraph 8.02 of the General Conditions, if Owner intends to contract with others for the performance of other work at or adjacent to the Site, to perform other work at or adjacent to the Site with Owner's employees, or to arrange to have utility owners perform work at or adjected to the Site, the following information pertains to such other work:

The identity of the individual or entity that will have authority and responsibility for coordination of the activities among the various contractors:

Garden Street Communities Southeast, LLC.

An itemization of the specific matters to be covered by such authority and responsibility:

Coordination with utility service providers, contracting with a landscaping subcontractor and purchase and installation of mailboxes, and all required conduits for Clay Electric and the chosen cable company, beyond the under road pipe sleeves

The extent of such authority and responsibilities: To determine final scope and schedule.
SC-10.03 RESIDENT PROJECT REPRESENTATIVE

Pursuant to Paragraph 10.03.A. of the General Conditions, if Engineer will furnish a Resident Project Representative to represent Engineer at the Site and assist Engineer in observing the progress and quality of the Work, that representative and its authorities and responsibilities are identified below.

N/A

Pursuant to Paragraph 10.03.B. of the General Conditions, if Owner designates an individual or entity who is not Engineer's consultant, agent, or employee to represent Owner at the Site, that representative and its responsibilities and authorities are identified below.

[Sco13e of BUties as iBeAtifieB iA Hie PeFSOAAel beasiAg P,gFeeR'leAt by JAB betweeA the 0•1meF JAB COAStFUcti0A MaAageF]

Bond Number: 0637016

PERFORMANCE BOND

'"'--- - ---...

:	...· =:=·t, -' l "_-

Contractor
Name:	Pipeline Constructors, Inc,
Address (principal place of business/:
2117 N. Temple Avenue Starke, FL 32091
Teleohooe Number: 904-964-Z019	Surety
Name:	Harco National Insurance Company
Address (principal place of business/:
4200 Six Forks Road, Suite 1400, Raleigh, NC 27609

Telephone Number: 973-776-3523	
Owner
Name:	Rolling Hills Community Deveiopmant
District
Mailing address (principal place of business/:
C/0 Goven,menta! Management Services, U..C. 475 Vt/est Town Place, Sulte 114
St. Augustine, Fl. 32092
Jels,12hone Number: 904-940-5_850	Contract

Description: 247 !ot subdivision

Contract Price: $8,057,453.00
Eight Million Fifty Seven Thousand Four Hundred
Fifty Three and 00/100 Dollars
Effective Date of Contract:	February 9, 2022	
Bond
Bond Amount:	$8,057,453.00  Eight Million Fifty Seven Thousand Four Hundred Fifty Three and 00/100 Dollars
Date of Bond:	February 16, 2022
(Date of Bond cannot be earlier than Effective Date of Contract)
Modifications to this Bond form:
□ None C::i:I See Paragraph 16	
Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth in this Performance Bond, do each cause this Performance Bond to be duly executed by an authorized officer,
agent, or representative.	
Contractor as Principal
Pipeline Constructors, Inc.	Surety
Harco National Insurance Comnanv	
(F  a,/ na'r) etul lcorp rate seal) .  - ··_·
By:	By:	:,,	/		,	)	,,' :,_,_
-	(Signatufe}(Attacu ........r'J:fo:...![o ey(-:··;·-
Name:	Dana Granice	:::.. -· -----. 	

(Signature)
Name:	Melissa Saracino
(Printed or typed)
Title:	Surety Account Representative

EJCDC8 C-610, Performance Bond.
CopyrightlD 2018 National Society of Professional Engineers, American Council of Engirleering Companies, and American Society of Civil Engineers. Allrights reserved.

Notes: (1) Provide supplemental execution by any additional parties, such asJoint venturers. {2/ Any singular reference
to Contractori Surety Owner or other party is considered plural where applicable.

The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference.
If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Paragraph 3.
If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond will arise after:
The Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice may indicate whether the Owner is requesting a conference among the Owner, Contractor, and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Paragraph 3.1 will be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor, and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement does not waive the Owner's right, if any, subsequently to declare a Contractor
Default;
The Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and
The Owner has agreed to pay the Balance of the Contract Price in accordance with the terms of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract.
Failure on the part of the Owner to comply with the notice requirement in Paragraph 3.1 does not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice.
When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions:
Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract;
Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors;
Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owners concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or

EJCDC" C-610, Performance Bond.
Copyright© 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.
PageZof4

Waive its right to perform and complete, arrange for completion, or obtain a new contractor, and with reasonable promptness under the circumstances:
After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner; or
Deny liability in whole or in part and notify the Owner, citing the reasons for denial.
If the Surety does not proceed as provided in Paragraph 5 with reasonable promptness, the Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Paragraph 5.4, and the Owner refuses the payment, or the Surety has denied liability, in whole or in part, without further notice, the Owner shall be entitled to enforce any remedy available
to the Owner.
If the Surety elects to act under Paragraph 5.1, 5.2, or 5.3, then the responsibilities of the Surety to the Owner will not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety will not be greater than those of the Owner under the Construction Contract. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication for:
the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract;
additional legal, design professional, and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 5; and
liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor.
If the Surety elects to act under Paragraph 5.1, 5.3, or 5.4, the Surety's liability is limited to the amount of this Bond.
The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price will not be reduced or set off on account of any such unrelated obligations. No right of action will accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors, and assigns.
The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations.
Any proceeding, legal or equitable, under this Bond must be instituted in any court of competent jurisdiction in the iocation in which the work or part of the work is located and must be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs first. If the provisions of this paragraph are void or prohibited by law, the minimum periods of limitations available to sureties as a defense in the jurisdiction of the suit will be applicable.
Notice to the Surety, the Owner, or the Contractor must be mailed or delivered to the address shown on the page on which their signature appears.
When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said
EJCDC111C1 -610, Performance Bond.
Copyright• 2018 National Society of Professional Engineers, American Council of Engineering Companies,

statutory or legal requirement will be deemed deleted therefrom and provisions conforming to such statutory or other legal requirement will be deemed incorporated herein. When so furnished, the intent is that this Bond will be construed as a statutory bond and not as a common law bond.
Definitions
Balance of the Contract Price-The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made including allowance for the Contractor for any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid
and proper payments made to or on behalf of the Contractor under the Construction Contract.
Construction Contract-The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents.
Contractor Default-Failure of the Contractor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract.
Owner Default-Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.
Contract Documents-All the documents that comprise the agreement between the Owner and Contractor.
If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond will be deemed to be Subcontractor and the term Owner will be deemed to be Contractor.
Modifications to this Bond are as follows: This Bond is hereby amended so that the provisions and limitations of Section 255.05, including without limitation subsection (6) and the notice and time limitation provisions in subsections (2) and (10), or Sections 713.23 and 713.245, Florida Statutes. whichever are applicable, are incorporated by reference herein.

EJCDC" C-610, Performance Bond.
CopyrightlD 2018 National Society of Professional Engineers, American Council of Engineering Companies,

POWER OF ATTORNEY
HARCO NATIONAL INSURANCE COMPANY INTERNATIONAL FIDELITY INSURANCE COMPANY

Bond#	0637016	

Member companies of IAT Insurance Group, Headquartered: 702 Oberlin Road, Raleigh, North Carolina 27605

KNOW ALL MEN BY THESE PRESENTS: That HARCO NATIONAL INSURANCE COMPANY, a corporation organized and existing under the laws of the State of Illinois, and INTERNATIONAL FIDELITY INSURANCE COMPANY, a corporation organized and existing under the laws of the State of New Jersey, and having their principal offices located respectively in the cities of Rolling Meadows, Illinois and Newark, New Jersey, do hereby constitute and appoint
DESIREE CAROLIN, DANA GRANICE, MICHELLE WANNAMAKER, KATHERINE ACOSTA, THOMAS BEAN, GERARD S.
MACHOLZ, CAMILLE MAITLAND, SUSAN LUPSKI, ROBERT T. PEARSON, RITA LOSQUARO, COLETTE R. CHISHOLM
Uniondale, NY
their true and lawful attorney(sHn-fact to execute, seal and deliver for and on its behalf as surety, any and all bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof, which are or may be allowed, required or permitted by law, statute, rule,·regulation, contract or otherwise, and the execution of such instrument(s) in pursuance of these presents, shall be as binding upon the said HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY, as fully and amply, to all intents and purposes, as if the same had
been duly executed and acknowledged by their regularly elected officers at their principal offices.
This Power of Attorney is executed, and may be revoked, pursuantto and by authority of the By-Laws of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY and is granted under and by authority of the following resolution adopted by the Board of Directors of INTERNATIONAL FIDELITY INSURANCE COMPANY at a meeting duly held on the 13th day of December, 2018	and by the Board of Directors of HARCO NATIONAL INSURANCE COMPANY at a meeting held on the 13th day of December, 2018.
"RESOLVED, that (1) the Chief Executive Officer, President, Executive Vice President, Senior Vice President, Vice President, or Secretary of the Corporation shall have the power to appoint, and to revoke the appointments of, Attorneys-in-Fact or agents with power and authority as defined or limited in their respective powers of attorney, and to execute on behalf of the Corporation and affix the Corporation's seal thereto, bonds, undertakings, recognizances, contracts of indemnity and other written obligations in the nature thereof or related thereto; and (2} any such Officers of the Corporation may appoint and revoke the appointments of joint-control custodians, agents for acceptance of process, and Attorneys-in-fact with authority to execute waivers and consents on behalf of the Corporation; and (3} the signature of any such Officer of the Corporation and the Corporation's seal may be affixed by facsimile to any power of attorney or certification given for the execution of any bond, undertaking, recognizance, contract of indemnity or other written obligation in the nature thereof or related thereto, such signature and seals when so used whether heretofore or hereafter, being hereby adopted by the Corporation as the original signature of such officer and the original seal of the Corporation, to be valid and binding upon the Corporation with the same
force and effect as though manually affixed."

IN WITNESS WHEREOF, HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL
FIDELITY INSURANCE COMPANY have each executed and attested these presents

on this  31st  day of  December, 2018

STATE OF NEW JERSEY
County of Essex

STATE OF ILUNOIS
County of Cook

Kenneth Chapman
Executive Vice President, Harco National Insurance Company and International Fidelity Insurance Company

On this 31st day of December, 2018	, before me came the individual who executed the preceding instrument, to me personally known, and, being by me duly sworn, said he Is the therein described and authorized officer of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY; that the seals affixed to said instrument are the Corporate Seals of said Companies; that the said Corporate Seals and his signature were duly affixed by order of the Boards of Directors of said Companies.

IN TESTIMONY WHEREOF, I have hereunto set my hand affixed my Official Seal, at the City of Newark, New Jersey the day and year first above written.

CERTIFICATION

My Commission Expires April 4,·2023

I, the undersigned officer of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY do hereby certify that I have compared the foregoing copy of the Power of Attorney and affidavit, and_.the copy of the Sections of the By-Laws of said Companies as set forth in said Power of Attorney, with the originals on file in lhe home office of said.-Cortlpc!_□ies:-BiicfthaJ the same are correct transcripts thereof, and of the
whole of the said originals, and that lhe said Power of Attorney has not been re_l1oked_8nd is now in tulLforce and effect.
.:: '.,- ,-	- -	. '

IN TESTIMONY WHEREOF, I have hereunto set my hand on this day,

Febriiaty til. 2022..::_ _

- .

:::
t -:: '--	- ..:	,- -	/7	, ti

A01946

 --- - ::,-- -:----: :---"	

·'lfene Martins, Assistant Secretary

Bond Number: 0637016

PAYMENT BOND

Contractor
Name:	Pipeline Constructors, inc.
Address (principal place of business): 2117 N, Temple Avenue Starke, Fl. 32091
Telepr,one Number: 904-964-2019	Surety
Name:	Harco National Insurance Company
Address {principal place of business):
4200 Six Forks Road, Suite 1400, Raleigh, NC 27609

Telephone Number: 973-776-3523	

Owner
Ro!Hr g Hills Comm"'mity Development Name:	Dlstrlct
Mailing address (principal place of business):
C/0 Governmental Management Services, llC,
475 VJest Town Place, Suite 114 St. ,'\ugustinc, Ft 32092 T.filfillli_one lumber: 904-940-58.50	Contract	
	Description (name and location):
Shadov1 Crnst at Ro!iing Hil!s, Clay Cmmty, F!mida
Contract Price:	$8,057,453.00	
	Eight Million Fifty Seven Thousand Four Hundred Fifty Three	
	and 00/100 Dollars	
	Effective Date of Contract:	Februa	9, 2022	
Bond
Bond Amount:	$8,057,453.00  Eight Million Fifty Seven Thousand Four Hundred Fifty Three and 00/100 Dollars
Date of Bond:	February 16, 2022
(Date of Bond cannot be earlier thon Effective Date of Contract)
Modifications to this Bond form:
D None 181 See Paragraph 18	
Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth in this Payment Bond, do each cause this Payment Bond to be duly executed by an authorized officer, agent, or
re resentative.	
Contractor as Principal
Pipeline Constructors, Inc.	Surety			
By:	(Fullform .t!!;!7;
Ro  {] (Signature)	K_
Name:.	X\	nmw  /
P Jq,ft ,4£
(Printed or typed)

Title:	
By:

Name:

Title:	

Dana Granice	"' -,--..	
		/Printed or typed)
Attorne -In-Fact	
 Atte /-·f U&	-d	Witness:
J/)(l)OOIJQ<: .ue_,l
Name:	t Y\ \.)/t	Name:	Melissa Saracino
}?.!Wa'i'1re)
'J	/Print d or typed)	(Printed or typed)
Title:	       Title:	Surety Account Representative
Notes: /1) Provide supp	ental execution by ny oddltionol port/es, such os joint venturers. (2) Any singularreference to
Contractor., Surety, Owner, or other party is considered plural where applicable.	

EJCDC8 C-615, Payment Bond.

'--
- -:~·-<

The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors, and assigns to the Owner to pay for labor, materials, and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms.
If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies, and holds harmless the Owner from claims, demands, liens, or suits by any person or entity seeking payment for labor, materials, or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond.
If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond will arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Paragraph 13) of claims, demands, liens, or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials, or equipment furnished for use in the performance of the Construction Contract, and tendered defense of such claims, demands, liens, or suits to the Contractor and the Surety.
When the Owner has satisfied the conditions in Paragraph 3, the Surety shall promptly and at the Surety's expense defend, indemnify, and hold harmless the Owner against a duly tendered claim, demand, lien, or suit.
The Surety's obligations to a Claimant under this Bond will arise after the following:
Claimants who do not have a direct contract with the Contractor
121..1. have furnished a written notice of non-payment to the Contractor, stating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, furnished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and
121..2. have sent a Claim to the Surety (at the address described in Paragraph 13).
Claimants who are employed by or have a direct contract with the Contractor have sent a Claim to the Surety (at the address described in Paragraph 13).
If a notice of non-payment required by Paragraph 5.1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Paragraph 5.1.1.
When a Claimant has satisfied the conditions of Paragraph 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions:
Send an answer to the Claimant, with a copy to the Owner, within sixty {60) days after receipt of the Claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed; and
Pay or arrange for payment of any undisputed amounts.
The Surety's failure to discharge its obligations under Paragraph 7.1 or 7.2 will not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which the Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Paragraph 7.1 or 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover anv sums found to be due and owing to the Claimant.
EJcoc• C-615, Payment Bond.

The Surety's total obligation will not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Paragraph 7.3, and the amount of this Bond will be credited for any payments made in good faith by the Surety.
Amounts owed by the Owner to the Contractor under the Construction Contract will be used for the performance of the Construction Contract and to satisfy claims, if any, under any construction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfying obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work.
The Surety shall not be liable to the Owner, Claimants, or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to or give notice on behalf of Claimants, or otherwise have any obligations to Claimants under this Bond.
The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders, and other obligations.
No suit or action will be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Paragraph 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit will be applicable.
Notice and Claims to the Surety, the Owner, or the Contractor must be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, will be sufficient compliance as of the date received.
When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement will be deemed deleted here from and provisions conforming to such statutory or other legal requirement will be deemed incorporated herein. When so furnished, the intent is that this Bond will be construed as a statutory bond and not as a common law bond.
Upon requests by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly furnish a copy of this Bond or shall permit a copy to be made.
Definitions
Claim-A written statement by the Claimant including at a minimum: 132..1. The name of the Claimant;
132..2. The name of the person for whom the labor was done, or materials or equipment furnished;
132..3. A copy of the agreement or purchase order pursuant to which labor, materials, or equipment was furnished for use in the performance of the Construction Contract;
132..4. A brief description of the labor, materials, or equipment furnished;
EJCOC® C 615, Payment Bond;
Copyright«i 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved,

132..5. The date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract;
132..6. The total amount earned by the Claimant for labor, materials, or equipment furnished as of the date of the Claim;
132..7. The total amount of previous payments received by the Claimant; and
132..8. The total amount due and unpaid to the Claimant for labor, materials, or equipment furnished as of the date of the Claim.
Claimant-An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials, or equipment for use in the performance of the Construction Contract. The term Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond is to include without limitation in the terms of "labor, materials, or equipment" that part of the water, gas, power, light, heat, oil, gasoline, telephone service, or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials, or equipment were furnished.
Construction Contract-The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents.
Owner Default-Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.
Contract Documents-All the documents that comprise the agreement between the Owner and Contractor.
If this Bond is issued for an agreement between a contractor and subcontractor, the term Contractor in this Bond will be deemed to be Subcontractor and the term Owner will be deemed to be Contractor.
Modifications to this Bond are as follows: This Bond is hereby amended so that the provisions and limitations of Section 255.05. including without limitation subsection 161 and the notice and time limitation provisions in subsections 121 and 1101. or Sections 713.23 and 713.245, Florida Statutes, whichever are applicable. are incorporated by reference herein.

EJCOC* C-615, Payment Bond.
Copyright"' 2018 National Society of Professional Engineers, American Council of Engineering Companies, and American Society of Civil Engineers. All rights reserved.

POWER OF ATTORNEY
HARCO NATIONAL INSURANCE COMPANY INTERNATIONAL FIDELITY INSURANCE COMPANY

Bond#	0637016	

Member companies of IAT Insurance Group, Headquartered: 702 Oberlin Road, Raleigh, North Carolina 27605

KNOW ALL MEN BY THESE PRESENTS: That HARCO NATIONAL INSURANCE COMPANY, a corporation organized and existing under the laws of the State of Illinois, and INTERNATIONAL FIDELITY INSURANCE COMPANY, a corporation organized and existing under the laws of the State of New Jersey, and having their principal offices located respectively in the cities of Rolling Meadows, Illinois and Newark, New Jersey, do hereby constitute and
appoint
DESIREE CAROLIN, DANA GRANICE, MICHELLE WANNAMAKER, KATHERINE ACOSTA, THOMAS BEAN, GERARD 5.
MACHOLZ, CAMILLE MAITLAND, SUSAN LUPSKI, ROBERT T. PEARSON, RITA LOSQUARO, COLETTE R. CHISHOLM
Uniondale, NY
their true and lawful attorney(s)-in-fact to execute, seal and deliver for and on its behalf as surety, any and all bonds and undertakings, contracts of indemnity and other writings obligatory in the nature thereof, which are or may be allowed, required or permitted by law, statute, rule, regulation, contract or otherwise, and the execution of such instn.iment(s) in pursuance of these presents, shall be as binding upon the said HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY, as fully and amply, to all intents and purposes, as if the same had been duly executed and acknowledged by their regularly elected officers at their principal offices.
This Power of Attorney is executed, and may be revoked, pursuant to and by authority of the By-Laws of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY and is granted under and by authority of the following resolution adopted by the Board of Directors of INTERNATIONAL FIDELITY INSURANCE COMPANY at a meeting duly held on the 13th day of December, 2018	and by the Board of Directors of HARCO NATIONAL INSURANCE COMPANY at a meeting held on the 13th day of December, 2018.
"RESOLVED, that (1) the Chief Executive Officer, President, Executive Vice President, Senior Vice President, Vice President, or Secretary of the Corporation shall have the power to appoint, and to revoke the appointments of, Attorneys-in-Fact or agents with power and authority as defined or limited in their respective powers of attorney, and to execute on behalf of the Corporation and affix the Corporation's seal thereto, bonds, undertakings, recognizances, contracts of indemnity and other written obligations in the nature thereof or related thereto; and (2) any such Officers of the Corporation may appoint and revoke the appointments of joint-control custodians, agents for acceptance of process, and Attorneys-in-fact with authority to execute waivers and consents on behalf of the Corporation; and (3) the signature of any such Officer of the Corporation and the Corporation's seal may be affixed by facsimile to any power of attorney or certification given for the execution of any bond, undertaking, recognizance, contract of indemnity or other written obligation in the nature thereof or related thereto, such signature and seals when so used whether heretofore or hereafter, being hereby adopted by the Corporation as the original signature of such officer and the original seal of the Corporation, to be va!td and binding upon the Corporation with the same
force and effect as though manually affixed."

IN WITNESS WHEREOF, HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL

FIDELITY INSURANCE COMPANY have each executed and attested these presents on this 31st day of December, 2018

STATE OF NEW JERSEY
County of Essex

STATE OF ILLINOIS
County of Cook

Kenneth Chapman
Executive Vice President, Harco National Insurance Company and International Fidelity Insurance Company

On this 31st day of December, 2018	, before me came the individual who executed the preceding instrument, to me personally known, and, being by me duly sworn, said he is the therein described and authorized officer of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMPANY; that the seals affixed to said instrument are the Corporate Seals of said Companies; that the said Corporate Seals and his signature were duly affixed by order of the Boards of Directors of said Companies,

IN TESTIMONY WHEREOF, I have hereunto set my hand affixed my Official Seal, at the City of Newark, New Jersey the day and year first above written.

CERTIFICATION

J/iM.Ju a.  	:_: ·.··...
ShirelleA.Outley a Notary PublicofNe_ - ;-L·		-	_ My Commission Expires April_4, 20?3	-	--_ ·-< \
... - -

I, the undersigned officer of HARCO NATIONAL INSURANCE COMPANY and INTERNATIONAL FIDELITY INSURANCE COMflANy d6-.ti€rebice(!,lfy: -"­ that I have compared the foregoing copy of the Power of Attorney and affidavit, and the copy of the Sections of the By-Laws of s8Jd·tompanies°'as set:::---•
forth in said Power of Attorney, with the originals on file in the home office of said companies, and that the same are correct transCrij:its·tlter_eof, and Q_tihe-" -
whole of the said originals, and that the said Power of Attorney has not been revoked and is now in full force and effect.	-,	-

IN TESTIMONY WHEREOF, I have hereunto set my hand on this day,  February 16, 2022

A01946
Irene Martins, Assistant Secretary

SECTION Ill

SUMMARY OF COSTS, SCHEDULE AND SPECIAL CONDITIONS

Attached is the Summary of Costs

Attached is the Schedule

Special Conditions:
Site Access:
The Site Contractor will utilize the unbuilt road access on the east side of the Rolling Hills project, from the northerly access south to the project, for all practical deliveries and truck access. The site contractor will install the required Clay County construction base materials at the project entrance, along with signage, indicating that this is strictly for construction access and that all other traffic is forbidden.
The Site Contractor will also install a project access, with required Clay County base requirements, at the entrance from Laurel Springs Drive.
The Site Contractor will install control gates/fences (at their choosing) to be used at each entrance.
There will be times where access will be required through the community,
however, the goal is to minimize as much as possible, any and all construction traffic from the completed Rolling Hills development.
Export of excess dirt from the site:
The contract amount assumes that because of anticipated excess dirt onsite, and the opinion that other projects in the area require dirt import, that excess dirt can be sold, The contract assumes that after the costs for loading equipment, manpower required to load trucks, and cost of truck rental are factored in, there will be $ 300,000 in net income. That net income of$ 300,000 is assumed in the contract amount, to defray the cost of the project.
Further, there is the possibility of over excavating the required ponds, and generating additional excess dirt for sale. The over excavation of any pond will only be performed with the approval of any government agency. Any sale of excess dirt, which generates additional income beyond$ 300,000, after consideration for the cost for the loading equipment, manpower to load trucks, project management, and cost of trucking, will be split 50% to the developer and 50% to the site contractor. These costs will be monitored on a monthly basis.
Project exclusions:
Mailboxes
Landscaping and irrigation.
Conduits required for Clay Electric.
Conduits required for the chosen cable company, except for the under road sleeves shown on the plans.
Road signage
Monument Signs

SECTION IV

REPORT OF GEOTECHNICAL EXPLORATION

Report of Exploratory Borings - Rolling Hills Section B, prepared by AGES of JAX, Inc., dated November 13, 2017.

Report of Exploratory Borings - Rolling Hills Section C, prepared by AGES of JAX, Inc., dated November 13, 2017.

SECTIONV

LIST OF CONTRACT DOCUMENTS

SHEET
C-1
C-2
C-3
C-4
C-5
C-6
C-7
C-8
C-9 C-10 C-11 C-12 C-13 C-14
C-15 C-16 C-17 C-18 C-19
C-20
C-21 C-22 C-23 C-24 C-25 C-26
C-27 C-28

DESCRIPTION
COVER
GENERAL NOTES GENERAL NOTES PROJECT LEGEND
EROSION CONTROL NOTES AND DETAILS
EXISTING CONDITIONS AND EROSION CONTROL PLAN SITE GEOMETRY PLAN - KEY MAP
SITE GEOMETRY PLAN SITE GEOMETRY PLAN SITE GEOMETRY PLAN
PAVING, GRADING AND DRAINAGE PLAN - OVERALL PAVING, GRADING AND DRAINAGE PLAN
PAVING, GRADING AND DRAINAGE PLAN PAVING, GRADING AND DRAINAGE PLAN UTILITY PLAN - OVERALL
UTILITY PLAN - KEY MAP UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE UTILITY PLAN AND PROFILE

Date
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021
12/20/2021

LIST OF CONTRACT DOCUMENTS

SHEET	DESCRIPTION	Date	
C-29	UTILITY PLAN AND PROFILE	12/20/2021	
C-30	UTILITY PLAN AND PROFILE	12/20/2021	
C-31	UTILITY PLAN AND PROFILE	12/20/2021	
C-32	CONSTRUCTION DETAILS	12/20/2021	
C-33	CONSTRUCTION DETAILS	12/20/2021	
C-34	CONSTRUCTION DETAILS	12/20/2021	
C-35	CONSTRUCTION DETAILS	12/20/2021	
C-36	UTILITY DETAILS - WATER	12/20/2021	
C-37	UTILITY DETAILS- WATER	12/20/2021	
C-38	UTILITY DETAILS - WATER	12/20/2021	
C-39	UTILITY DETAILS - WASTEWATER	12/20/2021	
C-40	UTILITY DETAILS - RECLAIMED	12/20/2021	
S-SPD	CCUA STD. TECHNICAL SPECIFICATIONS	6/6/2017	
	PERMITS		
St. Johns River Water Management District - ERP Permit Number 81625-7 November 19, 2021

Clay County Utility Authority - Approval Letter Clay County DRC-Approval Letter

December 13, 2021
January 4, 2022

THESE PLANS ARE FOR REFERENCE AND COORDINATION ONLY-This work is not part of this contract agreement.

SHEET	DESCRIPTION	Date	
Ll.0	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	
Ll.1	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	
Ll.2	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	
Ll.3	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	
Ll.4	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	
Ll.5	LANDSCAPE PLAN PREPARED BY JDV LANDSCAPE ARCHITECT	11.16.21	

1 of 1	
WO# 302693 DRAWING BY CLAY ELECTRIC COOPERATIVE	
9.23.21	

SUMMARY OF COSTS SECTION III. A
Shadow Crest at Rolling Hills - CDD Phase 3B & 3C

I	Mobilization and General Conditions	I	$	180,500.00	$	180,500.00	
2	Clearing and Earthwork	I	$ 1,848,236.00	$ 1,848,236.00	
3	Pond Excavation	I	$	668,800.00	$	668,800.00	
4	Erosion and Sediment Control and Pollution Abatement	I	$	48,420.00	$	48,420.00	
5	Stormwater Pollution Prevention	I	$	20,200,00	$	20,200.00	
6	Demolition and Site Preparation - Included in Clearing & Earthwork	I	$	-	$	-	
7	Drainage System	I	$	848,367.00	$	848,367.00	
8	Roadway Underdrain System - Include as a Unit Price in contract	I	$	-	$	-	
9	Water Distribution	I	$ 1,073,446.00	$ 1,073,446.00	
10	Reclaim/Reuse Water System	I	$	890,060.00	$	890,060.00	
II	Wastewater Collection System	I	$ 1,073,014.00	$ 1,073,014.00	
12	Conduits for Clay Electric and telecom road crossings	I	$	24,926.00	$	24,926.00	
13	Roadway Paving with 6 inch base versus 8 inch base	I	$	960,347.00	$	960,347.00	
14	Curb and Gutter	I	$	268,094.00	$	268,094.00	
15	Concrete Sidewalks	I	$	106,000.00	$	106,000,00	
16	Soding	I	$	131,920.00	$	131,920.00	
17	Seeding and/or Mulching	I	$	180,125.00	$	180,125.00	
2	Maintenance of Construction Haul Road	I	$	53,183.00	$	53,183.00	
18	Bond Costs - Indicate Bond Fee% to be used for adds and deducts	I	$	124,000.00	$	124,000.00	
	TOTAL BID	$	8,499,638.00	
I	Sales Tax$ Amount included in TOTAL BID above - (CDD project is tax exempt)	I	$ (142,185.00) $	(142,185.00)	
	TOTAL BID	$	8,357,453.00	
7	Additional Value Engineering/Project Cost Savings Measures Proposed - See Section ill. C. 2	I	$ (300,000.00) $	(300,000.00)	
	TOTAL CONTRACT AMOUNT - See 5.01 A	$	8,057,453.00	

Unit of

Bid Item

Measurement	Unit Price	Bid

	To be included in contract as a Unit Price Item		
8	Roadway Underdrain System - Included as a Unit Cost item - See 5.01 B	I I $	567,600.00 I $	567,600.00	
	TOTAL BID - Ifunderdrain system is required 100%	$	8,625,053.00	
Bid Alternates Items	Measurement	Unit Price	Bid
3	Chan_g_e Crushcrete Base to 8 inches versus 6 inches - See 5.0I B	11 $	76,798.oo I $	76,798.00

PIPELINE CONSTRUCTORS INC

Shadow Crest at Rolling Hills Contract Schedule - Section Ill. B PIPELINE CONSTRUCTORS, INC.

ec-
•Tn	2 I 3

an-
I 2 I 3

Mobi!zation/Silt Fence
ClearinWDemo
Stri_e_ S1te/Gru!ilR_ js'._h Grade
Cot Fl Sewer itorm
Water Re-Ose UGE
Curb
Base - Pavement
Seed -Sod
Punch - Out/Close - Out

22-Jar

I 1

I 4

	DATE (MM/DD/YYYY)
2/21/2022	
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.	
IMPORTANT:  If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed.
If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s).	
PRODUCER
Cecil W. Powell & Company 219 N. Newnan Street Jacksonville, FL 32202	CONTACT Vincent B. Ellinor, CRIS, TRIP
NAME:	
	PHONE	(904) 353-3181
(A/C, No, Ext):	FAX	(904) 353-5722
(A/C, No):	
	E-MAIL	VEllinor@cwpowellins.com
ADDRESS:	
	INSURER(S) AFFORDING COVERAGE	NAIC #	
	INSURER A : Charter Oak Fire Insurance Co	25615	
INSURED

Pipeline Constructors Inc. 2117 N. Temple Ave Starke, FL 32091	INSURER B : The Travelers Indemnity Co	25658	
	INSURER C : Continental Insurance Company	35289	
	INSURER D : BusinessFirst Insurance Co	11697	
	INSURER E :		
	INSURER F :		

PIPECON-02	DHIGHTOWER
CERTIFICATE OF LIABILITY INSURANCE

COVERAGES	CERTIFICATE NUMBER:	REVISION NUMBER:
THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.	
INSR LTR	TYPE OF INSURANCE	ADDL INSD	SUBR WVD	POLICY NUMBER	POLICY EFF
(MM/DD/YYYY)	POLICY EXP
(MM/DD/YYYY)	LIMITS	
A	X	COMMERCIAL GENERAL LIABILITY	
X	
X				EACH OCCURRENCE	$	1,000,000	
			CLAIMS-MADE  X OCCUR			DCO0R802131COF21	7/1/2021	7/1/2022	DAMAGE TO RENTED
PREMISES (Ea occurrence)	$	300,000	
	X	XCU						MED EXP (Any one person)	$	10,000	
								PERSONAL & ADV INJURY	$	1,000,000	
	GEN'L AGGREGATE LIMIT APPLIES PER:						GENERAL AGGREGATE	$	2,000,000	
		POLICY  X PRO-	LOC						PRODUCTS - COMP/OP AGG	$	2,000,000	
		JECT								
								EBL AGGREGATE	$	1,000,000	
										
		OTHER:								
B	AUTOMOBILE LIABILITY	
X	
X	
8100R8031882126G	
7/1/2021	
7/1/2022	COMBINED SINGLE LIMIT
(Ea accident)	$	1,000,000	
	X	ANY AUTO						BODILY INJURY (Per person)	$	
		OWNED AUTOS ONLY
HIRED AUTOS ONLY		SCHEDULED AUTOS
NON-OWNED AUTOS ONLY						BODILY INJURY (Per accident)	$	
										PROPERTY DAMAGE
(Per accident)	$	
											$	
C		UMBRELLA LIAB
EXCESS LIAB	X	OCCUR
CLAIMS-MADE			
CUE7018379125	
2/3/2022	
7/1/2022	EACH OCCURRENCE	$	5,000,000	
	X									AGGREGATE	$	5,000,000	
		DED	X	RETENTION $	10,000							$	
D	WORKERS COMPENSATION
AND EMPLOYERS' LIABILITY	Y / N
ANY PROPRIETOR/PARTNER/EXECUTIVE	

N / A	
X	
52120579	
4/17/2021	
4/17/2022	X	PER STATUTE		OTH- ER		
							E.L. EACH ACCIDENT	$	1,000,000	
	OFFICER/MEMBER EXCLUDED?								
							E.L. DISEASE - EA EMPLOYEE	$	1,000,000	
	(Mandatory in NH)								
	If yes, describe under						E.L. DISEASE - POLICY LIMIT	$	1,000,000	
	DESCRIPTION OF OPERATIONS below								
									
DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required)
Project: Shadow Crest at Rolling Hills

Rolling Hills Community Development District is added as Additional Insured with respects to General Liability incuding ongoing and completed operations and Automobile Liability on a primary and noncontributory basis when required by written contract or agreement per the attached endorsements.

A Waiver of Subrogation applies in favor of Rolling Hills Community Development District with respects to General Liability, Automobile Liability and Workers Compensation when required by written contract or agreement per the attached endorsements.
SEE ATTACHED ACORD 101	
CERTIFICATE HOLDER	CANCELLATION

AUTHORIZED REPRESENTATIVE

SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS.

Rolling Hills Community Development District 475 West Town Place Suite 114
Saint Augustine, FL 32092

ACORD 25 (2016/03)

© 1988-2015 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD

AGENCY CUSTOMER ID: PIPECON-02

DHIGHTOWER

LOC #: 1

ADDITIONAL REMARKS SCHEDULE

Page   1  of  1 

AGENCY
Cecil W. Powell & Company	NAMED INSURED
Pipeline Constructors Inc. 2117 N. Temple Ave Starke, FL 32091
Duval	
POLICY NUMBER
SEE PAGE 1		
CARRIER
SEE PAGE 1	NAIC CODE
SEE P 1		
		EFFECTIVE DATE: SEE PAGE 1	
ADDITIONAL REMARKS
THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM,

FORM NUMBER:  ACORD 25

FORM TITLE: Certificate of Liability Insurance	

Description of Operations/Locations/Vehicles:
A 30 day notice of cancellation applies except 10 days for nonpayment of premium.

ACORD 101 (2008/01)

© 2008 ACORD CORPORATION. All rights reserved.
The ACORD name and logo are registered marks of ACORD

COMMERCIAL AUTO

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

BUSINESS AUTO EXTENSION ENDORSEMENT - FLORIDA

This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM
With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement.
GENERAL DESCRIPTION OF COVERAGE - This endorsement broadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to the Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general coverage description only. Limitations and exclusions may apply to these coverages. Read all the provisions of this endorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered.

BROAD FORM NAMED INSURED

BLANKET ADDITIONAL INSURED

EMPLOYEE HIRED AUTO

EMPLOYEES AS INSURED

SUPPLEMENTARY PAYMENTS- INCREASED LIMITS

HIRED AUTO - LIMITED WORLDWIDE COVERAGE - INDEMNITY BASIS
WAIVER OF DEDUCTIBLE - GLASS PROVISIONS
BROAD FORM NAMED INSURED
The following is added to Paragraph A.1., Who Is An Insured, of SECTION II - LIABILITY COVERAGE:
Any organization you newly acquire or form during the policy period over which you maintain 50% or more ownership interest and that is not separately insured for Business Auto Coverage. Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier.
BLANKET ADDITIONAL INSURED
The following is added to Paragraph c. in A.1., Who Is An Insured, of SECTION II - LIABILITY COVERAGE:

HIRED AUTO PHYSICAL DAMAGE - LOSS OF USE - INCREASED LIMIT

PHYSICAL DAMAGE - TRANSPORTATION EXPENSES - INCREASED LIMIT

PERSONAL EFFECTS
AIRBAGS

NOTICE AND KNOWLEDGE OF ACCIDENT OR LOSS

BLANKET WAIVER OF SUBROGATION

UNINTENTIONAL ERRORS OR OMISSIONS

This includes any person or organization who you are required under a written contract or agreement between you and that person or organization, that is signed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, to name as an additional insured for Liability Coverage, but only for damages to which this insurance applies and only to the extent of that person's or organization's liability for the conduct of another "insured".
EMPLOYEE HIRED AUTO
The following is added to Paragraph A.1., Who Is An Insured, of SECTION II - LIABILITY COVERAGE:
An "employee" of yours is an "insured" while operating an "auto" hired or rented under a contract or agreement in that "employee's"

COMMERCIAL AUTO

name, with your permission, while performing duties related to the conduct of your business.
The following replaces Paragraph b. in B.5., Other Insurance, of SECTION IV - BUSINESS AUTO CONDITIONS:
For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own:
Any covered "auto" you lease, hire, rent or borrow; and
Any covered "auto" hired or rented by your "employee" under a contract in that individual "employee's" name, with your perm1ss1on, while performing duties related to the conduct of your business.
However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto".
EMPLOYEES AS INSURED
The following is added to Paragraph A.1., Who Is An Insured, of SECTION II - LIABILITY COVERAGE:
Any "employee" of yours is an "insured" while using a covered "auto" you don't own, hire or borrow in your business or your personal affairs.
SUPPLEMENTARY PAYMENTS - INCREASED LIMITS
The following replaces Paragraph A.2.a.(2),
of SECTION II - LIABILITY COVERAGE:
(2) Up to $3,000 for cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We do not have to furnish these bonds.
The following replaces Paragraph A.2.a.(4),
of SECTION II - LIABILITY COVERAGE:
All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work.
HIRED	AUTO	LIMITED	WORLDWIDE COVERAGE - INDEMNITY BASIS
The following replaces Subparagraph (5) in Paragraph B.7., Policy Period, Coverage Territory, of SECTION IV - BUSINESS AUTO CONDITIONS:
Anywhere in the world, except any country or jurisdiction while any trade sanction, embargo, or similar regulation imposed by the

United States of America applies to and prohibits the transaction of business with or within such country or jurisdiction, for Liability Coverage for any covered "auto" that you lease, hire, rent or borrow without a driver for a period of 30 days or less and that is not an "auto" you lease, hire, rent or borrow from any of your "employees", partners (if you are a partnership), members (if you are a limited liability company) or members of their households.
With respect to any claim made or "suit" brought outside the United States of America, the territories and possessions of the United States of America, Puerto Rico and Canada:
You must arrange to defend the "insured" against, and investigate or settle any such claim or "suit" and keep us advised of all proceedings and actions.
Neither you nor any other involved "insured" will make any settlement without our consent.
We may, at our discretion, participate in defending the "insured" against, or in the settlement of, any claim or "suit".
We will reimburse the "insured" for sums that the "insured" legally must pay as damages because of "bodily injury" or "property damage" to which this insurance applies, that the "insured" pays with our consent, but only up to the limit described in Paragraph C., Limit Of Insurance, of SECTION II	LIABILITY COVERAGE;
We will reimburse the "insured" for the reasonable expenses incurred with our consent for your investigation of such claims and your defense of the "insured" against any such "suit", but only up to and included within the limit described in Paragraph C., Limit Of Insurance, of SECTION II - LIABILITY COVERAGE, and not in addition to such limit. Our duty to make such payments ends when we have used up the applicable limit of insurance in payments for damages, settlements or defense expenses.

Page 2 of 4	© 2016 The Travelers Indemnity Company. All rights reserved.	CA F2 19 08 17

COMMERCIAL AUTO

This insurance is excess over any valid and collectible other insurance available to the "insured" whether primary, excess contingent or on any other basis.
This insurance is not a substitute for required or compulsory insurance in any country outside the United States, its territories and possessions, Puerto Rico and Canada.
You agree to maintain all required or compulsory insurance in any such country up to the minimum limits required by local law. Your failure to comply with compulsory insurance requirements will not invalidate the coverage afforded by this policy, but we will only be liable to the same extent we would have been liable had you complied with the compulsory insurance requirements.
It is understood that we are not an admitted or authorized insurer outside the United States of America, its territories and possessions, Puerto Rico and Canada. We assume no responsibility for the furnishing of certificates of insurance, or for compliance in any way with the laws of other countries relating to insurance.
WAIVER OF DEDUCTIBLE - GLASS
The following is added to Paragraph D., Deductible, of SECTION Ill - PHYSICAL DAMAGE COVERAGE:
No deductible applies under Specified Causes of Loss or Comprehensive coverage for "loss" to glass used in the windshield.
HIRED AUTO PHYSICAL DAMAGE - LOSS OF USE - INCREASED LIMIT
The following replaces the last sentence of Paragraph A.4.b., Loss Of Use Expenses, of SECTION Ill	PHYSICAL DAMAGE COVERAGE:
However, the most we will pay for any expenses for loss of use is $65 per day, to a maximum of
$750 for any one "accident".
PHYSICAL	DAMAGE -	TRANSPORTATION EXPENSES- INCREASED LIMIT
The following replaces the first sentence in Paragraph A.4.a., Transportation Expenses, of SECTION Ill	PHYSICAL DAMAGE COVERAGE:

We will pay up to $50 per day to a maximum of
$1,500 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type.
PERSONAL EFFECTS
The following is added to Paragraph A.4., Coverage Extensions, of SECTION Ill - PHYSICAL DAMAGE COVERAGE:
Personal Effects
We will pay up to $400 for "loss" to wearing apparel and other personal effects which are:
Owned by an "insured"; and
In or on your covered "auto".
This coverage applies only in the event of a total theft of your covered "auto".
No deductibles apply to this Personal Effects coverage.
AIRBAGS
The following is added to Paragraph 8.3., Exclusions, of SECTION Ill - PHYSICAL DAMAGE COVERAGE:
Exclusion 3.a. does not apply to "loss" to one or more airbags in a covered "auto" you own that inflate due to a cause other than a cause of "loss" set forth in Paragraphs A.1.b. and A.1.c., but only:
If that "auto"	is a covered	"auto"	for Comprehensive Coverage under this policy;
The airbags are not covered under any warranty; and
The airbags were not intentionally inflated.
We will pay up to a maximum of $1,000 for any one "loss".
NOTICE AND KNOWLEDGE OF ACCIDENT OR LOSS
The following is added to Paragraph A.2.a., of
SECTION IV - BUSINESS AUTO CONDITIONS:
Your duty to give us or our authorized representative prompt notice of the "accident" or "loss" applies only when the "accident" or "loss" is known to:
You (if you are an individual);
A partner (if you are a partnership);
A member (if you are a limited liability company);
An executive officer, director or insurance manager (if you are a corporation or other organization); or

CA F2 19 08 17	© 2016 The Travelers Indemnity Company. All rights reserved.	Page 3 of 4

COMMERCIAL AUTO

Any "employee" authorized by you to give notice of the "accident" or "loss".
BLANKET WAIVER OF SUBROGATION
The following replaces Paragraph A.5., Transfer Of Rights Of Recovery Against Others To Us, of SECTION IV - BUSINESS AUTO CONDITIONS:
5. Transfer Of Rights Of Recovery Against Others To Us
We waive any right of recovery we may have against any person or organization to the extent required of you by a written contract signed and executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises  out  of operations  contemplated  by

such contract. The waiver applies only to the person or organization designated in such contract.
UNINTENTIONAL ERRORS OR OMISSIONS
The following is added to Paragraph 8.2., Concealment, Misrepresentation, Or Fraud, of SECTION IV - BUSINESS AUTO CONDITIONS:
The unintentional omission of, or unintentional error in, any information given by you shall not prejudice your rights under this insurance. However this provision does not affect our right to collect additional premium or exercise our right of cancellation or non-renewal.

Page 4 of 4	© 2016 The Travelers Indemnity Company. All rights reserved.	CA F2 19 08 17

COMMERCIAL AUTO

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

BLANKET ADDITIONAL INSURED - PRIMARY AND NON-CONTRIBUTORY WITH OTHER INSURANCE - CONTRACTORS

This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM

PROVISIONS
The following is added to Paragraph c. in A.1., Who Is An Insured, of SECTION II - LIABILITY COVERAGE:
This includes any person or organization who you are required under a written contract or agreement, that is signed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, to name as an additional insured for Liability Coverage, but only for damages to which this insurance applies and only to the extent of that person's or organization's liability for the conduct of another "insured".

The following is added to Paragraph 8.5., Other Insurance of SECTION IV - BUSINESS AUTO CONDITIONS:
Regardless of the provisions of paragraph a. and paragraph d. of this part 5. Other Insurance, this insurance is primary to and non-contributory with applicable other insurance under which an additional insured person or organization is a named insured when a written contract or agreement with you, that is signed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period, requires this insurance to be primary and non­ contributory.

CA T4 99 12 15	© 2015 The Travelers Indemnity Company. All rights reserved.	Page 1 of 1

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

DESIGNATED PERSON OR ORGANIZATION - NOTICE OF CANCELLATION PROVIDED BY US

This endorsement modifies insurance provided under the following: ALL COVERAGE PARTS INCLUDED IN THIS POLICY
SCHEDULE

CANCELLATION:	Number of Days Notice:

PERSON OR

PROVISIONS
If we cancel this policy for any legally permitted reason other than nonpayment of premium, and a number of days is shown for Cancellation in the Schedule above, we will mail notice of cancellation to the person or organization shown in such Schedule. We will mail such notice to the address shown in the Schedule above at least the number of days shown for Cancellation in such Schedule before the effective date of cancellation.

COMMERCIAL GENERAL LIABILITY

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

BLANKET ADDITIONAL INSURED-AUTOMATIC STATUS IF REQUIRED BY WRITTEN CONTRACT (CONTRACTORS)

This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART

The following is added to SECTION II - WHO IS AN INSURED:
Any person or organization that:
You agree in a written contract or agreement to include as an additional insured on this Coverage Part; and
Has not been added as an additional insured for the same project by attachment of an endorse­ ment under this Coverage Part which includes such person or organization in the endorsement's schedule;
is an insured, but:
Only with respect to liability for "bodily injury" or "property damage" that occurs, or for "personal injury" caused by an offense that is committed, subsequent to the signing of that contract or agreement and while that part of the contract or agreement is in effect; and
Only as described in Paragraph (1), (2) or (3) be­ low, whichever applies:
If the written contract or agreement specifical­ ly requires you to provide additional insured coverage to that person or organization by the use of:
The Additional Insured - Owners, Les­ sees or Contractors - (Form B) endorse­ ment CG 20 10 11 85; or
Either or both of the following: the Addi­ tional Insured - Owners, Lessees or Con­ tractors - Scheduled Person Or Organi­ zation endorsement CG 20 10 10 01, or the Additional Insured - Owners, Lessees or Contractors - Completed Operations endorsement CG 20 37 10 01;
the person or organization is an additional in­ sured only if the injury or damage arises out of "your work" to which the written contract or agreement applies;
If the written contract or agreement specifical­ ly requires you to provide additional insured coverage to that person or organization by the use of:

The Additional Insured - Owners, Les­ sees or Contractors - Scheduled Person or Organization endorsement CG 20 10 07 04 or CG 20 10 04 13, the Additional Insured - Owners, Lessees or Contrac­ tors - Completed Operations endorse­ ment CG 20 37 07 04 or CG 20 3 7 04 13, or both of such endorsements with either of those edition dates; or
Either or both of the following: the Addi­ tional Insured - Owners, Lessees or Con­ tractors - Scheduled Person Or Organi­ zation endorsement CG 20 10, or the Ad­ ditional Insured - Owners, Lessees or Contractors - Completed Operations en­ dorsement CG 20 37, without an edition date of such endorsement specified;
the person or organization is an additional in­ sured only if the injury or damage is caused, in whole or in part, by acts or omissions of you or your subcontractor in the performance of "your work" to which the written contract or agreement applies; or
If neither Paragraph (1) nor (2) above applies:
The person or organization is an addi­ tional insured only if, and to the extent that, the injury or damage is caused by acts or omissions of you or your subcon­ tractor in the performance of "your work" to which the written contract or agree­ ment applies; and
Such person or organization does not qualify as an additional insured with re­ spect to the independent acts or omis­ sions of such person or organization.
The insurance provided to such additional insured is subject to the following provisions:
If the Limits of Insurance of this Coverage Part shown in the Declarations exceed the minimum limits required by the written contract or agree­ ment, the insurance provided to the additional in­ sured will be limited to such minimum required limits. For the purposes of determining whether

COMMERCIAL GENERAL LIABILITY

this limitation applies, the minimum limits required by the written contract or agreement will be con­ sidered to include the minimum limits of any Um­ brella or Excess liability coverage required for the additional insured by that written contract or agreement. This provision will not increase the limits of insurance described in Section Ill - Limits Of Insurance.
The insurance provided to such additional insured does not apply to:
Any "bodily injury", "property damage" or "personal injury" arising out of the providing, or failure to provide, any professional archi­ tectural, engineering or surveying services, including:
The preparing, approving, or failing to prepare or approve, maps, shop draw­ ings, opinions, reports, surveys, field or­ ders or change orders, or the preparing, approving, or failing to prepare or ap­ prove, drawings and specifications; and
Supervisory, inspection, architectural or engineering activities.
Any "bodily injury" or "property damage" caused by "your work" and included in the "products-completed operations hazard" un­ less the written contract or agreement specifi­ cally requires you to provide such coverage for that additional insured during the policy period.
The additional insured must comply with the fol­ lowing duties:
Give us written notice as soon as practicable of an "occurrence" or an offense which may

result in a claim. To the extent possible, such notice should include:
How, when and where the "occurrence" or offense took place;
The names and addresses of any injured persons and witnesses; and
The nature and location of any injury or damage arising out of the "occurrence" or offense.
If a claim is made or "suit" is brought against the additional insured:
Immediately record the specifics of the claim or "suit" and the date received; and
Notify us as soon as practicable and see to it that we receive written notice of the claim or "suit" as soon as practicable.
Immediately send us copies of all legal pa­ pers received in connection with the claim or "suit", cooperate with us in the investigation or settlement of the claim or defense against the "suit", and otherwise comply with all policy conditions.
Tender the defense and indemnity of any claim or "suit" to any provider of other insur­ ance which would cover such additional in­ sured for a loss we cover. However, this con­ dition does not affect whether the insurance provided to such additional insured is primary to other insurance available to such additional insured which covers that person or organiza­ tion as a named insured as described in Par­ agraph 4., Other Insurance, of Section IV - Commercial General Liability Conditions.

COMMERCIAL GENERAL LIABILITY

COMMERCIAL GENERAL LIABILITY COVERAGE FORM

Various provisions in this policy restrict coverage. Read the entire policy carefully to determine rights, duties and what is and is not covered.
Throughout this policy the words "you" and "your" refer to the Named Insured shown in the Declarations, and any other person or organization qualifying as a Named Insured under this policy. The words "we", "us" and "our" refer to the company providing this insurance.
The word "insured" means any person or organization qualifying as such under Section II - Who Is An Insured.
Other words and phrases that appear in quotation marks have special meaning. Refer to Section V - Definitions.
SECTION I-COVERAGES
COVERAGE A-BODILY INJURY AND PROPERTY DAMAGE LIABILITY
Insuring Agreement
We will pay those sums that the insured becomes legally obligated to pay as damages because of "bodily injury'' or "property damage" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "bodily injury'' or "property damage" to which this insurance does not apply. We may, at our discretion, investigate any "occurrence" and settle any claim or "suit" that may result. But:
The amount we will pay for damages is limited as described in Section Ill - Limits Of Insurance; and
Our right and duty to defend end when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C.
No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments.
This insurance applies to "bodily injury" and "property damage" only if:

The "bodily injury" or "property damage" is caused by an "occurrence" that takes place in the "coverage territory";
The "bodily injury'' or "property damage" occurs during the policy period; and
Prior to the policy period, no insured listed under Paragraph 1. of Section II - Who Is An Insured and no "employee" authorized by you to give or receive notice of an "occurrence" or claim knew that the "bodily injury" or "property damage" had occurred, in whole or in part. If such a listed insured or authorized "employee" knew, prior to the policy period, that the "bodily injury'' or "property damage" occurred, then any continuation, change or resumption of such "bodily injury" or "property damage" during or after the policy period will be deemed to have been known prior to the policy period.
"Bodily injury" or "property damage" which occurs during the policy period and was not, prior to the policy period, known to have occurred by any insured listed under Paragraph
of Section II - Who Is An Insured or any "employee" authorized by you to give or receive notice of an "occurrence" or claim, includes any continuation, change or resumption of that "bodily injury" or "property damage" after the end of the policy period.
"Bodily injury" or "property damage" will be deemed to have been known to have occurred at the earliest time when any insured listed under Paragraph 1. of Section II - Who Is An Insured or any "employee" authorized by you to give or receive notice of an "occurrence" or claim:
Reports all, or any part, of the "bodily injury" or "property damage" to us or any other insurer;
Receives a written or verbal demand or claim for damages because of the "bodily injury" or "property damage"; or
Becomes aware by any other means that "bodily injury" or "property damage" has occurred or has begun to occur.

COMMERCIAL GENERAL LIABILITY

Damages because of "bodily injury'' include damages claimed by any person or organization for care, loss of services or death resulting at any time from the "bodily injury''.
Exclusions
This insurance does not apply to:
Expected Or Intended Injury
"Bodily injury'' or "property damage" expected or intended from the standpoint of the insured. This exclusion does not apply to "bodily injury" or "property damage" resulting from the use of reasonable force to protect persons or property.
Contractual Liability
"Bodily injury" or "property damage" for which the insured is obligated to pay damages by reason of the assumption of liability in a contract or agreement. This exclusion does not apply to liability for damages:
That the insured would have in the absence of the contract or agreement; or
Assumed in a contract or agreement that is an "insured contract", provided that the "bodily injury'' or "property damage" occurs subsequent to the execution of the contract or agreement. Solely for the purposes of liability assumed in an "insured contract", reasonable attorneys' fees and necessary litigation expenses incurred by or for a party other than an insured will be deemed to be damages because of "bodily injury'' or "property damage", provided that:
Liability to such party for, or for the cost of, that party's defense has also been assumed in the same "insured contract"; and
Such attorneys' fees and litigation expenses are for defense of that party against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged.
Liquor Liability
"Bodily injury" or "property damage" for which any insured may be held liable by reason of:
Causing or contributing to the intoxication of any person;
The furnishing of alcoholic beverages to a person under the legal drinking age or under the influence of alcohol; or

Any statute, ordinance or regulation relating to the sale, gift, distribution or use of alcoholic beverages.
This exclusion applies only if you are in the business of manufacturing, distributing, selling, serving or furnishing alcoholic beverages. For the purposes of this exclusion, permitting a person to bring alcoholic beverages on your premises, for consumption on your premises, whether or not a fee is charged or a license is required for such activity, is not by itself considered the business of selling, serving or furnishing alcoholic beverages.
Workers' Compensation And Similar Laws
Any obligation of the insured under a workers' compensation, disability benefits or unemployment compensation law or any similar law.
Employer's Liability
"Bodily injury" to:
An "employee" of the insured arising out of and in the course of:
Employment by the insured; or
Performing duties related to the conduct of the insured's business; or
The spouse, child, parent, brother or sister of that "employee" as a consequence of Paragraph (1) above.
This exclusion applies whether the insured may be liable as an employer or in any other capacity and to any obligation to share damages with or repay someone else who must pay damages because of the injury.
This exclusion does not apply to liability assumed by the insured under an "insured contract".
Pollution
"Bodily injury" or "property damage" arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants":
At or from any premises, site or location which is or was at any time owned or occupied by, or rented or loaned to, any insured. However, this subparagraph does not apply to:
"Bodily injury'' if sustained within a building and caused by smoke, fumes, vapor or soot produced by or originating from equipment that

COMMERCIAL GENERAL LIABILITY

is used to heat, cool or dehumidify the building, or produced by or originating from equipment that is used to heat water for personal use by the building's occupants or their guests;
"Bodily injury'' or "property damage" for which you may be held liable, if you are a contractor and the owner or lessee of such premises, site or location has been added to your policy as an additional insured with respect to your ongoing operations performed for that additional insured at that premises, site or location and such premises, site or location is not and never was owned or occupied by, or rented or loaned to, any insured, other than that additional insured; or
"Bodily injury'' or "property damage" ans,ng out of heat, smoke or fumes from a "hostile fire";
At or from any premises, site or location which is or was at any time used by or for any insured or others for the handling, storage, disposal, processing or treatment of waste;
If such "pollutants" are or were at any time transported, handled, stored, treated, disposed of, or processed as waste by or for:
Any insured; or
Any person or organization for whom you may be legally responsible;
At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are performing operations if the "pollutants" are brought on or to the premises, site or location in connection with such operations by such insured, contractor or subcontractor. However, this subparagraph does not apply to:
"Bodily injury'' or "property damage" arising out of the escape of fuels, lubricants or other operating fluids which are needed

to perform the normal electrical, hydraulic or mechanical functions necessary for the operation of "mobile equipment" or its parts, if such fuels, lubricants or other operating fluids escape from a vehicle part designed to hold, store or receive them. This exception does not apply if the "bodily injury" or "property damage" arises out of the intentional discharge, dispersal or release of the fuels, lubricants or other operating fluids, or if such fuels, lubricants or other operating fluids are brought on or to the premises, site or location with the intent that they be discharged, dispersed or released as part of the operations being performed by such insured, contractor or subcontractor;
"Bodily injury'' or "property damage" sustained within a building and caused by the release of gases, fumes or vapors from materials brought into that building in connection with operations being performed by you or on your behalf by a contractor or subcontractor; or
"Bodily injury'' or "property damage" arising out of heat, smoke or fumes from a "hostile fire"; or
At or from any premises, site or location on which any insured or any contractors or subcontractors working directly or indirectly on any insured's behalf are or were at any time performing operations to test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants".
Any loss, cost or expense arising out of any:
Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or

COMMERCIAL GENERAL LIABILITY

Claim or suit by or on behalf of any governmental authority or any other person or organization because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, "pollutants".
Aircraft, Auto Or Watercraft
"Bodily injury'' or "property damage" arising out of the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft owned or operated by or rented or loaned to any insured. Use includes operation and "loading or unloading".
This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that insured, if the "occurrence" which caused the "bodily injury'' or "property damage" involved the ownership, maintenance, use or entrustment to others of any aircraft, "auto" or watercraft that is owned or operated by or rented or loaned to any insured.
This exclusion does not apply to:
A watercraft while ashore on premises you own or rent;
A watercraft you do not own that is:
50 feet long or less; and
Not being used to carry any person or property for a charge;
Parking an "auto" on, or on the ways next to, premises you own or rent, provided the "auto" is not owned by or rented or loaned to you or the insured;
Liability assumed under any "insured contract" for the ownership, maintenance or use of aircraft or watercraft;
"Bodily injury'' or "property damage" arising out of:
The operation of machinery or equipment that is attached to, or part of, a land vehicle that would qualify as "mobile equipment" under the definition of "mobile equipment" if such land vehicle were not subject to a compulsory or financial responsibility law, or other motor vehicle insurance law, where it is licensed or principally garaged; or

The operation of any of the machinery or equipment listed in Paragraph f.(2) or f.(3) of the definition of "mobile equipment"; or
An aircraft that is:
Chartered with a pilot to any insured;
Not owned by any insured; and
Not being used to carry any person or property for a charge.
Mobile Equipment
"Bodily injury" or "property damage" arising out of:
The transportation of "mobile equipment" by an "auto" owned or operated by or rented or loaned to any insured; or
The use of "mobile equipment" in, or while in practice for, or while being prepared for, any prearranged racing, speed, demolition, or stunting activity.
War
"Bodily injury" or "property damage" arising out of:
War, including undeclared or civil war;
Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or
Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these.
Damage To Property
"Property damage" to:
Property you own, rent, or occupy, including any costs or expenses incurred by you, or any other person, organization or entity, for repair, replacement, enhancement, restoration or maintenance of such property for any reason, including prevention of injury to a person or damage to another's property;
Premises you sell, give away or abandon, if the "property damage" arises out of any part of those premises;
Property loaned to you;
Personal property in the care, custody or control of the insured;

COMMERCIAL GENERAL LIABILITY

That particular part of real property on which you or any contractors or subcontractors working directly or indirectly on your behalf are performing operations, if the "property damage" arises out of those operations; or
That particular part of any property that must be restored, repaired or replaced because "your work" was incorrectly performed on it.
Paragraphs (1), (3) and (4) of this exclusion do not apply to "premises damage". A separate limit of insurance applies to "premises damage" as described in Paragraph 6. of Section Ill - Limits Of Insurance.
Paragraph (2) of this exclusion does not apply if the premises are "your work" and were never occupied, rented or held for rental by you.
Paragraphs (3), (4), (5) and (6) of this exclusion do not apply to liability assumed under a sidetrack agreement.
Paragraph (6) of this exclusion does not apply to "property damage" included in the "products­ completed operations hazard".
Damage To Your Product
"Property damage" to "your product" arising out of it or any part of it.
I.  Damage To Your Work
"Property damage" to "your work" arising out of it or any part of it and included in the "products­ completed operations hazard".
This exclusion does not apply if the damaged work or the work out of which the damage arises was performed on your behalf by a subcontractor.
Damage To Impaired Property Or Property Not Physically Injured
"Property damage" to "impaired property" or property that has not been physically injured, arising out of:
A defect, deficiency, inadequacy or dangerous condition in "your product" or "your work"; or
A delay or failure by you or anyone acting on your behalf to perform a contract or agreement in accordance with its terms.
This exclusion does not apply to the loss of use of other property arising out of sudden and

accidental physical injury to "your product" or "your work" after it has been put to its intended use.
Recall Of Products, Work Or Impaired Property
Damages claimed for any loss, cost or expense incurred by you or others for the loss of use, withdrawal, recall, inspection, repair, replacement, adjustment, removal or disposal of:
"Your product";
"Your work"; or
"Impaired property";
if such product, work, or property is withdrawn or recalled from the market or from use by any person or organization because of a known or suspected defect, deficiency, inadequacy or dangerous condition in it.
Personal And Advertising Injury
"Bodily injury" arising out of "personal and advertising injury''.
Electronic Data
Damages arising out of the loss of, loss of use of, damage to, corruption of, inability to access, or inability to manipulate "electronic data".
However, this exclusion does not apply to liability for damages because of "bodily injury".
Unsolicited Communication
"Bodily injury" or "property damage" arising out of any actual or alleged violation of any law that restricts or prohibits the sending, transmitting or distributing of "unsolicited communication".
Access Or Disclosure Of Confidential Or Personal Information
"Bodily injury" or "property damage" arising out of any access to or disclosure of any person's or organization's confidential or personal information.
Asbestos
"Bodily injury" or "property damage" arising out of the actual or alleged presence or actual, alleged or threatened dispersal of asbestos, asbestos fibers or products containing asbestos, provided that the "bodily injury" or "property damage" is caused or contributed to by the hazardous properties of asbestos.

COMMERCIAL GENERAL LIABILITY

"Bodily injury'' or "property damage" arising out of the actual or alleged presence or actual, alleged or threatened dispersal of any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapors, soot, fumes, acids, alkalis, chemicals and waste, and that are part of any claim or "suit" which also alleges any "bodily injury" or "property damage" described in Paragraph (1) above.
Any loss, cost or expense arising out of any:
Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, asbestos, asbestos fibers or products containing asbestos; or
Claim or suit by or on behalf of any governmental authority or any other person or organization because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, asbestos, asbestos fibers or products containing asbestos.
Employment-Related Practices
"Bodily injury" to:
A person arising out of any:
Refusal to employ that person;
Termination of that person's employment; or
Employment-related practice, policy, act or omission, such as coercion, demotion, evaluation, reassignment, discipline, failure to promote or advance, harassment, humiliation, discrimination, libel, slander, violation of the person's right of privacy, malicious prosecution or false arrest, detention or imprisonment applied to or directed at that person, regardless of whether such practice, policy, act or omission occurs, is applied or is committed before, during or after the time of that person's employment; or
The spouse, child, parent, brother or sister of that person as a consequence of "bodily injury" to that person at whom any of the

employment-related practices described in Paragraph (a), (b), or (c) above is directed. This exclusion applies whether the insured may
be liable as an employer or in any other capacity
and to any obligation to share damages with or repay someone else who must pay damages because of the "bodily injury".
Exclusions c. through n. do not apply to "premises damage". A separate limit of insurance applies to "premises damage" as described in Paragraph 6. of Section Ill - Limits Of Insurance.
COVERAGE B - PERSONAL AND ADVERTISING INJURY LIABILITY
Insuring Agreement
We will pay those sums that the insured becomes legally obligated to pay as damages because of "personal and advertising injury" to which this insurance applies. We will have the right and duty to defend the insured against any "suit" seeking those damages. However, we will have no duty to defend the insured against any "suit" seeking damages for "personal and advertising injury" to which this insurance does not apply. We may, at our discretion, investigate any offense and settle any claim or "suit" that may result. But:
The amount we will pay for damages is limited as described in Section Ill - Limits Of Insurance; and
Our right and duty to defend end when we have used up the applicable limit of insurance in the payment of judgments or settlements under Coverages A or B or medical expenses under Coverage C.
No other obligation or liability to pay sums or perform acts or services is covered unless explicitly provided for under Supplementary Payments.
This insurance applies to "personal and advertising injury" caused by an offense arising out of your business but only if the offense was committed in the "coverage territory'' during the policy period.
Exclusions
This insurance does not apply to:
Knowing Violation Of Rights Of Another
"Personal and advertising injury" caused by or at the direction of the insured with the knowledge that the act would violate the rights of another and would inflict "personal and advertising injury''.

COMMERCIAL GENERAL LIABILITY

This exclusion does not apply to "personal injury" caused by malicious prosecution.
Material Published With Knowledge Of Falsity
"Personal and advertising injury'' arising out of oral or written publication, including publication by electronic means, of material, if done by or at the direction of the insured with knowledge of its falsity.
Material Published Or Used Prior To Policy Period
"Personal and advertising injury'' arising out of oral or written publication, including publication by electronic means, of material whose first publication took place before the beginning of the policy period; or
"Advertising injury'' arising out of infringement of copyright, "title" or "slogan" in your "advertisement" whose first infringement in your "advertisement" was committed before the beginning of the policy period.
Criminal Acts
"Personal and advertising injury'' arising out of a criminal act committed by or at the direction of the insured.
Contractual Liability
"Personal and advertising injury" for which the insured has assumed liability in a contract or agreement. This exclusion does not apply to liability for damages:
That the insured would have in the absence of the contract or agreement; or
Because of "personal injury" assumed by you in a contract or agreement that is an "insured contract", provided that the "personal injury" is caused by an offense
committed subsequent to the execution of the contract or agreement. Solely for the purposes of liability assumed by you in an "insured contract", reasonable attorneys' fees and necessary litigation expenses incurred by or for a party other than an insured will be deemed to be damages because of "personal injury'', provided that:
Liability to such party for, or for the cost of, that party's defense has also been assumed by you in the same "insured contract"; and
Such attorneys' fees and litigation expenses are for defense of that party

against a civil or alternative dispute resolution proceeding in which damages to which this insurance applies are alleged.
Breach Of Contract
"Advertising injury'' arising out of a breach of contract.
Quality Or Performance Of Goods - Failure To Conform To Statements
"Advertising injury" arising out of the failure of goods, products or services to conform with any statement of quality or performance made in your "advertisement".
Wrong Description Of Prices
"Advertising injury" arising out of the wrong description of the price of goods, products or services stated in your "advertisement".
Intellectual Property
"Personal and advertising injury" arising out of any actual or alleged infringement or violation of any of the following rights or laws, or any other "personal and advertising injury" alleged in any claim or "suit" that also alleges any such infringement or violation:
Copyright;
Patent;
Trade dress;
Trade name;
Trademark;
Trade secret; or
Other intellectual property rights or laws. This exclusion does not apply to:
"Advertising injury'' arising out of any actual or alleged infringement or violation of another's copyright, "title" or "slogan" in your "advertisement"; or
Any other "personal and advertising injury" alleged in any claim or "suit" that also alleges any such infringement or violation of another's copyright, "title" or "slogan" in your "advertisement".
Insureds In Media And Internet Type Businesses
"Personal and advertising injury" caused by an offense committed by an insured whose business is:
Advertising, "broadcasting" or publishing;

COMMERCIAL GENERAL LIABILITY

Designing	or	determining	content	of websites for others; or
An Internet  search, access, content or

War

neutralizing, or in any way responding to, or assessing the effects of, "pollutants".

service provider.
However, this exclusion does not apply to Paragraphs a.(1), (2) and (3) of the definition of "personal injury''.
For the purposes of this exclusion:
Creating and producing correspondence written in the conduct of your business, bulletins, financial or annual reports, or newsletters about your goods, products or services will not be considered the business of publishing; and
The placing of frames, borders or links, or advertising, for you or others anywhere on the Internet will not, by itself, be considered the business of advertising, "broadcasting" or publishing.
Electronic Chatrooms Or Bulletin Boards
"Personal and advertising injury'' arising out of an electronic chatroom or bulletin board the insured hosts or owns, or over which the insured exercises control.
Unauthorized Use Of Another's Name Or Product
"Personal and advertising injury'' arising out of the unauthorized use of another's name or product in your e-mail address, domain name or metatag, or any other similar tactics to mislead another's potential customers.
m. Pollution
"Personal and advertising injury'' arising out of the actual, alleged or threatened discharge, dispersal, seepage, migration, release or escape of "pollutants" at any time.
n.  Pollution-Related
Any loss, cost or expense arising out of any:
Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or assess the effects of, "pollutants"; or
Claim or suit by or on behalf of any governmental authority or any other person or organization because of testing for, monitoring, cleaning up, removing, containing,   treating,   detoxifying   or

"Personal and advertising injury" arising out of:
War, including undeclared or civil war;
Warlike action by a military force, including action in hindering or defending against an actual or expected attack, by any government, sovereign or other authority using military personnel or other agents; or
Insurrection, rebellion, revolution, usurped power, or action taken by governmental authority in hindering or defending against any of these.
Unsolicited Communication
"Personal and advertising injury" arising out of any actual or alleged violation of any law that restricts or prohibits the sending, transmitting or distributing of "unsolicited communication".
Access Or Disclosure Of Confidential Or Personal Information
"Personal and advertising injury" arising out of any access to or disclosure of any person's or organization's confidential or personal information.
Asbestos
"Personal and advertising injury" arising out of the actual or alleged presence or actual, alleged or threatened dispersal of asbestos, asbestos fibers or products containing asbestos, provided that the "personal and advertising injury" is caused or contributed to by the hazardous properties of asbestos.
"Personal and advertising injury" arising out of the actual or alleged presence or actual, alleged or threatened dispersal of any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapors, soot, fumes, acids, alkalis, chemicals and waste, and that are part of any claim or "suit" which also alleges any "personal and advertising injury" described in Paragraph
above.
Any loss, cost or expense arising out of any:
Request, demand, order or statutory or regulatory requirement that any insured or others test for, monitor, clean up, remove, contain, treat, detoxify or neutralize, or in any way respond to, or

COMMERCIAL GENERAL LIABILITY

assess the effects of, asbestos, asbestos fibers or products containing asbestos; or
Claim or suit by or on behalf of any governmental authority or any other person or organization because of testing for, monitoring, cleaning up, removing, containing, treating, detoxifying or neutralizing, or in any way responding to, or assessing the effects of, asbestos, asbestos fibers or products containing asbestos.
Employment-Related Practices
"Personal injury" to:
A person arising out of any:
Refusal to employ that person;
Termination of that person's employment; or
Employment-related practice, policy, act or omission, such as coercion, demotion, evaluation, reassignment, discipline, failure to promote or advance, harassment, humiliation, discrimination, libel, slander, violation of the person's right of privacy, malicious prosecution or false arrest, detention or imprisonment applied to or directed at that person, regardless of whether such practice, policy, act or omission occurs, is applied or is committed before, during or after the time of that person's employment; or
The spouse, child, parent, brother or sister of that person as a consequence of "personal injury'' to that person at whom any of the employment-related practices described in Paragraph (a), (b), or (c) above is directed.
This exclusion applies whether the insured may be liable as an employer or in any other capacity and to any obligation to share damages with or repay someone else who must pay damages because of the "personal injury''.
COVERAGE C- MEDICAL PAYMENTS
Insuring Agreement
We will pay medical expenses as described below for "bodily injury" caused by an accident:
On premises you own or rent;
On ways next to premises you own or rent; or

Because of your operations; provided that:
The accident takes place in the "coverage territory" and during the policy period;
The expenses are incurred and reported to us within one year of the date of the accident; and
The injured person submits to examination, at our expense, by physicians of our choice as often as we reasonably require.
We will make these payments regardless of fault. These payments will not exceed the applicable limit of insurance. We will pay reasonable expenses for:
First aid administered at the time of an accident;
Necessary medical, surgical, X-ray and dental services, including prosthetic devices; and
Necessary ambulance, hospital, professional nursing and funeral services.
Exclusions
We will not pay expenses for "bodily injury":
Any Insured
To any insured, except "volunteer workers".
Hired Person
To a person hired to do work for or on behalf of any insured or a tenant of any insured.
Injury On Normally Occupied Premises
To a person injured on that part of premises you own or rent that the person normally occupies.
Workers' Compensation And Similar Laws
To a person, whether or not an "employee" of any insured, if benefits for the "bodily injury" are payable or must be provided under a workers' compensation or disability benefits law or a similar law.
Athletics Activities
To a person injured while practicing, instructing or participating in any physical exercises or games, sports, or athletic contests.
Products-Completed Operations Hazard
Included	within	the	"products-completed operations hazard".
Coverage A Exclusions
Excluded under Coverage A.

COMMERCIAL GENERAL LIABILITY

SUPPLEMENTARY PAYMENTS
We will pay, with respect to any claim we investigate or settle, or any "suit" against an insured we defend:
All expenses we incur.
Up to $2,500 for the cost of bail bonds required because of accidents or traffic law violations arising out of the use of any vehicle to which the Bodily Injury Liability Coverage applies. We do not have to furnish these bonds.
The cost of bonds to release attachments, but only for bond amounts within the applicable limit of insurance. We do not have to furnish these bonds.
All reasonable expenses incurred by the insured at our request to assist us in the investigation or defense of the claim or "suit", including actual loss of earnings up to $500 a day because of time off from work.
All court costs taxed against the insured in the "suit". However, these payments do not include attorneys' fees or attorneys' expenses taxed against the insured.
Prejudgment interest awarded against the insured on that part of the judgment we pay. If we make an offer to pay the applicable limit of insurance, we will not pay any prejudgment interest based on that period of time after the offer.
All interest on the full amount of any judgment that accrues after entry of the judgment and before we have paid, offered to pay, or deposited in court the part of the judgment that is within the applicable limit of insurance.
These payments will not reduce the limits of insurance.
If we defend an insured against a "suit" and an indemnitee of the insured is also named as a party to the "suit", we will defend that indemnitee if all of the following conditions are met:
The "suit" against the indemnitee seeks damages for which the insured has assumed the liability of the indemnitee in a contract or agreement that is an "insured contract";
This insurance applies to such liability assumed by the insured;
The obligation to defend, or the cost of the defense of, that indemnitee, has also been

assumed by the insured in the same "insured contract";
The allegations in the "suit" and the information we know about the "occurrence" or offense are such that no conflict appears to exist between the interests of the insured and the interests of the indemnitee;
The indemnitee and the insured ask us to conduct and control the defense of that indemnitee against such "suit" and agree that we can assign the same counsel to defend the insured and the indemnitee; and
The indemnitee:
Agrees in writing to:
Cooperate with us in the investigation, settlement or defense of the "suit";
Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the "suit";
Notify any other insurer whose coverage is available to the indemnitee; and
Cooperate with us with respect to coordinating other applicable insurance available to the indemnitee; and
Provides us with written authorization to:
Obtain records and other information related to the "suit"; and
Conduct and control the defense of the indemnitee in such "suit".
So long as the above conditions are met, attorneys' fees incurred by us in the defense of that indemnitee, necessary litigation expenses incurred by us and necessary litigation expenses incurred by the indemnitee at our request will be paid as Supplementary Payments. Notwithstanding the provisions of Paragraph 2.b.(2) of Section I - Coverages - Coverage A - Bodily Injury And Property Damage Liability or Paragraph 2.e. of Section I - Coverages - Coverage B - Personal And Advertising Injury Liability, such payments will not be deemed to be damages for "bodily injury", "property damage" or "personal injury", and will not reduce the limits of insurance.
Our obligation to defend an insured's indemnitee and to pay for attorneys' fees and necessary litigation expenses as Supplementary Payments ends when:

COMMERCIAL GENERAL LIABILITY

We have used up the applicable limit of insurance in the payment of judgments, settlements or medical expenses; or

workers" related	to business;

while
the

performing		duties conduct	of		your

The conditions set forth above, or the terms of the agreement described in Paragraph f. above, are no longer met.
SECTION II - WHO IS AN INSURED

(b)

To the spouse, child, parent, brother or sister of that co-"employee" or "volunteer worker" as a consequence of Paragraph (1)(a) above;

If you are designated in the Declarations as:
An individual, you and your spouse are insureds, but only with respect to the conduct of a business of which you are the sole owner.
A partnership or joint venture, you are an insured. Your members, your partners, and their spouses are also insureds, but only with respect to the conduct of your business.
A limited liability company, you are an insured. Your members are also insureds, but only with respect to the conduct of your business. Your managers are insureds, but only with respect to their duties as your managers.
An organization other than a partnership, joint venture or limited liability company, you are an insured. Your "executive officers" and directors are insureds, but only with respect to their duties as your officers or directors. Your stockholders are also insureds, but only with respect to their liability as stockholders.
A trust, you are an insured. Your trustees are also insureds, but only with respect to their duties as trustees.
Each of the following is also an insured:
Your "volunteer workers" only while performing duties related to the conduct of your business, or your "employees", other than either your "executive officers" (if you are an organization other than a partnership, joint venture or limited liability company) or your managers (if you are a limited liability company), but only for acts within the scope of their employment by you or while performing duties related to the conduct of your business. However, none of these "employees" or "volunteer workers" are insureds for:
"Bodily injury" or "personal injury":
To you, to your partners or members (if you are a partnership or joint venture), to your members (if you are a limited liability company), to a co-"employee" while in the course of his or her employment or performing duties related to the conduct of your business, or to your other "volunteer

For which there is any obligation to share damages with or repay someone else who must pay damages because of the injury described in Paragraph (1 )(a) or (b) above; or
Arising out of his or her providing or failing to provide professional health care services.
Unless you are in the business or occupation of providing professional health care services, Paragraphs (1)(a), (b), (c) and (d) above do not apply to "bodily injury" arising out of providing or failing to provide first aid or "Good Samaritan services" by any of your "employees" or "volunteer workers", other than an employed or volunteer doctor. Any such "employees" or "volunteer workers" providing or failing to provide first aid or "Good Samaritan services" during their work hours for you will be deemed to be acting within the scope of their employment by you or performing duties related to the conduct of your business.
"Property damage" to property:
Owned, occupied or used by;
Rented to, in the care, custody or control of, or over which physical control is being exercised for any purpose by;
you, any of your "employees", "volunteer workers", any partner or member (if you are a partnership or joint venture), or any member (if you are a limited liability company).
Any person (other than your "employee" or "volunteer worker"), or any organization, while acting as your real estate manager.
Any person or organization having proper temporary custody of your property if you die, but only:
With respect to liability arising out of the maintenance or use of that property; and
Until your legal representative has been appointed.

COMMERCIAL GENERAL LIABILITY

Your legal representative if you die, but only with respect to duties as such. That representative will have all your rights and duties under this Coverage Part.
Any person or organization that, with your express or implied consent, either uses or is responsible for the use of a watercraft that you do not own that is:
50 feet long or less; and
Not being used to carry any person or property for a charge.
Any organization you newly acquire or form, other than a partnership, joint venture or limited liability company, and of which you are the sole owner or in which you maintain an ownership interest of more than 50%, will qualify as a Named Insured if there is no other similar insurance available to that organization. However:
Coverage under this provision is afforded only until the 180th day after you acquire or form the organization or the end of the policy period, whichever is earlier;
Coverage A does not apply to "bodily injury" or "property damage" that occurred before you acquired or formed the organization; and
Coverage B does not apply to "personal and advertising injury'' arising out of an offense committed before you acquired or formed the organization.
For the purposes of Paragraph 1. of Section II - Who Is An Insured, each such organization will be deemed to be designated in the Declarations as:
An organization, other than a partnership, joint venture or limited liability company; or
A trust;
as indicated in its name or the documents that govern its structure.
Any person or organization that is a premises owner, manager or lessor and that you have agreed in a written contract or agreement to include as an additional insured on this Coverage Part is an insured, but only with respect to liability for "bodily injury'', "property damage" or "personal and advertising injury" that:
Is "bodily injury" or "property damage" that occurs, or is "personal and advertising injury" caused by an offense that is committed, subsequent to the signing of that contract or agreement; and

Arises out of the ownership, maintenance or use of that part of any premises leased to you.
The insurance provided to such premises owner, manager or lessor is subject to the following provisions:
The limits of insurance provided to such premises owner, manager or lessor will be the minimum limits that you agreed to provide in the written contract or agreement, or the limits shown in the Declarations, whichever are less.
The insurance provided to such premises owner, manager or lessor does not apply to:
Any "bodily injury" or "property damage" that occurs, or "personal and advertising injury" caused by an offense that is committed, after you cease to be a tenant in that premises; or
Structural alterations, new construction or demolition operations performed by or on behalf of such premises owner, manager or lessor.
Any person or organization that is an equipment lessor and that you have agreed in a written contract or agreement to include as an additional insured on this Coverage Part is an insured, but only with respect to liability for "bodily injury'', "property damage", or "personal and advertising injury'' that:
Is "bodily injury'' or "property damage" that occurs, or is "personal and advertising injury" caused by an offense that is committed, subsequent to the signing of that contract or agreement; and
Is caused, in whole or in part, by your acts or omissions in the maintenance, operation or use of equipment leased to you by such equipment lessor.
The insurance provided to such equipment lessor is subject to the following provisions:
The limits of insurance provided to such equipment lessor will be the minimum limits that you agreed to provide in the written contract or agreement, or the limits shown in the Declarations, whichever are less.
The insurance provided to such equipment lessor does not apply to any "bodily injury'' or "property damage" that occurs, or "personal and advertising injury" caused by an offense that is committed, after the equipment lease expires.
No person or organization is an insured with respect to the conduct of any current or past partnership, joint

COMMERCIAL GENERAL LIABILITY

venture or limited liability company that is not shown as a Named Insured in the Declarations. This paragraph does not apply to any such partnership, joint venture or limited liability company that otherwise qualifies as an insured under Section II - Who Is An Insured.
SECTION Ill-LIMITS OF INSURANCE
The Limits of Insurance shown in the Declarations and the rules below fix the most we will pay regardless of the number of:
Insureds;
Claims made or "suits" brought; or
Persons or organizations making claims or bringing "suits".
The General Aggregate Limit is the most we will pay for the sum of:
Medical expenses under Coverage C;
Damages under Coverage A, except damages because of "bodily injury'' or "property damage" included in the "products-completed operations hazard"; and
Damages under Coverage B.
The Products-Completed Operations Aggregate Limit is the most we will pay under Coverage A for damages because of "bodily injury'' and "property damage" included in the "products-completed operations hazard".
Subject to Paragraph 2. above, the Personal And Advertising Injury Limit is the most we will pay under Coverage B for the sum of all damages because of all "personal injury'' and "advertising injury'' sustained by any one person or organization.
Subject to Paragraph 2. or 3. above, whichever applies, the Each Occurrence Limit is the most we will pay for the sum of:
Damages under Coverage A; and
Medical expenses under Coverage C;
because of all "bodily injury'' and "property damage" arising out of any one "occurrence".
For the purposes of determining the applicable Each Occurrence Limit, all related acts or omissions committed in providing or failing to provide first aid or "Good Samaritan services" to any one person will be deemed to be one "occurrence".
Subject to Paragraph 5. above, the Damage To Premises Rented To You Limit is the most we will pay under Coverage A for damages because of "premises damage" to any one premises. The Damage To Premises Rented To You Limit will be:

The amount shown for the Damage To Premises Rented To You Limit in the Declarations of this Coverage Part; or
$300,000 if no amount is shown for the Damage To Premises Rented To You Limit in the Declarations of this Coverage Part.
Subject to Paragraph 5. above, the Medical Expense Limit is the most we will pay under Coverage C for all medical expenses because of "bodily injury" sustained by any one person.
The Limits of Insurance of this Coverage Part apply separately to each consecutive annual period and to any remaining period of less than 12 months, starting with the beginning of the policy period shown in the Declarations, unless the policy period is extended after issuance for an additional period of less than 12 months. In that case, the additional period will be deemed part of the last preceding period for purposes of determining the Limits of Insurance.
SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS
Bankruptcy
Bankruptcy or insolvency of the insured or of the insured's estate will not relieve us of our obligations under this Coverage Part.
Duties In The Event Of Occurrence, Offense,
Claim Or Suit
You must see to it that we are notified as soon as practicable of an "occurrence" or an offense which may result in a claim. To the extent possible, notice should include:
How, when and where the "occurrence" or offense took place;
The names and addresses of any injured persons and witnesses; and
The nature and location of any injury or damage arising out of the "occurrence" or offense.
If a claim is made or "suit" is brought against any insured, you must:
Immediately record the specifics of the claim or "suit" and the date received; and
Notify us as soon as practicable.
You must see to it that we receive written notice of the claim or "suit" as soon as practicable.
You and any other involved insured must:
Immediately send us copies of any demands, notices, summonses or legal papers received in connection with the claim or "suit";

COMMERCIAL GENERAL LIABILITY

Authorize us to obtain records and other information;
Cooperate with us in the investigation or settlement of the claim or defense against the "suit"; and
Assist us, upon our request, in the enforcement of any right against any person or organization which may be liable to the insured because of injury or damage to which this insurance may also apply.
No insured will, except at that insured's own cost, voluntarily make a payment, assume any obligation, or incur any expense, other than for first aid, without our consent.
The following provisions apply to Paragraph a. above, but only for purposes of the insurance provided under this Coverage Part to you or any insured listed in Paragraph 1. or 2. of Section II
- Who Is An Insured:
Notice to us of such "occurrence" or offense must be given as soon as practicable only after the "occurrence" or offense is known to you (if you are an individual), any of your partners or members who is an individual (if you are a partnership or joint venture), any of your managers who is an individual (if you are a limited liability company), any of your "executive officers" or directors (if you are an organization other than a partnership, joint venture, or limited liability company), any of your trustees who is an individual (if you are a trust) or any "employee" authorized by you to give notice of an "occurrence" or offense.
If you are a partnership, joint venture, limited liability company or trust, and none of your partners, joint venture members, managers or trustees are individuals, notice to us of such "occurrence" or offense must be given as soon as practicable only after the "occurrence" or offense is known by:
Any individual who is:
A partner or member of any partnership or joint venture;
A manager of any limited liability company;

An executive officer or director of any other organization; or
A trustee of any trust;
that is your partner, joint venture member, manager or trustee; or
Any employee authorized by such partnership, joint venture, limited liability company, trust or other organization to give notice of an "occurrence" or offense.
Notice to us of such "occurrence" or offense will be deemed to be given as soon as practicable if it is given in good faith as soon as practicable to your workers' compensation insurer. This applies only if you subsequently give notice to us of the "occurrence" or offense as soon as practicable after any of the persons described in Paragraph e.(1) or (2) above discovers that the "occurrence" or offense may result in sums to which the insurance provided under this Coverage Part may apply.
However, if this policy includes an endorsement that provides limited coverage for "bodily injury" or "property damage" or pollution costs arising out of a discharge, release or escape of "pollutants" which contains a requirement that the discharge, release or escape of "pollutants" must be reported to us within a specific number
of days after its abrupt commencement, this Paragraph e. does not affect that requirement.
Legal Action Against Us
No person or organization has a right under this Coverage Part:
To join us as a party or otherwise bring us into a "suit" asking for damages from an insured; or
To sue us on this Coverage Part unless all of its terms have been fully complied with.
A person or organization may sue us to recover on an agreed settlement or on a final judgment against an insured; but we will not be liable for damages that are not payable under the terms of this Coverage Part or that are in excess of the applicable limit of insurance. An agreed settlement means a settlement and release of liability signed by us, the insured, and the claimant or the claimant's legal representative.

COMMERCIAL GENERAL LIABILITY

Other Insurance
If valid and collectible other insurance is available to the insured for a loss we cover under Coverages A or B of this Coverage Part, our obligations are limited as described in Paragraphs a. and b. below.
As used anywhere in this Coverage Part, other insurance means insurance, or the funding of losses, that is provided by, through or on behalf of:
Another insurance company;
Us or any of our affiliated insurance companies, except when the Non cumulation of Each Occurrence Limit provision of Paragraph 5. of Section Ill - Limits Of Insurance or the Non cumulation of Personal and Advertising Injury Limit provision of Paragraph 4. of Section Ill - Limits	of Insurance applies	because the Amendment -	Non Cumulation Of Each Occurrence	Limit	Of	Liability	And	Non Cumulation Of Personal And Advertising Injury Limit endorsement is included in this policy;
Any risk retention group; or
Any self-insurance method or program, in which case the insured will be deemed to be the provider of other insurance.
Other insurance does not include umbrella insurance, or excess insurance, that was bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part.
As used anywhere in this Coverage Part, other insurer means a provider of other insurance. As used in Paragraph c. below, insurer means a provider of insurance.
Primary Insurance
This insurance is primary except when Paragraph b. below applies. If this insurance is primary, our obligations are not affected unless any of the other insurance is also primary. Then, we will share with all that other insurance by the method described in Paragraph c. below, except when Paragraph d. below applies.
Excess Insurance
This insurance is excess over:
Any of the other insurance, whether primary, excess, contingent or on any other basis:
That is Fire, Extended Coverage, Builder's Risk, Installation Risk or similar coverage for "your work";

That is insurance for "premises damage";
If the loss arises out of the maintenance or use of aircraft, "autos" or watercraft to the extent not subject to any exclusion in this Coverage Part that applies to aircraft, "autos" or watercraft;
That is insurance available to a premises	owner,	manager	or lessor that qualifies as an insured under Paragraph 4. of Section II - Who Is An Insured, except when Paragraph d. below applies; or
That is insurance available to an equipment lessor that qualifies as an insured under Paragraph 5. of Section II - Who Is An Insured, except when Paragraph d. below applies.
Any of the other insurance, whether primary, excess, contingent or on any other basis, that is available to the insured when the insured is an additional insured, or is any other insured that does not qualify as a named insured, under such other insurance.
When this insurance is excess, we will have no duty under Coverages A or B to defend the insured against any "suit" if any other insurer has a duty to defend the insured against that "suit". If no other insurer defends, we will undertake to do so, but we will be entitled to the insured's rights against all those other insurers.
When this insurance is excess over other insurance, we will pay only our share of the amount of the loss, if any, that exceeds the sum of:
The total amount that all such other insurance would pay for the loss in the absence of this insurance; and
The total of all deductible and self­ insured amounts under all that other insurance.
We will share the remaining loss, if any, with any other insurance that is not described in this Excess Insurance provision and was not bought specifically to apply in excess of the Limits of Insurance shown in the Declarations of this Coverage Part.

COMMERCIAL GENERAL LIABILITY

Method Of Sharing
If all of the other insurance permits contribution by equal shares, we will follow this method also. Under this approach each insurer contributes equal amounts until it has paid its applicable limit of insurance or none of the loss remains, whichever comes first.
If any of the other insurance does not permit contribution by equal shares, we will contribute by limits. Under this method, each insurer's share is based on the ratio of its applicable limit of insurance to the total applicable limits of insurance of all insurers.
Primary And Non-Contributory Insurance If Required By Written Contract
If you specifically agree in a written contract or agreement that the insurance afforded to an insured under this Coverage Part must apply on a primary basis, or a primary and non­ contributory basis, this insurance is primary to other insurance that is available to such insured which covers such insured as a named insured, and we will not share with that other insurance, provided that:
The "bodily injury'' or "property damage" for which coverage is sought occurs; and
The "personal and advertising injury" for which coverage is sought is caused by an offense that is committed;
subsequent to the signing of that contract or agreement by you.
Premium Audit
We will compute all premiums for this Coverage Part in accordance with our rules and rates.
Premium shown in this Coverage Part as advance premium is a deposit premium only. At the close of each audit period we will compute the earned premium for that period and send notice to the first Named Insured. The due date for audit and retrospective premiums is the date shown as the due date on the bill. If the sum of the advance and audit premiums paid for the policy period is greater than the earned premium, we will return the excess to the first Named Insured.
The first Named Insured must keep records of the information we need for premium computation, and send us copies at such times as we may request.
Representations
By accepting this policy, you agree:

The	statements	in	the	Declarations	are accurate and complete;
Those	statements	are	based	upon representations you made to us; and
We have issued this policy in reliance upon your representations.
The unintentional omission of, or unintentional error in, any information provided by you which we relied upon in issuing this policy will not prejudice your rights under this insurance. However, this provision does not affect our right to collect additional premium or to exercise our rights of cancellation or nonrenewal in accordance with applicable insurance laws or regulations.
Separation Of Insureds
Except with respect to the Limits of Insurance, and any rights or duties specifically assigned in this Coverage Part to the first Named Insured, this insurance applies:
As if each Named Insured were the only Named Insured; and
Separately to each insured against whom claim is made or "suit" is brought.
Transfer Of Rights Of Recovery Against Others To Us
If the insured has rights to recover all or part of any payment we have made under this Coverage Part, those rights are transferred to us. The insured must do nothing after loss to impair them. At our request, the insured will bring "suit" or transfer those rights to us and help us enforce them.
When We Do Not Renew
If we decide not to renew this Coverage Part, we will mail or deliver to the first Named Insured shown in the Declarations written notice of the nonrenewal not less than 30 days before the expiration date.
If notice is mailed, proof of mailing will be sufficient proof of notice.
SECTION V - DEFINITIONS
"Advertisement" means a notice that is broadcast or published to the general public or specific market segments about your goods, products or services for the purpose of attracting customers or supporters. For the purposes of this definition:
Notices that are published include material placed on the Internet or on similar electronic means of communication; and
Regarding websites, only that part of a website that is about your goods, products or services for the purposes of attracting customers or supporters is considered an advertisement.

COMMERCIAL GENERAL LIABILITY

"Advertising injury'':
Means injury caused by one or more of the following offenses:
Oral or written publication, including publication by electronic means, of material in your "advertisement" that slanders or libels a person or organization or disparages a person's or organization's goods, products or services, provided that the claim is made or the "suit" is brought by a person or organization that claims to have been slandered or libeled, or that claims to have had its goods, products or services disparaged;
Oral or written publication, including publication by electronic means, of material in your "advertisement" that:
Appropriates a person's name, voice, photograph or likeness; or
Unreasonably places a person in a false light; or
Infringement of copyright, "title" or "slogan" in your "advertisement", provided that the claim is made or the "suit" is brought by a person or organization that claims ownership of such copyright, "title" or "slogan".
Includes "bodily injury" caused by one or more of the offenses described in Paragraph a. above.
"Auto" means:
A land motor vehicle, trailer or semitrailer designed for travel on public roads, including any attached machinery or equipment; or
Any other land vehicle that is subject to a compulsory or financial responsibility law, or other motor vehicle insurance law, where it is licensed or principally garaged.
However, "auto" does not include "mobile equipment".
"Bodily injury'' means:
Physical harm, including sickness or disease, sustained by a person; or
Mental anguish, injury or illness, or emotional distress, resulting at any time from such physical harm, sickness or disease.
"Broadcasting" means transmitting any audio or visual material for any purpose:
By radio or television; or

In, by or with any other electronic means of communication, such as the Internet, if that material is part of:
Radio or television programming being transmitted;
Other entertainment, educational, instructional, music or news programming being transmitted; or
Advertising transmitted with any of such programming.
"Coverage territory" means:
The United States of America (including its territories and possessions), Puerto Rico and Canada;
International waters or airspace, but only if the injury or damage occurs in the course of travel or transportation between any places included in Paragraph a. above; or
All other parts of the world if the injury or damage arises out of:
Goods or products made or sold by you in the territory described in Paragraph a. above;
The activities of a person whose home is in the territory described in Paragraph a. above, but is away for a short time on your business; or
"Personal and advertising injury" offenses that take place through the Internet or similar electronic means of communication;
provided the insured's responsibility to pay damages is determined in a "suit" on the merits in the territory described in Paragraph a. above, or in a settlement we agree to.
"Electronic data" means information, facts or programs stored as or on, created or used on, or transmitted to or from computer software (including systems and applications software), hard or floppy disks, CD-ROMs, tapes, drives, cells, data processing devices or any other media which are used with electronically controlled equipment.
"Employee" includes a "leased worker". "Employee" does not include a "temporary worker".
"Executive officer" means a person holding any of the officer positions created by your charter, constitution, bylaws or any other similar governing document.

COMMERCIAL GENERAL LIABILITY

"Good Samaritan services" means any emergency medical services for which no compensation is demanded or received.
"Hostile fire" means a fire which becomes uncontrollable or breaks out from where it was intended to be.
"Impaired property" means tangible property, other than "your product" or "your work", that cannot be used or is less useful because:
It incorporates "your product" or "your work" that is known or thought to be defective, deficient, inadequate or dangerous; or
You have failed to fulfill the terms of a contract or agreement;
if such property can be restored to use by the repair, replacement, adjustment or removal of "your product" or "your work" or your fulfilling the terms of the contract or agreement.
"Insured contract" means:
A contract for a lease of premises. However, that portion of the contract for a lease of premises that indemnifies any person or organization for "premises damage" is not an "insured contract";
A sidetrack agreement;
Any easement or license agreement, except in connection with construction or demolition operations on or within 50 feet of a railroad;
An obligation, as required by ordinance, to indemnify a municipality, except in connection with work for a municipality;
An elevator maintenance agreement;
That part of any other contract or agreement pertaining to your business (including an indemnification of a municipality in connection with work performed for a municipality) under which you assume the tort liability of another party to pay for "bodily injury", "property damage" or "personal injury'' to a third person or organization. Tort liability means a liability that would be imposed by law in the absence of any contract or agreement.
Paragraph f. does not include that part of any contract or agreement:
That indemnifies a railroad for "bodily injury'' or "property damage" arising out of construction or demolition operations, within 50 feet of any railroad property and affecting any railroad bridge or trestle,

tracks, roadbeds, tunnel, underpass or crossing;
That indemnifies an architect, engineer or suNeyor for injury or damage arising out of:
Preparing, approving, or failing to prepare or approve, maps, shop drawings, opinions, reports, surveys, field orders, change orders or drawings and specifications; or
Giving directions or instructions, or failing to give them, if that is the primary cause of the injury or damage; or
Under which the insured, if an architect, engineer or suNeyor, assumes liability for an injury or damage arising out of the insured's rendering or failure to render professional services, including those listed in Paragraph (2) above and supeNisory, inspection, architectural or engineering activities.
"Leased worker" means a person leased to you by a labor leasing firm under an agreement between you and the labor leasing firm, to perform duties related to the conduct of your business. "Leased worker" does not include a "temporary worker".
"Loading or unloading" means the handling of property:
After it is moved from the place where it is accepted for movement into or onto an aircraft, watercraft or "auto";
While it is in or on an aircraft, watercraft or "auto"; or
While it is being moved from an aircraft, watercraft or "auto" to the place where it is finally delivered;
but "loading or unloading" does not include the movement of property by means of a mechanical device, other than a hand truck, that is not attached to the aircraft, watercraft or "auto".
"Mobile equipment" means any of the following types of land vehicles, including any attached machinery or equipment:
Bulldozers, farm machinery, forklifts and other vehicles designed for use principally off public roads;
Vehicles maintained for use solely on or next to premises you own or rent;
Vehicles that travel on crawler treads;

COMMERCIAL GENERAL LIABILITY

Vehicles, whether self-propelled or not, maintained primarily to provide mobility to permanently mounted:
Power cranes, shovels, loaders, diggers or drills; or
Road construction or resurfacing equipment such as graders, scrapers or rollers;
Vehicles not described in Paragraph a., b., c. or d. above that are not self-propelled and are maintained primarily to provide mobility to permanently attached equipment of the following types:
Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment; or
Cherry pickers and similar devices used to raise or lower workers;
Vehicles not described in Paragraph a., b., c. or d. above maintained primarily for purposes other than the transportation of persons or cargo.
However, self-propelled vehicles with the following types of permanently attached equipment are not "mobile equipment" but will be considered "autos":
Equipment designed primarily for:
Snow removal;
Road	maintenance,	but	not construction or resurfacing; or
Street cleaning;
Cherry pickers and similar devices mounted on automobile or truck chassis and used to raise or lower workers; and
Air compressors, pumps and generators, including spraying, welding, building cleaning, geophysical exploration, lighting and well servicing equipment.
However, "mobile equipment" does not include any land vehicle that is subject to a compulsory or financial responsibility law, or other motor vehicle insurance law, where it is licensed or principally garaged. Such land vehicles are considered "autos".
"Occurrence" means:
An accident, including continuous or repeated exposure to substantially the same general harmful conditions; or

An act or omission committed in providing or failing to provide first aid or "Good Samaritan services" to a person, unless you are in the business or occupation of providing professional health care services.
"Personal and advertising injury'' means "personal injury" or "advertising injury".
"Personal injury'':
Means injury, other than "advertising injury'', caused by one or more of the following offenses:
False arrest, detention or imprisonment;
Malicious prosecution;
The wrongful eviction from, wrongful entry into, or invasion of the right of private occupancy of a room, dwelling or premises that a person occupies, provided that the wrongful eviction, wrongful entry or invasion of the right of private occupancy is committed by or on behalf of the owner, landlord or lessor of that room, dwelling or premises;
Oral or written publication, including publication by electronic means, of material that slanders or libels a person or organization or disparages a person's or organization's goods, products or services, provided that the claim is made or the "suit" is brought by a person or organization that claims to have been slandered or libeled, or that claims to have had its goods, products or services disparaged; or
Oral or written publication, including publication by electronic means, of material that:
Appropriates a person's name, voice, photograph or likeness; or
Unreasonably places a person in a false light.
Includes "bodily injury" caused by one or more of the offenses described in Paragraph a. above.
"Pollutants" mean any solid, liquid, gaseous or thermal irritant or contaminant, including smoke, vapor, soot, fumes, acids, alkalis, chemicals and waste. Waste includes materials to be recycled, reconditioned or reclaimed.

COMMERCIAL GENERAL LIABILITY

"Premises damage" means:
With respect to the first paragraph of the exceptions in Exclusion j. of Section I - Coverage A - Bodily Injury And Property Damage Liability, "property damage" to any premises while rented to you for a period of seven or fewer consecutive days, including the contents of such premises; or
With respect to the exception to Exclusions c. through n. in the last paragraph of Paragraph 2. of Section I - Coverage A - Bodily Injury And Property Damage Liability, "property damage" to
any premises while rented to you for a period of more than seven consecutive days, or while temporarily occupied by you with permission of the owner, caused by:
Fire;
Explosion;
Lightning;
Smoke resulting from fire, explosion or lightning; or
Water.
But "premises damage" under this Paragraph
b. does not include "property damage" to any premises caused by:
Rupture, bursting, or operation of pressure relief devices;
Rupture or bursting due to expansion or swelling of the contents of any building or structure caused by or resulting from water; or
Explosion of steam boilers, steam pipes, steam engines or steam turbines.
"Products-completed operations hazard":
Includes all "bodily injury" and "property damage" occurring away from premises you own or rent and arising out of "your product" or "your work" except:
Products that are still in your physical possession; or
Work that has not yet been completed or abandoned. However, "your work" will be deemed completed at the earliest of the following times:
When all of the work called for in your contract has been completed.
When all of the work to be done at the job site has been completed if your

contract calls for work at more than one job site.
When that part of the work done at a job site has been put to its intended use by any person or organization other than another contractor or subcontractor working on the same project.
Work that may need service, maintenance, correction, repair or replacement, but which is otherwise complete, will be treated as completed.
Does not include "bodily injury'' or "property damage" arising out of:
The transportation of property, unless the injury or damage arises out of a condition in or on a vehicle not owned or operated by you, and that condition was created by the "loading or unloading" of that vehicle by any insured;
The existence of tools, uninstalled equipment or abandoned or unused materials; or
Products or operations for which the classification, listed in the Declarations or in a policy Schedule, states that products­ completed operations are subject to the General Aggregate Limit.
"Property damage" means:
Physical injury to tangible property, including all resulting loss of use of that property. All such loss of use will be deemed to occur at the time of the physical injury that caused it; or
Loss of use of tangible property that is not physically injured. All such loss of use will be deemed to occur at the time of the "occurrence" that caused it.
For the purposes of this insurance, "electronic data" is not tangible property.
"Slogan":
Means a phrase that others use for the purpose of attracting attention in their advertising.
Does not include a phrase used as, or in, the name of:
Any person or organization, other than you; or
Any business, or any of the premises, goods, products, services or work, of any person or organization, other than you.

COMMERCIAL GENERAL LIABILITY

"Suit" means a civil proceeding in which damages because of "bodily injury", "property damage" or "personal and advertising injury'' to which this insurance applies are alleged. "Suit" includes:
An arbitration proceeding in which such damages are claimed and to which the insured must submit or does submit with our consent; or
Any other alternative dispute resolution proceeding in which such damages are claimed and to which the insured submits with our consent.
"Temporary worker" means a person who is furnished to you to substitute for a permanent "employee" on leave or to meet seasonal or short­ term workload conditions.
"Title" means a name of a literary or artistic work.
"Unsolicited communication" means any communication, in any form, that the recipient of such communication did not specifically request to receive.
"Volunteer worker" means a person who is not your "employee", and who donates his or her work and acts at the direction of and within the scope of duties determined by you, and is not paid a fee, salary or other compensation by you or anyone else for their work performed for you.
"Your product":
Means:
Any goods or products, other than real property, manufactured, sold, handled, distributed or disposed of by:

You;
Others trading under your name; or
A person or organization whose business or assets you have acquired; and
Containers (other than vehicles). materials, parts or equipment furnished in connection with such goods or products.
Includes:
Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your product"; and
The providing of or failure to provide warnings or instructions.
Does not include vending machines or other property rented to or located for the use of others but not sold.
"Your work":
Means:
Work or operations performed by you or on your behalf; and
Materials, parts or equipment furnished in connection with such work or operations.
Includes:
Warranties or representations made at any time with respect to the fitness, quality, durability, performance or use of "your work"; and
The providing of or failure to provide warnings or instructions.

COMMERCIAL GENERAL LIABILITY

THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY.

XTEND ENDORSEMENT FOR CONTRACTORS

This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART
GENERAL DESCRIPTION OF COVERAGE - This endorsement broadens coverage. However, coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to this Coverage Part, and these coverage broadening provisions do not apply to the extent that coverage is excluded or limited by such an endorsement. The following listing is a general coverage description only. Read all the provisions of this endorsement and the rest of your policy carefully to determine rights, duties, and what is and is not covered.

Who Is An Insured - Unnamed Subsidiaries
Blanket Additional Insured - Governmental Entities - Permits Or Authorizations Relating To Operations

Incidental Medical Malpractice
Blanket Waiver Of Subrogation
Contractual Liability - Railroads
Damage To Premises Rented To You

PROVISIONS
WHO	IS	AN	INSURED SUBSIDIARIES

UNNAMED

An organization other than a partnership, joint venture or limited liability company; or
A trust;

The following is added to SECTION II - WHO IS AN INSURED:
Any of your subsidiaries, other than a partnership, joint venture or limited liability company, that is not shown as a Named Insured in the Declarations is a Named Insured if:
You are the sole owner of, or maintain an ownership interest of more than 50% in, such subsidiary on the first day of the policy period; and
Such subsidiary is not an insured under similar other insurance.
No such subsidiary is an insured for "bodily injury" or "property damage" that occurred, or "personal and advertising injury" caused by an offense committed:
Before you maintained an ownership interest of more than 50% in such subsidiary; or
After the date, if any, during the policy period that you no longer maintain an ownership interest of more than 50% in such subsidiary.
For purposes of Paragraph 1. of Section II - Who Is An Insured, each such subsidiary will be deemed to be designated in the Declarations as:

as indicated in its name or the documents that govern its structure.
BLANKET	ADDITIONAL	INSURED GOVERNMENTAL ENTITIES - PERMITS OR AUTHORIZATIONS RELATING TO OPERATIONS
The following is added to SECTION II - WHO IS AN INSURED:
Any governmental entity that has issued a permit or authorization with respect to operations performed by you or on your behalf and that you are required by any ordinance, law, building code or written contract or agreement to include as an additional insured on this Coverage Part is an insured, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" arising out of such operations.
The insurance provided to such governmental entity does not apply to:
Any "bodily injury", "property damage" or "personal and advertising injury" arising out of operations performed for the governmental entity; or
Any "bodily injury" or "property damage" included in the "products-completed operations hazard".

CG DJ 16 02 19	© 2017 The Travelers Indemnity Company. All rights reserved.	Page 1 of 3

COMMERCIAL GENERAL LIABILITY

INCIDENT AL MEDICAL MALPRACTICE
The following replaces Paragraph b. of the definition of "occurrence" in the DEFINITIONS Section:
b. An act or omission committed in providing or failing to provide "incidental medical services", first aid or "Good Samaritan services" to a person, unless you are in the business or occupation of providing professional health care services.
The following replaces the last paragraph of Paragraph 2.a.(1) of SECTION II - WHO IS AN INSURED:
Unless you are in the business or occupation of providing professional health care services, Paragraphs (1)(a). (b). (c) and (d) above do not apply to "bodily injury" arising out of providing or failing to provide:
"Incidental medical services" by any of your "employees" who is a nurse, nurse assistant, emergency medical technician or paramedic; or
First aid or "Good Samaritan services" by any of your "employees" or "volunteer workers", other than an employed or volunteer doctor. Any such "employees" or "volunteer workers" providing or failing to provide first aid or "Good Samaritan services" during their work hours for you will be deemed to be acting within the scope of their employment by you or performing duties related to the conduct of your business.
The following replaces the last sentence of Paragraph 5. of SECTION Ill - LIMITS OF INSURANCE:
For the purposes of determining the applicable Each Occurrence Limit, all related acts or omissions committed in providing or failing to provide "incidental medical services", first aid or "Good Samaritan services" to any one person will be deemed to be one "occurrence".
The	following	exclusion	is	added	to Paragraph 2., Exclusions, of SECTION I - COVERAGES - COVERAGE A - BODILY INJURY	AND		PROPERTY		DAMAGE LIABILITY:
Sale Of Pharmaceuticals
"Bodily injury" or "property damage" arising out of the violation of a penal statute or ordinance  relating  to  the  sale  of

pharmaceuticals committed by, or with the knowledge or consent of, the insured.
The following is added to the DEFINITIONS
Section:
"Incidental medical services" means:
Medical, surgical, dental, laboratory, x-ray or nursing service or treatment, advice or instruction, or the related furnishing of food or beverages; or
The furnishing or dispensing of drugs or medical, dental, or surgical supplies or appliances.
The following is added to Paragraph 4.b., Excess Insurance, of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS:
This insurance is excess over any valid and collectible other insurance, whether primary, excess, contingent or on any other basis, that is available to any of your "employees" for "bodily injury" that arises out of providing or failing to provide "incidental medical services" to any person to the extent not subject to Paragraph 2.a.(1) of Section II - Who Is An Insured.
BLANKET WAIVER OF SUBROGATION
The following is added to Paragraph 8., Transfer Of Rights Of Recovery Against Others To Us, of SECTION IV - COMMERCIAL GENERAL LIABILITY CONDITIONS:
If the insured has agreed in a contract or agreement to waive that insured's right of recovery against any person or organization, we waive our right of recovery against such person or organization, but only for payments we make because of:
"Bodily injury" or "property damage" that occurs; or
"Personal and advertising injury" caused by an offense that is committed;
subsequent to the execution of the contract or agreement.
CONTRACTUAL LIABILITY - RAILROADS
The following replaces Paragraph c. of the definition of "insured contract" in the DEFINITIONS Section:
Any easement or Iicense agreement;

Page 2 of 3	© 2017 The Travelers Indemnity Company. All rights reserved.	CG DJ 16 02 19

COMMERCIAL GENERAL LIABILITY

Paragraph f.(1) of the definition of "insured contract" in the DEFINITIONS Section is deleted.
DAMAGE TO PREMISES RENTED TO YOU
The following replaces the definition of "premises damage" in the DEFINITIONS Section:
"Premises damage" means "property damage" to:

Any premises while rented to you or temporarily occupied by you with permission of the owner; or
The contents of any premises while such premises is rented to you, if you rent such premises for a period of seven or fewer consecutive days.

CG DJ 16 02 19	© 2017 The Travelers Indemnity Company. All rights reserved.	Page 3 of 3

WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY	WC 00 03 13
(Ed. 4-84)

WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT

We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.)

This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule.

Schedule

*Blanket Waiver of Subrogation Applies*

This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. Date Prepared: April 8, 2021

Carrier: BusinessFirst Insurance Company Effective Date of Endorsement: April 17, 2021
Policy Number: 521-20579	Countersigned by:

Insured: Pipeline Constructors, Inc.

WC 00 03 13 (Ed. 4-84)

"Includes copyright material of the National Council on Compensation Insurance, Inc. used with its permission. Copyright 1984 NCCI"